Loading...
HomeMy WebLinkAbout04323 - INTERACTIVE DESIGN SKATE PARK PALM 3A City of Palm Springs �O`` *� Office of the City Clerk (760) 323-8204 � N MEMORANDUM OiCIFOV- Date: May 7, 2003 To: Parks & Recreation From: City Clerk AGREEMENT#4323— Interactive Design Center Please let us know the status of the above agreement, and if it may be closed. Termination Date of Agreement: 12-20-01 STATUS: COMPLETED: REMAIN OPEN UNTIL: Date & Initials CLOSE AGR Signature PLEASE RETURN TO THE OFFICE OF THE CITY CLERK c-clk\fo ms.std\agr-clse.mem • Interactive Design Corp Skate Park/Swim Ctr design AGREEMENT #4323 M06767, 12-20-00 CITY OF PALM SPRINGS CONTRACT SERVICES AGREEMENT FOR ARCHITECTURAL SERVICES THIS CONTRACT SERVICES AGREEMENT(herein "Agreement"), is made and entered into this X day of �fi re+_, 20j, by and between the CITY OF PALM SPRINGS, a municipal corporation, (herein "City") and Interactive Design Corporation, (herein "Contractor"). (The term Contractor includes professionals performing in a consulting capacity.) The parties hereto agree as follows: 1.0 SERVICES OF CONTRACTOR 1.1 Scope of Services. In compliance with all terms and conditions of this Agreement, the Contractor shall provide those services specified in the "Scope of Services" attached hereto as Exhibit"A" and incorporated herein by this reference, which services may be referred to herein as the "services" or "work" hereunder. As a material inducement to the City entering into this Agreement, Contractor represents and warrants that Contractor is a provider of first class work and services and Contractor is experienced in performing the work and services contemplated herein and, in light of such status and experience, Contractor covenants that it shall follow the highest professional standards in performing the work and services required hereunder and that all materials will be of good quality, fit for the purpose intended. For purposes of this Agreement, the phrase "highest professional standards" shall mean those standards of practice recognized by one or more first-class firms performing similar work under similar circumstances. 1.2 Contractor's Proposal. The Scope of Service shall include the Contractor's proposal or bid which shall be incorporated herein by this reference as though fully set forth herein. In the event of any inconsistency between the terms of such proposal and this Agreement, the terms of this Agreement shall govern. 1.3 Compliance with Law. All services rendered hereunder shall be provided in accordance with all ordinances, resolutions, statutes, rules, and regulations of the City and any Federal, State or local governmental agency having jurisdiction in effect at the time service is rendered. 1.4 Licenses, Permits, Fees and Assessments. Contractor shall obtain at its sole cost and expense such licenses, permits and approvals as may be required by law for the performance of the services required by this Agreement. Contractor shall have the sole obligation to pay for any fees, assessments and taxes, plus applicable penalties and interest,which may be imposed by law and arise from or are necessary for the Contractor's performance of the services required by this Agreement, and shall indemnify, defend and hold harmless City against any such fees, assessments, taxes penalties or interest levied, assessed or imposed against City hereunder. 1.5 Familiarity with Work. By executing this Contract, Contractor warrants that Contractor(a) has thoroughly investigated and considered the scope of services to be performed, (b) has carefully considered how the services should be performed, and (c)fully understands the facilities, difficulties and restrictions attending performance of the services under this Agreement. If the services involve work upon any site, Contractor warrants that Contractor has or will investigate the site and is or will be fully acquainted with the conditions there existing, prior to commencement of services hereunder. Should the Contractor discover any latent or unknown conditions,which will materially affect the performance of the services hereunder, Contractor shall immediately inform the City of such fact and shall not proceed except at Contractor's risk until written instructions are received from the Contract Officer. SPECIAL/INTERACTIVE DESIGN Revised.03/17/99 1 1.6 Care of Work. The Contractor shall adopt reasonable methods during the life of the Agreement to furnish continuous protection to the work, and the equipment, materials, papers, documents, plans, studies and/or other components thereof to prevent losses or damages, and shall be responsible for all such damages, to persons or property, until acceptance of the work by City, except such losses or damages as may be caused by City's own negligence. 1.7 Further Responsibilities of Parties. Both parties agree to use reasonable care and diligence to perform their respective obligations under this Agreement. Both parties agree to act in good faith to execute all instruments, prepare all documents and take all actions as may be reasonably necessary to carry out the purposes of this Agreement. Unless hereafter specified, neither party shall be responsible for the service of the other. 1.8 Additional Services. City shall have the right at any time during the performance of the services, without invalidating this Agreement, to order extra work beyond that specified in the Scope of Services or make changes by altering, adding to or deducting from said work. No such extra work may be undertaken unless a written order is first given by the Contract Officer to the Contractor, incorporating therein any adjustment in (i) the Contract Sum, and/or (ii) the time to perform this Agreement, which said adjustments are subject to the written approval of the Contractor. Any increase in compensation of up to five percent (5%) of the Contract Sum or $25,000; whichever is less, or in the time to perform of up to one hundred eighty (180) days may be approved by the Contract Officer. Any greater increases, taken either separately or cumulatively must be approved by the City Council. It is expressly understood by Contractor that the provisions of this Section shall not apply to services specifically set forth in the Scope of Services or reasonably contemplated therein. Contractor hereby acknowledges that it accepts the risk that the services to be provided pursuant to the Scope of Services maybe more costly or time consuming than Contractor anticipates and that Contractor shall not be entitled to additional compensation therefore. 1.9 Special Requirements. Additional terms and conditions of this Agreement, if any, which are made a part hereof are set forth in the "Special Requirements" attached hereto as Exhibit"B" and incorporated herein by this reference. In the event of a conflict between the provisions of Exhibit"B" and any other provisions of this Agreement, the provisions of Exhibit"B" shall govern. 2.0 COMPENSATION 2.1 Contract Sum. For the services rendered pursuant to this Agreement, the Contractor shall be compensated in accordance with the "Schedule of Compensation" attached hereto as Exhibit"C" and incorporated herein by this reference, but not exceeding the maximum contract amount of $36,060 (herein "Contract Sum") (See Exhibit "C"), except as provided in Section 1.8. The method of compensation may include: (i)a lump sum payment upon completion, (ii)payment in accordance with the percentage of completion of the services, (iii) payment for time and materials based upon the Contractor's rates as specified in the Schedule of Compensation, but not exceeding the Contract Sum or (iv) such other methods as may be specified in the Schedule of Compensation. Compensation may include reimbursement for actual and necessary expenditures for reproduction costs,telephone expense, transportation expense approved by the Contract Officer in advance, and no other expenses and only if specified in the Schedule of Compensation. The Contract Sum shall include the attendance of Contractor at all project meetings reasonably deemed necessary by the City; Contractor shall not be entitled to any additional compensation for attending said meetings. 2.2 Method of Payment. Unless some other method of payment is specified in the Schedule of Compensation, in any month in which Contractor wishes to receive payment, no later than the first(1st)working day of such month, Contractor shall submit to the City in the form approved by the City's Director of Finance, an invoice for services rendered prior to the date of SPECIAIJINTERACTIVE DESIGN 2Revised 03/17/99 the invoice. Except as provided in Section 7.3, City shall pay Contractor for all expenses stated thereon which are approved by City pursuant to this Agreement no later than the last working day of the month. 3.0 PERFORMANCE SCHEDULE 3.1 Time of Essence. Time is of the essence in the performance of this Agreement. 3.2 Schedule of Performance. Contractor shall commence the services pursuant to this Agreement upon receipt of a written notice to proceed and shall perform all services within the time period(s) established in the "Schedule of Performance" attached hereto as Exhibit "D", if any, and incorporated herein by this reference. When requested by the Contractor, extensions to the time period(s) specified in the Schedule of Performance may be approved in writing by the Contract Officer but not exceeding one hundred eighty (180) days cumulatively. 3.3 Force Maieure. Thetime period(s)specified in the Schedule of Performance for performance of the services rendered pursuant to this Agreement shall be extended because of any delays due to unforeseeable causes beyond the control and without the fault or negligence of the Contractor, including, but not restricted to, acts of God or of the public enemy, unusually severeweather,fires,earthquakes,floods,epidemics,quarantine restrictions,riots, strikes,freight embargoes, wars, litigation, and/or acts of any governmental agency, including the City, if the Contractor shall within ten (10) days of the commencement of such delay notify the Contract Officer in writing of the causes of the delay. The Contract Officer shall ascertain the facts and the extent of delay, and extend the time for performing the services for the period of the enforced delay when and if in the judgment of the Contract Officer such delay is justified. The Contract Officer's determination shall be final and conclusive upon the parties to this Agreement. In no event shall Contractor be entitled to recover damages against the City for any delay in the performance of this Agreement, howevercaused,Contractor's sole remedy being extension of the Agreement pursuant to this Section. 3.4 Term. Unless earlier terminated in accordance with Section 7.8 of this Agreement, this Agreement shall continue in full force and effect until completion of the services but notexceeding one(1)yearfrom the date hereof,except as otherwise provided in the Schedule of Performance. 4.0 COORDINATION OF WORK 4.1 Representative of Contractor. The following principals of Contractor are hereby designated as being the principals and representatives of Contractor authorized to act in its behalf with respect to the work specified herein and make all decisions in connection therewith: REUEL A. YOUNG, A.I.A. INTERACTIVE DESIGN CORPORATION It is expressly understood that the experience, knowledge, capability and reputation of the foregoing principals were a substantial inducement for City to enter into this Agreement. Therefore, the foregoing principals shall be responsible during the term of this Agreement for directing all activities of Contractor and devoting sufficient time to personally supervise the services hereunder. For purposes of this Agreement,the foregoing principals may not be replaced nor may their responsibilities be substantially reduced by Contractor without the express written approval of City. 4.2 Contract Officer. The Contract Officer shall be such person as may be designated by the City Manager of City. It shall be the Contractor's responsibility to assure that SPECIALflNTERACTIVE DESIGN Revised 03/17/99 3 the Contract Officer is kept informed of the progress of the performance of the services and the Contractor shall refer any decisions which must be made by City to the Contract Officer. Unless otherwise specified herein, any approval of City required hereunder shall mean the approval of the Contract Officer. The Contract Officer shall have authority to sign all documents on behalf of the City required hereunder to carry out the terms of this Agreement. 4.3 Prohibition Against Subcontracting or Assignment. The experience, knowledge, capability and reputation of Contractor, its principals and employees were a substantial inducement for the City to enter into this Agreement. Therefore, Contractor shall not contractwith any other entity to perform in whole or in part the services required hereunder without the express written approval of the City. In addition, neither this Agreement nor any interest herein maybe transferred, assigned,conveyed, hypothecated or encumbered voluntarily orby operation of law, whether for the benefit of creditors or otherwise, without the prior written approval of City. Transfers restricted hereunder shall include the transfer to any person or group of persons acting in concert of more than twenty five percent (25%) of the present ownership and/or control of Contractor, taking all transfers into account on a cumulative basis. In the event of any such unapproved transfer, including any bankruptcy proceeding, this Agreement shall be void. No approved transfer shall release the Contractororany surety of Contractor of any liability hereunder without the express consent of City. The City's policy is to encourage the awarding of subcontracts to persons or entities with offices located within the jurisdictional boundaries of the City of Palm Springs and, if none are available, to persons or entities with offices located in the Coachella Valley ("Local Subcontractors"). Contractor hereby agrees to use good faith efforts to award subcontracts to Local Subcontractors, if Local Subcontractors are qualified to perform the work required. In requesting for the City to consent to a subcontract with a person or entity that is not a Local Subcontractor, the Contractor shall submit evidence to the City that such good faith efforts have been made or that no Local Subcontractors are qualified to perform the work. Said good faith efforts may be evidenced by placing advertisements inviting proposals or by sending requests for proposals to selected Local Subcontractors. The City may consider Contractor's efforts in determining whether it will consent to a particular subcontractor. Contractor shall keep evidence of such good faith efforts and copies of all contracts and subcontracts hereunder for the period specified in Section 6.2. 4.4 Independent Contractor. Neither the City nor any of its employees shall have any control over the manner, mode or means by which Contractor, its agents or employees, perform the services required herein, except as otherwise set forth herein. City shall have no voice in the selection, discharge, supervision or control of Contractor's employees, servants, representatives or agents, or in fixing their number, compensation or hours of service. Contractor shall perform all services required herein as an independent contractor of City and shall remain at all times as to City a wholly independent contractorwith only such obligations as are consistent with that role. Contractor shall not at any time or in any manner represent that it or any of its agents or employees are agents or employees of City. City shall not in any way or for any purpose become or be deemed to be a partner of Contractor in its business or otherwise or a joint venturer or a member of any joint enterprise with Contractor. 5.0 INSURANCE, INDEMNIFICATION AND BONDS 5.1 Insurance. The Contractor shall procure and maintain, at its sole cost and expense, in a form and content satisfactory to City, during the entire term of this Agreement including any extension thereof, the following policies of insurance: (a) Comprehensive General Liability Insurance. A policy of comprehensive general liability insurance written on a per occurrence basis. The policy of insurance shall be in an amount not less than either(i) a combined single limit of $1,000,000 for bodily injury, death and property damage or(ii)bodily injury limits of$500,000 per person, $1,000,000 peroccurrence SPECIAIJINTERACTIVE DESIGN 4 Revised 03/17/99 and $1,000,000 products and completed operations and property damage limits of$500,000 per occurrence. If the Contract Sum is greater than $100,000, the policy of insurance shall be in an amount not less than $5,000,000 combined single limit. (b) Worker's Compensation Insurance. A policy of worker's compensation insurance in such amount as will fully comply with the laws of the State of California and which shall indemnify, insure and provide legal defense for both the Contractor and the City against any loss, claim or damage arising from any injuries or occupational diseases occurring to any worker employed by or any persons retained by the Contractor in the course of carrying out the work or services contemplated in this Agreement. (c) Automotive Insurance. A policy of comprehensive automobile liability insurance written on a per occurrence basis in an amount not less than either (i) bodily injury liability limits of$500,000 perperson and$1,000,000 peroccurrence and propertydamage liability limits of $250,000 per occurrence and $500,000 in the aggregate or (ii) combined single limit liability of$1,000,000. Said policy shall include coverage for owned, non-owned, leased and hired cars. (d) Additional Insurance. Policies of such other insurance, including professional liability insurance, as may be required in the Special Requirements. All of the above policies of insurance shall be primary insurance and shall name the City, its officers, employees and agents as additional insureds, except that the City shall not be named as an additional insured for the Worker's Compensation Insurance nor the Professional Liability Insurance. The insurer shall waive all rights of subrogation and contribution it may have against the City, its officers, employees and agents and their respective insurers. All of said policies of insurance shall provide that said insurance may not be amended or canceled without providing thirty (30) days prior written notice by registered mail to the City. In the event any of said policies of insurance are canceled, the Contractor shall, prior to the cancellation date, submit new evidence of insurance in conformance with this Section 5.1 to the Contract Officer. No work or services under this Agreement shall commence until the Contractor has provided the City with Certificates of Insurance or appropriate insurance binders evidencing the above insurance coverages and said Certificates of Insurance or binders are approved by the City. All certificates shall name the City as additional insured (providing the appropriate endorsement), be signed by an authorized agent of the insurer, and shall contain the following "cancellation" notice: "CANCELLATION: Should any of the above described policies be canceled before the expiration date thereof, the issuing company shall mail an advance 30-day written notice to the Certificate holder named herein." The Contractor agrees that the provisions of this Section 5.1 shall not be construed as limiting in any way the extent to which the Contractor may be held responsible for the payment of damages to any persons or property resulting from the Contractor's activities or the activities of any person or persons for which the Contractor is otherwise responsible. In the event the Contractor subcontracts any portion of the work in compliance with Section 4.3 of this Agreement, the contract between the Contractor and such subcontractor shall require the subcontractor to maintain the same policies of insurance that the Contractor is required to maintain pursuant to this Section 5.1. 5.2 Indemnification. Contractor agrees to indemnify the City, its officers,agents and employees against, and will hold and save them and each of them harmless from, any and all actions, suits, claims, damages to persons or property, losses, costs, penalties, obligations, errors, omissions or liabilities, (herein"claims or liabilities")that may be asserted or claimed by any SPECIAVINTERACTIVE DESIGN 5 Revised'03/17/99 person, firm or entity arising out of or in connection with the negligent performance of the work, operations or activities of Contractor, its agents, employees, subcontractors, or invitees, provided for herein, or arising from the negligent acts or omissions of Contractor hereunder, or arising from Contractor's negligent performance of or failure to perform any term, provision, covenant or condition of this Agreement, whether or not there is concurrent passive or active negligence on the part of the City, its officers, agents or employees but excluding such claims or liabilities to the extent caused by the negligence orwillful misconduct of the City, its officers, agents or employees, who are directly responsible to the City, and in connection therewith: (a) Contractorwill promptly pay anyjudgment rendered againstthe City, its officers, agents or employees, including but not limited to, legal costs and attorneys' fees for any such claims or liabilities arising out of or in connection with the negligent performance of or failure to perform such work, operations or activities of Contractor hereunder; and Contractor agrees to save and hold the City, its officers, agents, and employees harmless therefrom; (b) In the event the City, its officers, agents or employees is made a party to any action or proceeding filed or prosecuted against Contractorfor such damages or other claims arising out of or in connection with the negligent performance of or failure to perform the work, operation or activities of Contractor hereunder, Contractor agrees to pay to the City, its officers, agents or employees, any and all costs and expenses incurred by the City, its officers, agents or employees in such action or proceeding, including but not limited to, legal costs and attorneys' fees. 5.3 Performance Bond. Concurrently with execution of this Agreement, Contractor shall deliver to City a performance bond in the sum of the amount of this Agreement, in the form provided by the City Clerk, which secures the faithful performance of this Agreement, unless such requirement is waived by the Contract Officer. The bond shall contain the original notarized signature of an authorized officer of the surety and affixed thereto shall be a certified and current copy of his power of attorney. The bond shall be unconditional and remain in force during the entire term of the Agreement and shall be null and void only if the Contractor promptly and faithfully performs all terms and conditions of this Agreement. 5.4 Sufficiency of Insurer or Surety. Insurance or bonds required by this Agreement shall be satisfactory only if issued by companies qualified to do business in California, rated"A"or better in the most recent edition of Best Rating Guide, The Key Rating Guide or in the Federal Register, and only if they are of a financial category Class VII or better, unless such requirements are waived by the City Manager or designee of the City ("City Manager") due to unique circumstances. In the event the City Manager determines that the work or services to be performed under this Agreement creates an increased or decreased risk of loss to the City, the Contractor agrees that the minimum limits of the insurance policies and the performance bond required by this Section 5 may be changed accordingly upon receipt of written notice from the City Manager or designee; provided that the Contractor shall have the right to appeal a determination of increased coverage by the City Manager to the City Council of City within ten (10) days of receipt of notice from the City Manager. 6.0 REPORTS AND RECORDS 6.1 Reports. Contractor shall periodically prepare and submit to the Contract Officer such reports concerning the performance of the services required by this Agreement as the Contract Officer shall require. Contractor hereby acknowledges that the City is greatly concerned about the cost of work and services to be performed pursuant to this Agreement. For this reason, Contractor agrees that if Contractor becomes aware of any facts, circumstances, techniques, or events that may or will materially increase or decrease the cost of the work or services contemplated herein or, if Contractor is providing design services, the cost of the project being designed, Contractor shall promptly notify the Contract Officer of said fact, circumstance, technique or event and the estimated increased or decreased cost related thereto and, if SPECIAVINTERACTIVE DESIGN R. d:03/17/99 6 Contractor is providing design services, the estimated increased or decreased cost estimate for the project being designed. 6.2 Records. Contractor shall keep, and require subcontractors to keep, such books and records as shall be necessary to perform the services required by this Agreement and enable the Contract Officer to evaluate the performance of such services. The Contract Officer shall have full and free access to such books and records at all times during normal business hours of City, including the right to inspect, copy, audit and make records and transcripts from such records. Such records shall be maintained for a period of three (3) years following completion of the services hereunder, and the City shall have access to such records in the event any audit is required. 6.3 Ownership of Documents. All drawings, specifications, reports, records, documents and othermaterials prepared by Contractor, its employees,subcontractors and agents in the performance of this Agreement shall be the property of City and shall be delivered to City upon request of the Contract Officer or upon the termination of this Agreement, and Contractor shall have no claim for further employment or additional compensation as a result of the exercise by City of its full rights of ownership of the documents and materials hereunder. Any use of such completed documents for other projects and/or use of uncompleted documents without specific written authorization by the Contractor will be at the City's sole risk and without liability to Contractor, and the City shall indemnify the Contractor for all damages resulting therefrom. Contractor may retain copies of such documents for its own use. Contractor shall have an unrestricted right to use the concepts embodied therein. All subcontractors shall provide for assignment to City of any documents or materials prepared by them, and in the event Contractor fails to secure such assignment, Contractor shall indemnify City for all damages resulting therefrom. 6.4 Release of Documents. The drawings, specifications, reports, records, documents and other materials prepared by Contractor in the performance of services under this Agreement shall not be released publicly without the priorwritten approval of the Contract Officer. 7.0 ENFORCEMENT OF AGREEMENT 7.1 California Law. This Agreement shall be construed and interpreted both as to validity and to performance of the parties in accordance with the laws of the State of California. Legal actions concerning any dispute, claim or matter arising out of or in relation to this Agreement shall be instituted in the Superior Court of the County of Riverside, State of California, or any other appropriate court in such county, and Contractor covenants and agrees to submit to the personal jurisdiction of such court in the event of such action. 7.2 Disputes. In the event of any dispute arising under this Agreement, the injured party shall notify the injuring party in writing of its contentions by submitting a claim therefor. The injured party shall continue performing its obligations hereunder so long as the injuring party commences to cure such default within ten (10) days of service of such notice and completes the cure of such default within forty-five (45) days after service of the notice, or such longer period as may be permitted by the injured party; provided that if the default is an immediate danger to the health, safety and general welfare, such immediate action may be necessary. Compliance with the provisions of this Section shall be a condition precedent to termination of this Agreement for cause and to any legal action, and such compliance shall not be a waiver of any party's right to take legal action in the event that the dispute is not cured, provided that nothing herein shall limitCity's orthe Contractor's right to terminate this Agreement without cause pursuant to Section 7.8. 7.3 Retention of Funds. Contractor hereby authorizes City to deduct from any amount payable to Contractor(whether or not arising out of this Agreement) (i) any amounts the payment of which may be in dispute hereunder orwhich are necessary to compensate City for any SPECIAUINTERACTIVE DESIGN Revised:03/17/99 losses, costs, liabilities, or damages suffered by City, and (ii) all amounts for which City may be liable to third parties, by reason of Contractor's acts or omissions in performing or failing to perform Contractor's obligation under this Agreement. In the event that any claim is made by a third party, the amount or validity of which is disputed by Contractor, or any indebtedness shall exist which shall appear to be the basis for a claim of lien, City may withhold from any payment due, without liability for interest because of such withholding, an amount sufficient to cover such claim. The failure of City to exercise such right to deduct or to withhold shall not, however, affect the obligations of the Contractor to insure, indemnify, and protect City as elsewhere provided herein. 7.4 Waiver. No delay or omission in the exercise of any right or remedy by a nondefaulting party on any default shall impair such right or remedy or be construed as a waiver. A party's consent to or approval of any act by the other party requiring the party's consent or approval shall not be deemed to waive or render unnecessary the other party's consent to or approval of any subsequent act. Any waiver by either party of any default must be in writing and shall not be a waiver of any other default concerning the same or any other provision of this Agreement. 7.5 Rights and Remedies are Cumulative. Except with respect to rights and remedies expressly declared to be exclusive in this Agreement, the rights and remedies of the parties are cumulative and the exercise by either party of one or more of such rights or remedies shall not preclude the exercise by it, at the same or different times, of any other rights or remedies for the same default or any other default by the other party. 7.6 Legal Action. In addition to any other rights or remedies, either party may take legal action, in law or in equity, to cure, correct or remedy any default, to recover damages for any default, to compel specific performance of this Agreement, to obtain declaratory or injunctive relief, or to obtain any other remedy consistent with the purposes of this Agreement. 7.7 Liquidated Damages. Since the determination of actual damages for any delay in performance of this Agreement would be extremely difficult or impractical to determine in the event of a breach of this Agreement, the Contractor and its sureties shall be liable for and shall pay to the City the sum of -0- ($ ) as liquidated damages for each working day of delay in the performance of any service required hereunder, as specified in the Schedule of Performance (Exhibit "D"). The City may withhold from any monies payable on account of services performed by the Contractor any accrued liquidated damages. 7.8 Termination Prior to Expiration Of Term. This Section shall govern any termination of this Agreement except as specifically provided in the following Section for termination for cause. The City reserves the right to terminate this Agreement at any time, with orwithout cause, upon thirty(30) days'written notice to Contractor, except that where termination is due to the fault of the Contractor, the period of notice may be such shorter time as may be determined by the Contract Officer. In addition, the Contractor reserves the right to terminate this Agreement at any time upon, with or without cause, upon sixty (60) days' written notice to City, except that where termination is due to the fault of the City, the period of notice may be such shorter time as the Contractor may determine. Upon receipt of any notice of termination, Contractor shall immediately cease all services hereunder except such as may be specifically approved by the Contract Officer. Except where the Contractor has initiated termination, the Contractor shall be entitled to compensation for all services rendered prior to the effective date of the notice of termination and for any services authorized by the Contract Officer thereafter in accordance with the Schedule of Compensation or such as may be approved by the Contract Officer, except as provided in Section 7.3. In the event the Contractor has initiated termination, the Contractor shall be entitled to compensation only for the reasonable value of the work product actually produced hereunder. In the event of termination without cause pursuant to this Section, the terminating party need not provide the non-terminating party with the opportunity to cure pursuant to Section 7.2. SPECIAIJINTERACTIVE DESIGN Revised:03117/99 8 7.9 Termination for Default of Contractor. If termination is due to the failure of the Contractor to fulfill its obligations under this Agreement, City may, after compliance with the provisions of Section 7.2, take over the work and prosecute the same to completion by contract or otherwise, and the Contractor shall be liable to the extent that the total cost for completion of the services required hereunder exceeds the compensation herein stipulated (provided that the City shall use reasonable efforts to mitigate such damages), and City may withhold any payments to the Contractor for the purpose of set-off or partial payment of the amounts owed the City as previously stated. 7.10 Attorneys' Fees. If either party to this Agreement is required to initiate or defend or made a party to any action or proceeding in any way connected with this Agreement, the prevailing party in such action or proceeding, in addition to any other relief which may be granted,whether legal orequitable, shall be entitled to reasonable attorney's fees. Attorney's fees shall include attorney's fees on any appeal, and in addition a party entitled to attorney's fees shall be entitled to all other reasonable costs for investigating such action, taking depositions and discovery and all other necessary costs the court allows which are incurred in such litigation. All such fees shall be deemed to have accrued on commencement of such action and shall be enforceable whether or not such action is prosecuted to judgment. 8.0 CITY OFFICERS AND EMPLOYEES: NON-DISCRIMINATION 8.1 Non-liability of City Officers and Employees. No officer or employee of the City shall be personally liable to the Contractor, or any successor in interest, in the event of any default or breach by the City or for any amount which may become due to the Contractor or to its successor, or for breach of any obligation of the terms of this Agreement. 8.2 Conflict of Interest. No officer or employee of the City shall have any financial interest, direct or indirect, in this Agreement nor shall any such officer or employee participate in any decision relating to the Agreement which effects his financial interest or the financial interest of any corporation, partnership or association in which he is, directly or indirectly, interested, in violation of any State statute or regulation. The Contractor warrants that it has not paid or given and will not pay or give any third party any money or other consideration for obtaining this Agreement. 8.3 Covenant Against Discrimination. Contractor covenants that, by and for itself, its heirs, executors, assigns, and all persons claiming under or through them,that there shall be no discrimination against or segregation of, any person or group of persons on account of race, color, creed, religion, sex, marital status, national origin, or ancestry in the performance of this Agreement. Contractor shall take affirmative action to insure that applicants are employed and that employees are treated during employment without regard to their race, color, creed, religion, sex, marital status, national origin, or ancestry. 9.0 MISCELLANEOUS PROVISIONS 9.1 Notice. Any notice, demand, request, document, consent, approval, or communication either party desires or is required to give to the other party or any other person shall be in writing and either served personally or sent by prepaid, first-class mail, in the case of the City, to the City Manager and to the attention of the Contract Officer, CITY OF PALM SPRINGS, P.O. Box 2743, Palm Springs, California 92263, and in the case of the Contractor, to the person at the address designated on the execution page of this Agreement. Either party may change its address by notifying the other party of the change of address in writing. Notice shall be deemed communicated at the time personally delivered or in seventy-two (72) hours from the time of mailing if mailed as provided in this Section. 9.2 Interpretation. The terms of this Agreement shall be construed in accordance with the meaning of the language used and shall not be construed for or against SPECIAUINTERACTIVE[DESIGN Revised:03117199 9 either party by reason of the authorship of this Agreement or any other rule of construction which might otherwise apply. 9.3 Integration;Amendment. It is understood that there are no oral agreements between the parties hereto affecting this Agreement and this Agreement supersedes and cancels any and all previous negotiations,arrangements,agreements and understandings, if any,between the parties,and none shall be used to interpret this Agreement. This Agreement maybe amended at any time by the mutual consent of the parties by an instrument in writing. 9.4 Severability. In the event that any one or more of the phrases, sentences, clauses, paragraphs, or sections contained in this Agreement shall be declared invalid or unenforceable by a valid judgment or decree of a court of competent jurisdiction, such invalidity or unenforceability shall not affect any of the remaining phrases, sentences,clauses,paragraphs, or sections of this Agreement which are hereby declared as severable and shall be interpreted to carry out the intent of the parties hereunder unless the invalid provision is so material that its invalidity deprives either party of the basic benefit of their bargain or renders this Agreement meaningless. 9.5 Corporate Authority. The persons executing this Agreement on behalf of the parties hereto warrant that (i) such party is duly organized and existing, (ii) they are duly authorized to execute and deliverthis Agreement on behalf of said party, (iii) by so executing this Agreement, such party is formally bound to the provisions of this Agreement, and (iv)the entering into this Agreement does not violate any provision of any other Agreement to which said party is bound. IN WITNESS WHEREOF, the parties have executed and entered into this Agreement as of the date first written above. CITY OF PALM SPRINGS, a municipal corporation +� • - f _ i� City Manager eity Clerk APPROVED AS TO FORM: (Ck"one: Individual_Partnership M"t� /Corporation) City orney CONTRACTOR: INTERACTIVE /DESIGN CORPORATION (NOTARIZED) By: �cG��G�G2i t ���i ���i ✓ r] ur , Z.G�II�N✓( Print Name&Title (NOTARIZED) (Corporations require two signatures: One from each of the By: following: A. Chairman of Board, President, any Vice President: AND B. Secretary, AssistantSecretary, Treasurer, Assistant Treasurer,or Chief Financial Officer). Print ame&Title i Mailing Address 3001 E ahquitz Canyon Way Suite#104 Palm Springs, CA 92262 (760) 323-4980/FAX (760) 322-5308 (END OF SIGNATURES) SPECIAUNTERACTIVE DESIGN Revised'03/17/99 10 EXHIBIT "A" SCOPE OF SERVICES 1. Contractor shall provide the following services: a. Programming i. Meet with City/Client staff and team consultants 1. Verify work program, schedules and channels of communication. 2. Review proposed master plan, skate park location, size, budget, schedule and design program. ii. Develop master design guidelines for skate park iii. Review with city staff proposed operations and relationship between Skate Park and Swim Center b. Existing conditions i. Review survey prepared by others ii. Review existing Swim Center structure in terms of possible seismic upgrade and to establish budget for upgrade iii. Review existing water treatment system to establish budget for upgrade iv. Review existing pump room in terms of spatial needs for new watertreatment equipment. c. Site analysis i. Develop environmental and physical analysis plan based on existing and proposed conditions ii. Develop access and operations analysis between Swim Center and Skate Park iii. Develop bubble diagrams illustrating site layout and program relationships to adjacent park amenities/conditions d. Conceptual design i. Develop bubble diagrams illustrating the layout and program relationships of the skate park to the overall master plan amenities. ii. Diagram skill levels, approximate size of amenities and circulation throughout each transition zone. iii. Diagram entry/access patterns for Skate Park and Swim Center e. Schematic Design i. Review conceptual diagrams, design guidelines and project budget prior to starting schematic design ii. Develop schematic skate park design based on conceptual bubble diagram layouts and client approval. iii. Facilitate work session (Design Workshop #1) to develop consensus of approved scheme/amenities to be incorporated in revised plan iv. Prepare Schematic Master Plan of approximately 30,000 SF, for which the preliminary construction budget is $500,000 incorporating: 1. Vehicular accesses parking and circulation diagrams. 2. Pedestrian access and circulation. 3. Landforms and grading concept (skate park only). v. Prepare Schematic Design Alternative related to the replacement and upgrading of watertreatment equipment forthe Swim Center,forwhich the preliminary construction budget is $200,000. vi. Schematic design services related to developing and evaluating alternative Master Site Planning approaches and refurbishment, upgrade and/or replacement of the Swim Center buildings and walls. Provide preliminary construction budget for all options prescribed. f. Revise Schematic Site Plan based upon Design Workshop #1 g. Conduct design workshop #2 h. Revise Schematic Master Plan based upon Design Workshop #2 i. Present Schematic Master Plan for review by Council and Commissions SPECIAUINTERACTIVE DESIGN ReAi etl:0317199 tt EXHIBIT "B" SPECIAL REQUIREMENTS Section 5.1, Insurance, first paragraph after 5.1(d), change to 5.1(e) and add the following to the end of the first sentence: "except for Professional Error and Omissions Insurance". Section 5.1, Insurance, replace 5.1(d) with the following: "(d) Professional Errors and Omissions Insurance. A policy of Professional and Omissions Insurance in an amount not less than Five Hundred Thousand Dollars ($500,000) per claim and in the aggregate with respect to loss arising from the actions of the Contractor performing professional services hereunder on behalf of the City. Section 5.3, Performance Bond. The requirement for a Performance Bond is waived for this Agreement. EXHIBIT "B" TO CONTRACT SERVICES AGREEMENT SRECIAUINTERACTIVE DESIGN R"w .d 03/17/99 12 EXHIBIT "C" SCHEDULE OF COMPENSATION PROGRAMMING/EXISTING CONDITIONS Hourly not to exceed $15,500 CONCEPTUAL DESIGN AND MASTER PLAN Hourly not to exceed $ 6,000 SCHEMATIC DESIGN Hourly not to exceed $ 7,000 MEETINGS AND PRESENTATIONS Unit rate of$840/meeting Meetings include: 2 Staff, 1 Field Survey, 2 Skaters, 1 Community, 1 Parks and Recreations Commission, 1 Planning Commission and 1 City Council meeting 9 meetings at$840/meeting $ 7,560 Total Compensation $36,060 EXHIBIT"C" TO CONTRACT SERVICES AGREEMENT SPECIAL/INTERACTNE DESIGN Revised.03/17/99 13 EXHIBIT "D" SCHEDULE OF PERFORMANCE The Contractor shall begin the Research and Programming Phase by March 15, 2001. Presentation to the City Council will take place by June 30,2001. EXHIBIT "D" TO CONTRACT SERVICES AGREEMENT SRECIAUINTERACTIVE DESIGN 14 Revised:03/17/99 CALIFORNIA 01=1 ALL-PURPOSE ACKNOWLEDGEMENT STATE OF CALIFORNIA COUNTY OF Riverside On Sept. 26, 2001 before Me, Elaine L. Wedekind, Notary Public ----------- DATE NAME,TITLE OF OFFICER -E.G.,"JANE DOE,NOTARY PUBLIC" personally appeared, Nedra Pope Young and Reuel A. Young ------------------------ personally known to me4Qr-proVed4o-me-on-tbe-basis-of satisfactory evidenceL)to be the person(§3) whose name i s/(fgq)subscrjbed to the within instrument and acknowledged to me that he/she/ S)xecthey in hislh uted the same ji) authorized capacit and that by his/he6jh1ir) signaturefisyon the instrument the persor as or the entity upon behalf of which the person(Bacted, executed the instrument. WITNESS my hand and official seal. N07�60 .. WtFD p 4IM'#12 EKIND ,y 0 1 PI)eLIC 06984 ll/�RSI 'CAL11ro (SEAL) colwj�7.. C Coo '?&JA 0 NOTARY PUBLIC SIGNATU Exa Fee sN os 0 OPTIONAL INFORMATION TITLE OR TYPE OF DOCUMENT DATE OF DOCUMENT NUMBER OF PAGES SIGNER(S)OTHER THAN NAMED ABOVE 09/28/20111 11.51 lUUU31121U9 AHib FAbE U2 ACiR CERTrF[GA- _ F LIABIUTY WSURA 620 r PRODUCER Serial# A2075 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ARTS INSURANCE SERVICES ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR 2101 BUSINESS CENTER DRIVE,SUITE 230 ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. IRVINE. CA 92612 LIC. NO 0795446 INSURERS AFFORDING COVERAGE INSURED ' w6URERA, AMERICAN ZURICH INS CO INTERACTIVE DESIGN CORP. INSURER 9 3001 E TAHOUITZ CANYON WAY,SUITE 104 M RERC; PALM SPRINGS, CA 92262 LIKURERD INBUflE0.E COVERAGES THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED NOTWITHSTANDING ANY REQUIREMENT. TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BYTHE POLICIES DESCRIBED HEREIN IS SUBJECTTO ALL THE TERMS,EXCLUSIONS AND CONDITIONS OF SUCH POLICIES,AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS, M6q TYPR OF INSURANCE POLICY NUMBER POLICY EFFECTIVE POLICygXPIRA ONiDATE Rk LIM116 GENERAL LIABILITY EACH OCCURRENCE S r COMMERCIAL GENERAL LIABILITY FIRE DAMAGE(Any one tlre) $ �� CLAIMS MADE E OCCVR MED EXP(Any one person) 6 PERSONAL G ADV INJURY 18 GENERAL AGGREGATE S I EN1 AOGREOATE LIMITAPPUES PER PRODUCTS-CO.MPIOP AGG 5 POLICY PRO- LOC AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT E ANY AUTO (Ea Eccpenl) F ALL OVINEDAUTOS BODILY INJURY SCHEDULED AUTOS (PRI P.nm) HIREDAUTOB BODILY INJURY ; NOW-OWNED AU706 (PSI ecUDPIIII PROPERTYDAMAGE 5 GARAGE.LIABILLTY AUTO ONLY_FA ACCIDENT $ _ANYAUTO OTHER THAN EA ACC 3 AUTO ONLY, AGG 4. EYCE661.IABILITY EACH OCCURRENCE S OCCUR ClAIM6 MAbE AOOgEOATE 5 5 DEDUCTIBLE E RETENTION S E WORKER6 COMPENSATION AND 2043665 09/01/01 09/01/02 x TORYL TU TR ST A EMPLOYERS`tIABItITY EL EACH ACCIDENT E 10DOD0O EL DISEASE-EA EMPLOYEE E 1000000 E.L.DISEASE-POLICY LIMIT 5 1000000 j OTHER I MISIRIPTION OFOPERATIONB/LOOhT1ONBNERIEtE$IEXDLN61ONl RDOEDBYENDORSEMENTjEPFCYAC PROVIBI \LL ARCHITECTURAL OPERATIONS OF THE NAMED INSURED C 0 lV TH-' E'IC1tT FOR No :ERTIFICATE HOLDER " ADDITIONAL INSURED INSURER LETTER: CANCELLATION ' I^ , `� .j ' " ` `- - SHODU-AN THEABOVE DESCRINEDPOLICIESSECANCELLED BEFORE THE EXPIRATIOa- THE CITY OF PALM SPRINGS PATE THEREOF,THE IBBUIN01NSURER WILL L'/UL46B-sO�MA`ILL 3D DAVIS WRITTEN ATTN: PATRICIAA SANDERS 4"BE TO THE GERTIFK;RFE-HOLDER NAMED To-THELEFT.nyJy.,'�i J�ri .j�Das&_aucG P O.BOX 2743 Poo uc N ,I R PALM SPRINGS, CA 92263-2743 :HCRIZGD REPRESENTATIVE ,CORD 26.9(7-197) O ACORD CORPORATION 1988, SEP-26-2001 > ED 03:54 PM WEINGARTEN III HOUGH ;An QU ibUjLDJ, s1 JL MY4 �y, 0 I TF/ 0 9 2 6 O 1 PRODUCER Weingarten & Hough-Lic#0086542 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION P 0 BOX 1866 ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED RY THE POLICIES BELOW. Palm Springs CA 92263 COMPANIES AFFORDING COVERAGE_ _ (760) 325-2526 COMPANY A Zurich Insurance Group INSURED COMPANY interactive Design Corporation B Safeco Insurace Co, _ 3001 Tahquitz Canyon Way #104 COMPANY c Palm Springs CA 92262 [fD THIS I&TO-CERTIFV THAT THE POLICIES-OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE-INSURED-NAMED-ABOVE FOR-THE POLICY F'ER I INDICATED,NOTWITHSTANDING ANY REQUIREMENT.TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS-AND CONDITION&OF SUCH POLICIE&LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. CO TYPE OF INSURANCE POLICY NUMBER POLICYEFFECTIVE POLICYIDINIs ION LIMITS LTR DATE IMMMUNYI DATe(MM1DDNVL A CENERALLIABILITY / (IENERALAGGRCGATE 82 000 000 X COMMERCIALGENERALLIABIULTY PA-ga S262-2.0`L a7/2-4,/G1 97-/24/02 PRODUCT&-CDMP/oPA00 DDQOa f}F}E} JCLAIMSMAUE FYI OCCUR PERSONAL&AOVINJURV $1 000 000 OWNER'S&CONTRACTOR'S PROT EACH OCCURRENCE i1,T IOL aaa- FIREDAMAGE(A^Yo_n._Ilra) 51 000 000 ... MED EXP(I w. ), S. L0- 0-0-0-'• B AUTOMOBILE LIABILITY ANY AUTO A230521S 02/17/01 02/17/02 COMBINED SINGLE LIMIT b ALL OWNED AUTOS ODDILY INJURY X SCHEDULED AUTOS (Par...... IS Soo000 HIRED AUTOS BODILY INJURY NON•OWNEDAUT09 (Par MJC10vtl 5500 000 --"- PROPERTY DAMAGE 5100 000 GAHAGEUABICRP AUTO ONLY-EA ACCIDENT 5 ANY AUTO / / / / OTHER THAN AUTO ONLY I EACH ACCIDENT 5 AGGREGATE 8 EXBF55 LIABIkR'Y / EACH OCCURRENCE S UMBRELLA FORM / / / / AGGREGATE 9 OTHER THANUMBRELLAFORM S WORXER5 COMPENSATION AND STATUTORY LIMITS PMPLOYERWIJABILITY EAO"A VENT S THEPROPRIEIOR/ INCL DISEASE-POLICY LIMIT 5 PARTNERWEXECUTIVE OFFICERS ARE EXCL DISEASE-EACHEMPLOYEE T OTHER DESCRIPTION OF OPERATIONSILOCATIONSNEHICLe SPECIAL ITEMS Certificate holder is named as an additional insured. Endarsement is on file with the company. Revised 9/26/01 to strike ',endeavor clause" . Paxed to 322-530H Ori final to follow b mail . cEHTlpI«4TFc,k#Q4CaR ;' 4MFISiATICN, SHOULD ANY OF THE ABOVE 0011411111150 POLICIES BE CANCELLED 9EFORE THE City of Palm Springs EXPIRATION DATE THEREOF, THE ISSUING COMPANY WILL LG 0061D6 MAIL Attn: City Clerk/Patricia Sanders 30 GAYS WRITTEN NOTICE TO THE CERTIFICATE MOLDER NAMED TO THE LEFT, 3200 Tahquitz Canyon Way Palm Springs CA 92262 Q tOO1�A17QNfggB' fclienty 5658 1 Lvv�Lvv INTEGCONSBINDYY) VVL ACORn_, CERTIFICAW, OF LIABILITY INSU CE 09/26/01 PRODUCER THIS CERTTFICATE ➢S ISSUED AS A MATTER OF INFORMnTTO1N Dealey, Renton 6 Associates ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE 600 S. Lake Avenue, �uUYte 30B HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. Pasadena, CA 91106 626 844 3070 INSURERS AFFORDING COVERAGE INSURED INSURRRA Design Professional Insurance Co. Integral-Consultants INSURERS 10 Lynnfield INSURER hVine,CA 92620 INSURER D. NSURER E COVERAGES THE POLICIES OF INSURM{CE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVB FOR THE POLICY PERIOD INDICATED NOTVITHSPAN'DIN ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTAACP OR OTHER DOCUNIENT WITH RESPECT' TO WMCIi TUBS CERTIFICATE MAY BE ISSUER 01 MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCR@ED HEREIN IS SUSPECT TO ALL THE TERMS,EXCLUSIONS AND CONDITIONS OF SUCF POLICIES AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS KES POLIOVEFFECTIVE PO6IOYEXPIRATION .TR TYPEOFINSURANUP POLICY NUMBER DATR(M DDYY DATE MMIDDIVYI LIMITS GENERAL LIABILITY RACE OCCURRENCE S COMM R RCIALGENERALLIABILITT PIRU DAMAGE(Any one i,a) S CLAIMS MADE OCCUR DIED ONE(Any une Fe...n) PERSONAL&ARC INJURY GENERALAGGREGATE S GENTAGOREGATE LINIRAPPLIE5 PER: PRODUCTS -CONIGOPAGG 5 POLICY PRO LOC AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT 5 .ANY AUTO @ammeNq ALL OWNED AUTOS BODILI'INJURY S SCHEDULBD AUTOS (Per ry+sery Ii1REDAUTDS BODILY INJURY $ NONOW NRD AUTOS (Per acatlen:� PROPERTY DAMAGE S (Pv ccitlenU MGARAGRUARMITY AUTOONLY EAACCIDENTANYAUTO CAACCOTLHERTHAN ALTO ONLY ACv 5 EXCESS LIABILITY PACE OCCURRENCE S O=Uz �CLAIMS MADE AGGREGAT2 S 5 DEDUCTIBLE S RETENTION S S WC STATUTH- , -WORHERS COMPEIiSATtpRrt�D O EMPLOYERS'LIABILITY E L EACH ACCIDENT 9 E L I iSBA5 BAEMPLOYER S EL DISEASE -POLICY LIMIT I S A rHDRProfeaaional PL509BB102 10/13/00 10/13/01 $1,000,000 per claim ability $1,000,000 aggregate DESCRIPTION OF OPERA]'IONSILOCAT10N%IVCHICLES/EXCLUSIONS ADDED BY ENDORIEMCNT/SPECIAL PROVISIONS CERTTFICATEHOLDER anDRXrIALwsursr.,o-wsuRERLETrers: CANCELLATION SHOU{AANYOFTNEA66VEDESCRIBEDI'IX,IC�S BD CANCCLLED IICF ORETHECl1'IILST!0.^I City of Palm Springs DATE THERE OF,THE ISSUING INSURER WILL)1KQQSX(XXKI1NAIL3.o_DAYS WRITERS Attn: Marilynn BoSWell IAMWC TOYHE CMTIVICATa IT CLDERs: RD TO TH K LNMXM gA� X-WXSQ}¢y¢XX 3200 Tahquitz Canyon Way xacx�aacaauomolcaca➢uswsaas�saaaxnamma�ncxinc lacB�aacx Palm Spr ngs,CA 92262 AUTHORIZEDREPRESENTATIVE yyk4q- cc, ACORD 25-S(719?) 1 of 1 #M46507 MAF 0 ACORD CORPORATION 1988