Loading...
HomeMy WebLinkAbout04231 - CVAG MULTI AGENCY TRAFFIC SIGNAL COOP CP95-06 Page 1 of 1 Kathie Hart From: Carrie Rovney Sent: May 04, 2009 9:10 AM To: Kathie Hart Cc: Dave Parakian, Richard Jenkins Subject: CVAG A#423 -Contract Status-CP#95-06 Kathie, Dave said that we can go ahead and CLOSE this agreement with CVAG regarding the Signal Interconnect Agreement for CP#95-06 C=p ` O5/04/09 CVAG Traffic Signal Co-op CP95-06 AGREEMENT #4231 Amend 1 FIRST AMENDMENT TO AGREEMENT NO. 42 MO7198, 11-26-02 „WI,THT'C"OACHELLA VALLEY ASSOCIATION OF GOVERNMEN-.— CVAG MULTI-AGENCY TRAFFIC SIGNAL COOPERATIVE AGREEMENT CITY PROJECT 95-06 The following provisions of Agreement No. 4231 are hereby amended to read as follows: SECTION 1 (a) is amended as follows: Revise the second sentence to read: Both parties agree that the budgeted amount for the construction within CPS is$564,555.67, Except as specifically amended by this Amendment No. 1, all terms and provisions of Agreement No. 4231 remain in full force and effect. ATTEST: CITY OF PALM SPRINGS, a municipal corporation 9 n �a . l �..,, ,rr/ By:. `°� City Cier City Manager fi APPROVED AS TO FORM: r �M V Tim a y ,�r'x�`�i"�:"vim �: -- — °City-Attorney COACHELLAVALLEYASSOCIATION OF GOVERNMENTS (CVAG) By: CVAG Chair By: � CVAG Executive Director CVAG Multi-Agency Traffic Signal :� ff Cooperative Agr AGREEMENT #4231 a' TRAFFIC SIGNAL COOPERATIVE AGREEMEl M06628, 6-7-- -- -- :i�9i THIS AGREEMENT (herein "Agreement") is made and entered into this day of i � ,2000,by and between the City of Palm Springs,a municipal corporation(herein CPS) agi'd the Coachella Valley Association of Governments(herein CVAG). The parties hereto agree as follows: RECITALS The City of Palm Springs has approval for Federal STP funding for construction of certain traffic signal improvements on Indian Canyon Drive. The seven (7) intersections are: Indian Canyon Drive at Baristo Road,Tamarisk Road,Amado Road,La Plaza Parking,Alejo Road,Arenas Road, and Andreas Road. In addition, the CVAG Valleywide Signal Synchronization project includes interconnecting these same signals on Indian Canyon Drive. Both designs were completed by DKS Assoc. under separate agreements with CPS and CVAG. The plans and specifications for both projects have been approved by both CPS and CVAG. It is the intent of both parties that the projects will be constructed by a single contractor tinder one contract(project). WITNESSETH WHEREAS,the traffic signal locations listed in"Exhibit A"are within the jurisdictional boundaries of CPS; and WHEREAS, Caltrans and CPS share jurisdiction or hold jurisdiction exclusively as indicated in "Exhibit A"; and WHEREAS,the Coachella Valley Traffic Signal Synchronization Feasibility Final Report and other engineering studies indicate that an intereou iected and/or coordinated traffic signal system would be mutually beneficial to the agencies and would improve traffic safety and flow; and WHEREAS, the CVAG Signal Synchronization PS&E Design will be implemented and provide a coordinated traffic signal system which would be mutually beneficial to the agencies and would improve traffic safety and flow; NOW THEREFORE, the parties agree as follows: 1. Project. CVAG and CPS hereby agree that CVAG will advertise,open bids,and enter into a construction contract with a licensed contractor for the construction of said projects. CVAG shall be lead agency and provide all inspection, construction engineering, administration in accordance with Federal rules and procedures,and testing for said project,with the exception of work included in Section B of the project specifications. All payments to contractors, engineers or consultants will be made directly by CVAG. CPS agrees to reimburse the following to CVAG upon presentation of pay estimates showing that the work has been performed and payment approved therefore: Agreement CPS/CVAG C.P. 495-06 Page 2 (a)Payment for all construction as shown on said drawings by DKS Associates,and included as Section B, as bid by the constriction contractor. Both parties agree that the budgeted amount for the construction within CPS is $522,200.00 for Section B. Payment shall be made in accordance with the construction Section B,as awarded by CVAG. A maximum of 1 progress payment shall be made per calendar month by CPS to CVAG. (b) CPS will perform all testing for items included on Section B, and will designate the testing laboratory for the signal equipment. (c) CPS agrees to perform all work necessary for the Federal reimbursement of costs Lmder Section B. (d)CPS agrees to review all reimbursement requests received from CVAG and to make such reimbursements within a reasonable period prior to contractor's payment from CVAG becoming due, subject to completion of construction of the items contained on the request,to satisfaction of CPS. (e) Signal Timing: CVAG shall provide the initial traffic signal coordination timing for the traffic signal locations listed in `Exhibit A". The timings shall be established and agreed upon in writing by the Traffic/City Engineer or his/her designee of CPS. Changes in cycle length, offsets and coordination time that affect system operation proposed by CPS that effects ally other adjacent city/county signal timings shall notify all affected parties for their review and shall then be agreed upon in writing by the Traffic/City Engineer or his/her designee of each affected party. (f) Common Time Reference: CPS shall maintain WWV clock time for its signals, with equipment provided by CVAG, and shall resynchronize system clock time each day. (g)Upgrade:If certain signals are mutually desired to be in the system but are not compatible due to obsolete or incompatible equipment, CPS shall upgrade the necessary equipment to bring the signals onto the system. If existing equipment is marginal in regards to operation, CPS shall consider upgrading the equipment in the normal course of project budgeting. (h)Maintenance:Upon completion of the traffic signal system and designated signal tuning, the maintenance of the system shall become the responsibility of CPS,individually,for those traffic signal locations within its jurisdiction. (i) Coordinating Committee: CPS understand that in order for the system to operate optimally it is necessary that the operational characteristics of the system be reviewed Agreement CPS/CVAG C.P. #95-06 Page 3 regularly. Therefore,CVAG shall establish a Coordinating Committee. The committee shall meet, at a minimum of semi-annually, to review the operating characteristics of the system and propose any needed modifications to the system. The committee shall be comprised of the Transportation Engineer of CVAG, or his/her designee, and the various Traffic/City Engineers of COOPERATING AGENCIES,or their designate representatives,and any other individual mutually agreed to by the parties. Each Coordinating Committee member shall be responsible for notifying all other committee member's as soon as possible but no later than the first working day following discovery within that member's boundary of a system failure, an emergency repair, or a power failure affecting the system. The committee member(s) of the COOPERATIVE AGENCY shall also give advance notice of at least two(2)working days prior to any shutdown of the master controller as part of regularly scheduled routine maintenance or any other regularly scheduled maintenance within his/her agency's boundary affecting the system. The Coordinating Committee shall prepare a summary report of its meetings,system activity and future needs at the end of each calendar year. The report shall be completed by January 3 1" of each year. 0) Records: All parties shall each keep open book records of the project which shall be available for inspection by any party at any reasonable time during business hours. (k) Notification: Notices shall be sufficient hereunder if personally served upon the City Manager/Administrator/Engineer of each party, or sent to those individuals via the United States Post Office, postage prepaid, addressed as follows: CPS shall have the right to review the Section B bids for the construction project. In the event the lowest responsible bid is more than the budgeted amount,CVAG may proceed with the project on its own, without any further participation with CPS. Both parties shall have the right to revise the bid specifications subject to standard change order procedures. As it pertains to work under section B,CPS shall have the right to review the construction project and approve such construction through CVAG's field inspector prior to completion of progress payments to the construction contractor. CPS shall have the right to review and approve any change orders or cost over-nuns for construction on Section B. CPS shall have the right to approve completion of the project and be a signator to the Notice of Completion. Copies of all documents pertaining to the construction shall be delivered to CPS upon written request to CVAG. CVAG shall schedule construction contractor such that construction on Section B will be completed on or before November 15, 2000 Agreement CPS/CVAG C.P. #95-06 Page 4 2. Force Majeure. If CVAG is delayed, prevented or hindered from the performance of any condition of this Agreement because of acts of God, adverse weather, war, invasion, insurrection, acts of a public enemy, riot, mob violence, civil commotion, sabotage, labor disputes, inability to procure or general shortage of labor,materials,facilities,equipment or supplies on the open market, unusual delay in transportation, laws, rules, regulations or orders of governmental or military authorities,inability to obtain permits or approvals or any other cause beyond the reasonable control of CVAG,whether similar or dissimilar to the foregoing,such perfonnance shall be excused for the period of the delay, provided that CVAG shall, within 5 days of the commencement of such delay, notify CPS in writing, of the and the period for such performance shall be extended for a period equivalent to the period of such delay, provided that CVAG shall, within five days of the commencement of such delay,notify CPS in writing of the causes of the delays. CPS shall ascertain the facts and the extent of delay, and extend the time for completion for the period of the enforced delay when and if, in the judgment of CPS, such delay is justified. 3. Miscellaneous Obligation. All services rendered hereunder shall be provided in accordance with all ordinances,resolutions,statutes,rules and regulations of CPS and CVAG,and any Federal,State or local govermnental agency having jurisdiction in effect at the time services are performed. Both parties agree to use reasonable care and diligence to perform their respective obligations under this Agreement. Both parties agree to act in good faith to execute all necessary instruments, prepare all documents, take all actions as may be reasonably necessary to carry out the purposes of this Agreement, and make contract payments and reimbursements. CVAG agrees to require the construction contractor to provide proof of insurance in the following amounts: Bodily injuries: $500,000 each person, $1,000,000 each accident, $1,000,OOOaggregate products and completed operations. Property damage $1,000,000 each accident. Workers' Compensation: statutory. CVAG agrees to require construction contractor to name CPS, its City Council, officers, officials and employees as additionally name insured with respect to liabilities arising out of construction contractor's performance of the work under construction contract. CVAG further agrees to require, with further provision, that such insurance is primary insurance with respect to the interests of the named parties,and that any other insurance maintained by the parties or other additionally named insureds,is excess and not contributing insurance with the insurance required hereunder. 4. Coordination of Work. Both parties agree that neither CPS,nor any of its respective employees, shall have any control over the man ier, mode or means by which the construction contractor, its agents, or employees perform the work required under their construction contract Agreement with Agreement CPS/CVAG C.P. 495-06 Page 5 CVAG with the exception of work include in Section B. CVAG agrees to allow CPS' employees access to the work site, and further agrees to enforce requirements of CPS, upon the construction contractor, upon receipt of verbal or written instructions from CPS' field personnel. 5. Records and Reports. CVAG agrees to provide CPS all final record drawings, specifications, reports, records, documents and other materials for the work performed under this Agreement. 6. Enforcement of Agreement. This Agreement shall be construed and interpreted both as to validity and to performance of the parties in accordance with the laws of the State of California. Legal actions concerning any dispute, claim or matter arising out of,or in relation to,this Agreement shall be instituted in the Superior Court of the County of Riverside, State of California, or any other appropriate court in such county. In the event of any dispute arising under this Agreement, the injured party shall notify the injuring party in writing of its contentions by submitting a claim therefor. The injured party shall continue performing its obligations hereunder so long as the injuring party commences to cure such default within ten (10) days of service of such notice and completes the cure of such default within forty-five (45) days after service of the notice, or such longer period as may be permitted by the injured party;provided that if the default is an immediate danger to the health, safety and general welfare, such immediate action may be necessary. Compliance with the provisions of this Section shall be a condition precedent to termination of this Agreement for cause and to any legal action, and such compliance shall not be a waiver of any parry's right to take legal action in the event that the dispute is not cured, provided that nothing herein shall limit CPS or CVAG's right to terminate this Agreement without cause pursuant to this Section. CVAG hereby authorizes CPS to deduct from any amount payable to CVAG(whether or not arising out of this Agreement)(i)any amounts the payment of which may be in dispute hereunder or which are necessary to compensate CPS for any losses, costs, liabilities, or damages suffered by CPS,and(ii)all amounts for which CPS may be liable to third parties,by reason of CVAG's acts or omissions in performing or failing to perform CVAG's obligation under this Agreement. In the event that any claim is made by a third party,the amount or validity of which is disputed by CVAG, or any indebtedness shall exist which shall appear to be the basis for a claim of lien, CPS may withhold from any payment due, without liability for interest because of such withholding, an amount sufficient to cover such claim. The failure of CPS to exercise such right to deduct or to withhold shall not, however, affect the obligations of CVAG to insure, indemnify, and protect CPS as elsewhere provided herein. No delay or omission in the exercise of any right or remedy by a nondefaulting party on any default shall impair such right or remedy or be construed as a waiver. A party's consent to or approval of any act by the other party requiring the party's consent or approval shall not be deemed Agreement CPS/CVAG C.P. 495-06 Page 6 to waive or render unnecessary the other party's consent to or approval of any subsequent act. Any waiver by either party of any default must be in writing and shall not be a waiver of any other default concerning the same or any other provision of this Agreement. Except with respect to rights and remedies expressly.declared to be exclusive in this Agreement,the rights and remedies of the parties are cumulative and the exercise by either party of one or more of such rights or remedies shall not preclude the exercise by it, at the same or different times, of any other rights or remedies for the same default or any other default by the other party. In addition to any other rights or remedies, either party may take legal action, in law or in equity,to cure,correct or remedy any default,to recover damages for any default,to compel specific performance of this Agreement, to obtain declaratory or injunctive relief, or to obtain any other remedy consistent with the purposes of this Agreement. This Section shall govern any termination of this Agreement except as specifically provided in the following Section for termination for cause. CPS reserves the right to terminate This Agreement at any time,with or without cause,upon thirty(30)days written notice to CVAG,except that where termination is due to the fault of CVAG,the period of notice may be such shorter time as may be determined by the Contract Officer. In addition, CVAG reserves the right to terminate this Agreement at any time, with or without cause, upon sixty (60) days written notice to CPS, except that where termination is due to the fault of CPS, the period of notice may be such shorter time as CVAG may determine. Upon receipt of any notice of termination, CVAG shall innnediately cease all services hereunder except such as may be specifically approved by the Contract Officer. Except where CVAG has initiated termination, CVAG shall be entitled to compensation for all services rendered prior to the effective date of the notice of termination and for any services authorized by the Contract Officer thereafter in accordance with the Schedule of Compensation or such as may be approved by the Contract Officer, except as provided in this Section. In the event CVAG has initiated termination, CVAG shall be entitled to compensation only for the reasonable value of the work product actually produced hereunder. In the event of termination without cause pursuant to this Section,the terminating party need not provide the non-terminating party with the opportunity to cure pursuant to this Section. 7. City Officers and Employees, Non-Discrimination. No officer or employee of CPS shall be personally liable to CVAG, or any successor in interest in the event of any default or breach by CPS, or for any amount which may become due to CVAG or to its successors, or for breach of any obligation of the terms of this Agreement. CVAG covenants that by and for itself, and all persons claiming under or through them,that there shall be no discrimination against or segregation of,any person or group of persons,on account of race, color, creed, religion, sex, marital status, physical or mental disability, national origin or Agreement CPS/CVAG C.P. 995-06 Page 7 ancestry, in the performance of this Agreement. 8. Miscellaneous Provisions. Any notice, demand, request, document, consent, approval, or communication either party desires, or is required to give to the other party, or any other person, shall be in writing and either served personally or sent by pre-paid, first class mail,to the following address: Coachella Valley Association of Governments Attention: Patricia Larson, Executive Director 73-710 Fred Waring Drive Suite 200 Palm Desert, CA. 92260 City of Palm Springs Attention.: David J. Barakian, City Engineer P.O. Box 2743 Palm Springs, CA 92263 Either party may change its address by notifying the other party of the change of address in writing. Notice shall be deemed communicated at the time personally delivered,or in 72 hours from the time of depositing in the mail, if mailed as provided in this section. The terms of this Agreement shall be construed in accordance with the meaning of the language used and shall not be construed for or against either party by reason of the authorship of this Agreement, or any other rule of construction which might otherwise apply. It is understood that there are no oral Agreements between the parties hereto affecting this Agreement, and this Agreement supersedes and cancels any and all previous negotiations, arrangements,Agreements and understandings,if any,between the parties,and none shall be used to interpret this Agreement. This Agreement may be amended at any time by the mutual consent of the parties by an instrument in writing. 9. Severability. In the event any one or more of the phrases, sentences, clauses, paragraphs or sections contained in this Agreement shall be declared invalid or unenforceable by a valid judgment or decree of the court of a competent jurisdiction, such invalidity or unenforecability shall not affect any of the remaining phrases, sentences, clauses, paragraphs or sections of this Agreement which are hereby declared as severable,and shall be interpreted to carry out the intent of the parties hereunder, unless the invalid provision is so material that its invalidity deprives either party of the basic benefit of their bargain or renders this Agreement meaningless. Agreement CPS/CVAG C.P. #95-06 Page 8 10. Authority. The persons executing this Agreement on behalf of the parties hereto warrant that(i) such party is duly organized and existing, (ii) they are duly authorized to execute and deliver this Agreement on behalf of said party, (iii) by so executing this Agreement, such party is formally bound to the provisions of this Agreement,and(iv)the entering into this Agreement does not violate any provision of any other Agreement to which said party is bound. 11. Waiver. No waiver of any breach of any of the terms, covenants, Agreements, restrictions or conditions of this Agreement shall be construed as a waiver of any succeeding breach of the same or other covenants, Agreements, restrictions and conditions hereof. Any and all waivers of the provisions of this Agreement must be in writing and signed by the appropriate authorities of CVAG and CPS. 12. Gender. The use herein of(i) the singular number shall be deemed to mean the plural; (ii) the masculine gender shall be deemed to mean the feminine or neuter and,(iii)the neuter gender shall be deemed to mean masculine or feminine whenever the sense of this Agreement so requires. 13. Execution. This Agreement may be executed in counterparts,each of which shall be deemed to be an original, and such counterpart, in the aggregate, shall constitute one and the same instrument. • i Agreement CPS/CVAG C.P. 995-06 Page 9 IN WITNESS WHEREOF, the parties have executed and entered into this Agreement as of the date first written above. AT , T: CITY OF PALM SPRINGS, a municipal corporation City Cleric City Manager APPROVED AS TO FORM: City(Al Qt 1rney COACHELLA VALLEY ASSOCIATION OF GOVERNMENTS (QVAQ) By: �f Cd �'S� �,t✓ i' ` ip �l Ctp�i`i�✓ APPRO- VED BY THE CITY COUNCIL Print ame & Title AY Re& mod By ��L3J Print Name & Title Mailing Address: 73710 Fred Waring Drive Suite 200 Palm Desert, CA 92260 - • EXHIBIT"A" • PALM DESERT COOK STREET FRED WARING DRIVE COOKSTREET HOVLEY LANE EAST COOK STREET MERLE DRIVE COUNTRY CLUB DRIVE COOK STREET COUNTRY CLUB DRIVE DESERT FALLS COUNTRY CLUB/THE LAKES COUNTRY CLUB COUNTRY CLUB DRIVE DESERT SPRINGS DRIVE COUNTRY CLUB DRIVE EL DORADO DRIVE COUNTRY CLUB DRIVE MONTEREYAVENUE COUNTRY CLUB DRIVE PALM GREENS PARKWAY COUNTRY CLUB DRIVE PALM VALLEY DRIVE/INDIAN RIDGE DRIVE COUNTRY CLUB DRIVE PORTOLA AVENUE COUNTRY CLUB DRIVE SAN TROPEZ/SUNCREST COUNTRY CLUB E.PALM CANYON DESERT CROSSING. E.PALM CANYON FRED WARING DR E.PALM CANYON PAINTERS PATI-I/PARKVIEW FRED WARING DRIVE HWYLI FRED WARING DRIVE WARNERTRAIL FRED WARING DRIVE EEP CANYON RD FREDWARINGDRIVE MONTEREY AVE FRED WARING DRIVE PHYLLIS JACKSON FRED WARING DRIVE PORTOLA FRED WARING DRIVE SAN PABLO FRED WARING DRIVE SAN PASCUAL FRED WARING DRIVE TOWN CENTER IIWY 111 PLAZA WAY HWY Ill DEEP CYN RD HWY 111 EL PASEO/CABRILLO HWY Ill HOSPITALITY ROW HWY 111 MONTEREY AVE/HWY 74 FIWY Ill PORTOLA AVE HWY I I I SAN LUIS REY AVE HWY 111 SAN PABLO AVE HWY ill TOWN CENTER/EL PASEO MONTEREY AVE SAN GORGONIO MONTEREY AVE CLANCEY LANE MONTEREY AVE COUNTRY CLUB DR MONTEREY AVE FRED WARING DR MONTEREY AVE GRAND VIA/L,PALMAS MONTEREY AVE PARK VIEW DR PALM SPRINGS N.PALM CYN TACHEVAH DRIVE N.PALM CYN TAMARISK ROAD N.PALM CYN ALElO ROAD N.PALM CYN AMADO CENTER N.PALM CYN AMADO ROAD N.PALM CYN ANDREAS ROAD N.PALM CYN FASHION PLAZA N/S PALM CYN TAHQUITZ CANYON WAY S.PALM CYN LA PLAZA PARKING LOT S.PALM CYN ARENAS ROAD S.PALM CYN VILLAGE GREEN S.PALM CYN BARISTO ROAD S.PALM CYN RAMON ROAD S.PALM CYN SUNNY DUNES S.PALM CYN MESQUITE S.PALM CYN MORONGO S.PALM CANYON E.PALM CANYON DR. E.PALM CANYON DR. CAMINO REAL E.PALM CANYON DR. SUNRISE E.PALM CANYON DR. SMOKETREE/CERRITOS RD • EXHIBIT"A" E.PALM CANYON DR. PARR ELL/BARONA RD. E.PALM CANYON DR. ESCOBA/ARABY RD E.PALM CANYON DR. CHEROKEE WY INDIAN CAYON DRIVE ALEIO ROAD INDIAN CAYON DRIVE AMADO ROAD INDIAN CAYON DRIVE ANDREAS ROAD INDIAN CAYON DRIVE ARENAS ROAD INDIAN CAPON DRIVE GRANVIA VALMONTE(Flasher) INDIAN CAYON DRIVE LA PLAZA PARKING LOT INDIAN CAYON DRIVE RAMON ROAD INDIAN CAYON DRIVE RACQUET CLUB INDIAN CAYON DRIVE SOUTH PALM CANYON DRIVE/CAMINO PAROCELA INDIAN CAYON DRIVE TACHEVAH DRIVE INDIAN CAYON DRIVE TAIIQUITZ CANYON WAY RAMON ROAD CALLE ENCILIA RAMON ROAD AVENIDA CABALLEROS RAMON ROAD SUNRISE WAY RAMONROAD FARRELL DRIVE RAMON ROAD COMPADRE ROAD RAMON ROAD EL CIELO ROAD RAMON ROAD ELPLACER RAMON ROAD PASEO DOROTEA RAMON ROAD GENE AUTRY TRAIL RAMON ROAD SAN LUIS REY AVE RAMON ROAD CROSSLEY ROAD RANCHO MIRAGE BOB HOPE DRIVE AVENIDA LAS PALMAS BOB HOPE DRIVE COUNTRY CLUB DRIVE BOB HOPE DRIVE DINAH SHORE DRIVE BOB HOPE DRIVE EISENHOWER MEDICAL CENTER/THE SPRINGS BOB HOPE DRIVE GERALD FORD DRIVE BOB HOPE DRIVE GINGER ROGERS AVENUE BOB HOPE DRIVE HOPE SQUARE BOB HOPE DRIVE RANCHO LAS PALMAS COUNTRY CLUB DRIVE .IOI-IN L SINN ROAD COUNTRY CLUB DRIVE VISTA DEL SOL/DESERT LAKES DRIVE E.PALM CANYON DR. INDIAN TRAIL RD. ' E.PALM CANYON DR. ATRIUM WAY E.PALM CANYON DR. BOB HOPE DR. E.PALM CANYON DR. COUNTRY CLUB DR E.PALM CANYON DR. FRANK SINATRA DR E.PALM CANYON DR. INNKEEPER E.PALM CANYON DR. MAGNESIA FALLS E.PALM CANYON DR. MIRAGE COVE DR E.PALM CANYON DR. PETERSON RD E.PALM CANYON DR. RANCI-10 LAS PALMAS DR E.PALM CANYON DR. THUNDERBIRD RD/FAIRWAY E.PALM CANYON DR. VIA FLORENCIO. FRANK SINATRA DRIVE BOB HOPE DRIVE FRANK SINATRA DRIVE DA VALL DRIVE FRANK SINATRA DRIVE MORNINGSIDE DRIVE/THOMPSON ROAD GERALD FORD DRIVE DA VALL DRIVE GERALD FORD DRIVE LOS ALAMOS DRIVEANVERNESS DRIVE EXHIBIT"A" CITY ARTERIAL STREET CROSSSTREET $LYTHE HOBSON WAY LOVEKIN ST HOBSON WAY MAIN ST. HOBSON WAY BROADWAY HOBSON WAY 7TH ST CATHEDRAL CITY E.PALM CANYON ALLEN AVE E.PALM CANYON AUTO PARK RD E.PALM CANYON CATHEDRAL CANYON DR E.PALM CANYON DATE PALM DR E.PALM CANYON E.BUDDY ROGERS E.PALM CANYON EAGLE CANYON PLAZA E.PALM CANYON EL DORADO E.PALM CANYON PEREZ E.PALM CANYON SUNGATE AVE E.PALM CANYON VAN FLEET AVE E.PALM CANYON W BUDDY ROGERS/GLEN VISTA CHINO AVENIDA MARAVILLA VISTA CHINO AVENIDA QUINTANA VISTA CHINO DATE PALM DRIVE VISTA CHINO LANDAU BOULEVARD COACHELLA IFWY 86 50TH AVE HWY 86 51 ST AVE HWY 86 52ND AVE HWY 86 6TH St IIWY 86 AIRPORT BLVD COUNTY OF RIVERSIDE COOK STREET 1-10 EB COOK STREET I-10 WB COOK STREET VARNER RD MONTEREY AVENUE BROADMOOR DRIVE MONTEREY AVENUE I-10 EB MONTEREY AVENUE I-IOWB MONTEREY AVENUE VARNER RD. VARNER I-IO WB WASHINGTON STREET MARKETPLACE WASHINGTON STREET 42 ND ST WASHINGTON STREET AVENUE OF THE STATES WASHINGTON STREET COUNTRY CLUB WASHINGTON STREET HARRIS LN WASHINGTON STREET I-10 EB WASHINGTON STREET VARNER RD DESERT HOT SPRINGS PALM DRIVE HACIENDA PALM DRIVE PIERSON PALM DRIVE TWO BUNCH PALMS INDIAN WELLS COOK STREET HORIZON WAY FRED WARING DRIVE COOKST FRED WARING DRIVE EL DORADO DR. HWY III EL DORADO DR HWY Ill INDIAN WELLS LN. HWY III CLUB DR HWY Ill COOK ST HWY III MILES AVE HWY Ill RANCHO PALMERAS DR HWY Ill VILLAGE CTR DR INDIO FRED WARING DRIVE CLINTON ST. FRED WARING DRIVE JEFFERSON 0 EXHIBIT"A" is FRED WARING DRIVE MADISON ST FRED WARING DRIVE MONROE ST ANDIO 44TH HWY ill ARABIA S'I' HWY Ill AUTO CTR DL/LORRAINE ST HWY ill CLINTON ST HWY II I INDIO BLVD/86 HWY ill JACKSON ST HWY Ill LAS PALMAS HWY ill MADISON ST HWY 111 MONROE ST IIWY Ill OASIS ST, HWY ill RUBIDOUX ST TIWY86 48 TH AVE MONROE STREET CROWN WAY MONROE STREET HIGHWAY 111 &AVE 46 MONROE STREET INDIO BOULEVARD MONROE STREET INDUSTRIAL PLACE MONROE STREET MILES AVENUE MONROE STREET SHADOW PALM AVENUE/REQUA AVENUE LA QUINTA FRED WARING DRIVE ADAMS ST FRED WARING DRIVE DUNE PALMS RD. FRED WARING DRIVE WASHINGTON ST HWY ill DUNE PALMS HWY 111 LA QUINTA CTR DR HWY III MT COVE HWY Ill SIMON DR, HWY 111 WASHINGTON ST HWY Ill ADAMS ST HWY ill HOME DEPOT DWY HWY Ill .JEFFERSON ST HWY III PLAZA LA QUINTA WASHINGTON STREET 47TH AVENUE WASHINGTON STREET 48TH AVENUE WASHINGTON STREET 50TH AVENUE/AVENIDA MAZATLAN WASHINGTON STREET CALLS TAMPICO WASIINGTON STREET EISENHOWER DRIVE/RANCHO LA QUINTA WASHINGTON STREET MILES WASHINGTON STREET ILA QUINTA VILLAGE s