HomeMy WebLinkAbout04760 - THIRDWAVE CORPORATION TIBURON COMPUTER ASSESSMENT COMPUTER CAPS Thirdwave Corporation
Tiburon Assessment
AGREEMENT #4760
CM signed 8-20-03
CITY OF PALM SPRINGS
CONTRACT SERVICES AGREEMENT FOR
Independent Review and Assessment of Computer Assisted Public Safety(`CAPS') System
THIS CONTRACT SERVICES AGREEMENT (herein "Agreement") is made and entered
into this 18th day of August, 2003, by and between the CITY OF PALM SPRINGS, a municipal
corporation (herein "City") and ThirdWave, Inc. (herein "Contractor").
NOW, THEREFORE, the parties hereto agree as follows:
1.0 SERVICES OF CONTRACTOR
1.1 Scope of Services. In compliance with all of the terms and conditions of
this Agreement, the Contractor shall perform the work or services set forth in the "Scope of
Services" attached hereto as Exhibit"A" and incorporated herein by reference. Contractor
warrants that all work and services set forth in the Scope of Services will be performed in a
competent, professional and satisfactory manner.
1.2 Compliance With Law. All work and services rendered hereunder shall
be provided in accordance with all ordinances, resolutions, statutes, rules, and regulations of
the City and any Federal, State or local governmental agency of competent jurisdiction.
1.3 Licenses, Permits Fees and Assessments. Contractor shall obtain at its
sole cost and expense such licenses, permits and approvals as may be required by law for the
performance of the services required by this Agreement.
1.4 Special Requirements. Additional terms and conditions of this
Agreement, if any, which are made a part hereof are set forth in the "Special Requirements"
attached hereto as Exhibit "B" and incorporated herein by this reference. In the event of a
conflict between the provisions of Exhibit "B" and any other provisions of this Agreement, the
provisions in Exhibit "B" shall govern.
2.0 COMPENSATION
2.1 Contract Sum. For the services rendered pursuant to this Agreement,
Contractor shall be compensated in accordance with the "Schedule of Compensation" attached
hereto as Exhibit "C" and incorporated herein by this reference, but not exceeding the maximum
contract amount of Eight Thousand Five Hundred Sixty-six Dollars ($8,566.00) ("Contract
Sum").
2.2 Method of Payment. Provided that Contractor is not in default under the
terms of this Agreement, in any month in which Contractor wishes to receive payment, no later
than the tenth (10ffi) day of such month, Contractor shall submit to the City in the form approved
by the City's Director of Finance, an invoice for services rendered prior to the date of the
invoice. City shall pay Contractor for all expenses stated thereon which are approved by City
pursuant to this Agreement no later than the last working day of the month.
_�_ P.tyep¢anC�l-�q:p��Nb-gN�. �f+aJ(�pjl.�l�+
3.0 COORDINATION OF WORK
3.1 Representative of Contractor. Roy Hernandez is hereby designated as
being the principal and representative of Contractor authorized to act in its behalf with respect to
the work and services specified herein and make all decisions in connection therewith.
3.2 Contract Officer. The Contract Officer shall be such person as may be
designated by the City Manager of City. It shall be the Contractor's responsibility to assure that
the Contract Officer is kept informed of the progress of the performance of the services and the
Contractor shall refer any decisions which must be made by City to the Contract Officer. Unless
otherwise specified herein, any approval of City required hereunder shall mean the approval of
the Contract Officer. The Contract Officer shall have authority to sign all documents on behalf
of the City required hereunder to carry out the terms of this Agreement.
3.3 Prohibition Against Subcontracting or Assignment. Contractor shall not
contract with any entity to perform in whole or in part the work or services required hereunder
without the express written approval of the City. Neither this Agreement nor any interest herein
may be assigned or transferred, voluntarily or by operation of law, without the prior written
approval of City. Any such prohibited assignment or transfer shall be void.
3.4 Independent Contractor. Neither the City nor any of its employees shall
have any control over the manner, mode or means by which Contractor, its agents or
employees, perform the services required herein, except as otherwise set forth. Contractor
shall perform all services required herein as an independent contractor of City and shall remain
under only such obligations as are consistent with that role. Contractor shall not at any time or
in any manner represent that it, or any of its agents or employees, are agents or employees of
City.
4.0 INSURANCE, INDEMNIFICATION AND BONDS
4.1 Insurance. The Contractor shall procure and maintain, at its sole cost
and expense, in a form and content satisfactory to City, during the entire term of this Agreement
including any extension thereof, the following policies of insurance:
(a) Commercial General Liability Insurance. A policy of commercial
general liability insurance written on a per occurrence basis with a combined single limit
of at least $1,000,000 bodily injury and property damage including coverages for
contractual liability, personal injury, independent contractors, broad form property
damage, products and completed operations. The Commercial General Liability Policy
shall name the City of Palm Springs as an additional insured in accordance with
standard ISO additional insured endorsement form CG2010(1185) or equivalent
language.
(b) Worker's Compensation Insurance. A policy of worker's
compensation insurance in an amount which fully complies with the statutory
requirements of the State of California and which includes $1,000,000 employer's
liability.
(c) Business Automobile Insurance. A policy of business automobile
liability insurance written on a per occurrence basis with a single limit liability in the
amount of$1,000,000 bodily injury and property damage. Said policy shall include
coverage for owned, non-owned, leased and hired cars.
-2-
(d) Additional Insurance. Additional limits and coverages, which may
include professional liability insurance, will be specified in Exhibit B.
All of the above policies of insurance shall be primary insurance. (Reference Section 4.4
regarding sufficiency.) The insurer shall waive all rights of subrogation and contribution it may
have against the City, its officers, employees and agents, and their respective insurers. In the
event any of said policies of insurance are canceled, the Contractor shall, prior to the
cancellation date, submit new evidence of insurance in conformance with this Section 4.1 to the
Contract Officer. No work or services under this Agreement shall commence until the
Contractor has provided the City with Certificates of Insurance, endorsements or appropriate
insurance binders evidencing the above insurance coverages and said Certificates of Insurance,
endorsements or binders are approved by the City.
The contractor agrees that the provisions of this Section 4.1 shall not be construed as
limiting in any way the extent to which the Contractor may be held responsible for the payment
of damages to any persons or property resulting from the Contractor's activities or the activities
of any person or persons for which the Contractor is otherwise responsible.
In the event the Contractor subcontracts any portion of the work in compliance with
Section 3.3 of this Agreement the contract between the Contractor and such subcontractor shall
require the subcontractor to maintain the same polices of insurance that the Contractor is
required to maintain pursuant to this Section.
4.2 Indemnification. Contractor agrees to indemnify the City, its officers,
agents and employees against, and will hold and save them and each of them harmless from,
any and all actions, suits, claims, damages to persons or property, losses, costs, penalties,
obligations, errors, omissions or liabilities, including paying any legal costs, attorneys' fees, or
paying any judgment (herein "claims or liabilities") that may be asserted or claimed by any
person, firm or entity arising out of the negligent performance of the work or services of
Contractor, its agents, employees, subcontractors, or invitees, provided for herein, or arising
from the negligent acts or omissions of Contractor hereunder, or arising from Contractor's
negligent performance of or failure to perform any term, provision, covenant or condition of this
Agreement, but excluding such claims or liabilities to the extent caused by the negligence or
willful misconduct of the City.
4.3 Performance Bond. Concurrently with execution of this Agreement,
Contractor shall deliver to City a performance bond in the sum of the amount of this Agreement,
in the form provided by the City, which secures the faithful performance of this Agreement,
unless such requirement is waived by the Contract Officer. The bond shall contain the original
notarized signature of an authorized officer of the surety and affixed thereto shall be a certified
and current copy of his power of attorney. The bond shall be unconditional and remain in force
during the entire term of the Agreement and shall be null and void only if the Contractor
promptly and faithfully performs all terms and conditions of this Agreement.
4.4 Sufficiency of Insurer or Surety. Insurance or bonds required by this
Agreement shall be satisfactory only if issued by companies qualified to do business in
California, rated "A" or better in the most recent edition of Best's Key Rating Guide or in the
Federal Register, unless such requirements are waived by the City Manager or designee of the
City Manager due to unique circumstances. In the event the City Manager determines that the
work or services to be performed under this Agreement creates an increased or decreased risk
of loss to the City, the Contractor agrees that the minimum limits of the insurance policies and
the performance bond required by this Section 4 may be changed accordingly upon receipt of
written notice from the City Manager or designee; provided that the Contractor shall have the
-3-
right to appeal a determination of increased coverage by the City Manager to the City Council of
City within ten (10) days of receipt of notice from the City Manager.
5.0 TERM
5.1 Time of Essence. Time is of the essence in the performance of this
Agreement.
5.2 Schedule of Performance. Contractor shall commence the services
pursuant to this Agreement upon receipt of a written notice to proceed and shall perform all
services within the time period(s) established in the "Schedule of Performance" attached hereto
as Exhibit "D", if any, and incorporated herein by this reference. When requested by the
Contractor, extensions to the time period(s) specified in the Schedule of Performance may be
approved in writing by the Contract Officer but not exceeding One Hundred Twenty (120) days
cumulatively.
5.3 Force Maieure. The time period(s) specified in the Schedule of
Performance for performance of the services rendered pursuant to this Agreement shall be
extended because of any delays due to unforeseeable causes beyond the control and without
the fault or negligence of the Contractor, including, but not restricted to, acts of God or of the
public enemy, unusually severe weather, fires, earthquakes, floods, epidemics, quarantine
restrictions, riots, strikes, freight embargoes, wars, litigation, and/or acts of any governmental
agency, including the City, if the Contractor shall within ten (10) days of the commencement of
such delay notify the Contract Officer in writing of the causes of the delay. The Contract Officer
shall ascertain the facts and the extent of delay, and extend the time for performing the services
for the period of the enforced delay when and if in the judgment of the Contract Officer such
delay is justified. The Contract Officer's determination shall be final and conclusive upon the
parties to this Agreement. In no event shall Contractor be entitled to recover damages against
the City for any delay in the performance of this Agreement, however caused, Contractor's sole
remedy being extension of the Agreement pursuant to this Section.
5.4 Term. Unless earlier terminated in accordance with Section 6.7 of this
Agreement, this Agreement shall continue in full force and effect until completion of the services
but not exceeding One Hundred Twenty (120) days from the date hereof, except as otherwise
provided in the Schedule of Performance (Exhibit"D").
6.0 ENFORCEMENT OF AGREEMENT
6.1 California Law. This Agreement shall be construed and interpreted both
as to validity and to performance of the parties in accordance with the laws of the State of
California. Legal actions concerning any dispute, claim or matter arising out of or in relation to
this Agreement shall be instituted in the Superior Court of the County of Riverside, State of
California, or any other appropriate court in such county. Contractor covenants and agrees to
submit to the personal jurisdiction of such court in the event of such action.
6.2 Disputes. In the event of any dispute arising under this Agreement, the
injured party shall notify the injuring party, in writing, of its contentions by submitting a claim
therefor. The injured party shall continue performing its obligations hereunder so long as the
injuring party commences to cure such default within ten (10) days of service of such notice and
completes the cure of such default within forty-five (45) days after service of the notice, or such
longer period as may be permitted by the injured party; provided that if the default is an
immediate danger to the health, safety and general welfare, such immediate action may be
necessary. Compliance with the provisions of this Section shall be a condition precedent to
-4-
termination of this Agreement for cause and to any legal action, and such compliance shall not
be a waiver of any party's right to take legal action in the event that the dispute is not cured,
provided that nothing herein shall limit City's or the Contractor's right to terminate this
Agreement without cause pursuant to Section 6.7.
6.3 Retention of Funds. Contractor hereby authorizes City to deduct from
any amount payable to Contractor (whether or not arising out of this Agreement) (i) any
amounts the payment of which may be in dispute hereunder or which are necessary to
compensate City for any losses, costs, liabilities, or damages suffered by City, and (ii) all
amounts for which City may be liable to third parties, by reason of Contractor's acts or
omissions in performing or failing to perform Contractor's obligation under this Agreement. In
the event that any claim is made by a third party, the amount or validity of which is disputed by
Contractor, or any indebtedness shall exist which shall appear to be the basis for a claim of lien,
City may withhold from any payment due, without liability for interest because of such
withholding, an amount sufficient to cover such claim. The failure of City to exercise such right
to deduct or to withhold shall not, however, affect the obligations of the Contractor to insure,
indemnify, and protect City as elsewhere provided herein.
6.4 Waiver. No delay or omission in the exercise of any right or remedy by a
non-defaulting party on any default shall impair such right or remedy or be construed as a
waiver. A party's consent to or approval of any act by the other party requiring the party's
consent or approval shall not be deemed to waive or render unnecessary the other party's
consent to or approval of any subsequent act. Any waiver by either party of any default must be
in writing and shall not be a waiver of any other default concerning the same or any other
provision of this Agreement.
6.5 Rights and Remedies are Cumulative. Except with respect to rights and
remedies expressly declared to be exclusive in this Agreement, the rights and remedies of the
parties are cumulative and the exercise by either party of one or more of such rights or
remedies shall not preclude the exercise by it, at the same or different times, of any other rights
or remedies for the same default or any other default by the other party.
6.6 Legal Action. In addition to any other rights or remedies, either party may
take legal action, in law or in equity, to cure, correct or remedy any default, to recover damages
for any default, to compel specific performance of this Agreement, to obtain declaratory or
injunctive relief, or to obtain any other remedy consistent with the purposes of this Agreement.
6.7 Termination Prior to Expiration Of Term. This Section shall govern any
termination of this Agreement except as specifically provided in the following Section for
termination for cause. The City reserves the right to terminate this Agreement at any time, with
or without cause, upon thirty (30) days written notice to Contractor, except that where
termination is due to the fault of the Contractor, the period of notice may be such shorter time as
may be determined by the Contract Officer. In addition, the Contractor reserves the right to
terminate this Agreement at any time, with or without cause, upon sixty (60) days written notice
to City, except that where termination is due to the fault of the City, the period of notice may be
such shorter time as the Contractor may determine. Upon receipt of any notice of termination,
Contractor shall immediately cease all services hereunder except as may be specifically
approved by the Contract Officer. Except where the Contractor has initiated termination, the
Contractor shall be entitled to compensation for all services rendered prior to the effective date
of the notice of termination and for any services authorized by the Contract Officer thereafter in
accordance with the Schedule of Compensation or as may be approved by the Contract Officer,
except as provided in Section 6.3. In the event the Contractor has initiated termination, the
Contractor shall be entitled to compensation only for the reasonable value of the work product
-5-
actually produced hereunder. In the event of termination without cause pursuant to this Section,
the terminating party need not provide the non-terminating party with the opportunity to cure
pursuant to Section 6.2.
6.8 Termination for Default of Contractor. If termination is due to the failure of
the Contractor to fulfill its obligations under this Agreement, City may, after compliance with the
provisions of Section 6.2, take over the work and prosecute the same to completion by contract
or otherwise, and the Contractor shall be liable to the extent that the total cost for completion of
the services required hereunder exceeds the compensation herein stipulated (provided that the
City shall use reasonable efforts to mitigate such damages), and City may withhold any
payments to the Contractor for the purpose of set-off or partial payment of the amounts owed
the City as previously stated.
6.9 Attorneys' Fees. If either party to this Agreement is required to initiate or
defend or made a party to any action or proceeding in any way connected with this Agreement,
the prevailing party in such action or proceeding, in addition to any other relief which may be
granted, whether legal or equitable, shall be entitled to reasonable attorney's fees. Attorney's
fees shall include attorney's fees on any appeal, and in addition a party entitled to attorney's
fees shall be entitled to all other reasonable costs for investigating such action, taking
depositions and discovery and all other necessary costs the court allows which are incurred in
such litigation. All such fees shall be deemed to have accrued on commencement of such
action and shall be enforceable whether or not such action is prosecuted to judgment.
7.0 CITY OFFICERS AND EMPLOYEES: NON-DISCRIMINATION
7.1 Non-liability of City Officers and Employees. No officer or employee of
the City shall be personally liable to the Contractor, or any successor in interest, in the event of
any default or breach by the City or for any amount which may become due to the Contractor or
to its successor, or for breach of any obligation of the terms of this Agreement.
7.2 Conflict of Interest. No officer or employee of the City shall have any
financial interest, direct or indirect, in this Agreement nor shall any such officer or employee
participate in any decision relating to the Agreement which effects his financial interest or the
financial interest of any corporation, partnership or association in which he is, directly or
indirectly, interested, in violation of any State statute or regulation. The Contractor warrants that
it has not paid or given and will not pay or give any third party any money or other consideration
for obtaining this Agreement.
7.3 Covenant Against Discrimination. Contractor covenants that, by and for
itself, its heirs, executors, assigns, and all persons claiming under or through them, that there
shall be no discrimination against or segregation of, any person or group of persons on account
of race, color, creed, religion, sex, marital status, national origin, or ancestry in the performance
of this Agreement. Contractor shall take affirmative action to insure that applicants are
employed and that employees are treated during employment without regard to their race, color,
creed, religion, sex, marital status, national origin, or ancestry.
-s-
8.0 MISCELLANEOUS PROVISIONS
8.1 Notice. Any notice, demand, request, document, consent, approval, or
communication either party desires or is required to give to the other party or any other person
shall be in writing and either served personally or sent by prepaid, first-class mail, in the case of
the City, to the City Manager and to the attention of the Contract Officer, CITY OF PALM
SPRINGS, P.O. Box 2743, Palm Springs, California 92263. In the case of the Contractor, it
should be addressed to the person at the address designated on the execution page of this
Agreement. Either party may change its address by notifying the other party of the change of
address in writing. Notice shall be deemed communicated at the time personally delivered or in
seventy-two (72) hours from the time of mailing if mailed as provided in this Section.
8.2 Interpretation. The terms of this Agreement shall be construed in
accordance with the meaning of the language used and shall not be construed for or against
either party by reason of the authorship of this Agreement or any other rule of construction
which might otherwise apply.
8.3 Integration; Amendment. It is understood that there are no oral
agreements between the parties hereto affecting this Agreement and this Agreement
supersedes and cancels any and all previous negotiations, arrangements, agreements and
understandings, if any, between the parties, and none shall be used to interpret this Agreement.
This Agreement may be amended at any time by the mutual consent of the parties by an
instrument in writing.
8.4 Severability. In the event that any one or more of the phrases,
sentences, clauses, paragraphs, or sections contained in this Agreement shall be declared
invalid or unenforceable by a valid judgment or decree of a court of competent jurisdiction, such
invalidity or unenforceability shall not affect any of the remaining phrases, sentences, clauses,
paragraphs, or sections of this Agreement which are hereby declared as severable and shall be
interpreted to carry out the intent of the parties hereunder unless the invalid provision is so
material that its invalidity deprives either party of the basic benefit of their bargain or renders this
Agreement meaningless.
8.5 Corporate Authority. The persons executing this Agreement on behalf of
the parties hereto warrant that (i) such party is duly organized and existing, (ii) they are duly
authorized to execute and deliver this Agreement on behalf of said party, (iii) by so executing
this Agreement, such party is formally bound to the provisions of this Agreement, and (iv) the
entering into this Agreement does not violate any provision of any other Agreement to which
said party is bound.
[SIGNATURE BLOCK ON NEXT PAGE]
-7-
IN WITNESS WHEREOF, the parties have executed and entered into this Agreement as of the
date first written above
CITY OF PALM SPRINGS
f ATTEST: a municipal corporation
City Clerk (?/2_0)03 City Manager'
CONTRACTOR: Check one:_Individual_Partnership v Corporation
By: By:
�� ,Signaturet(.nottraririzedl)) Signature (notarized)
Name: I '-k V_ (�1 t�-�I" +--� Name:
Title: �NZG� 1Dr4-#- / Cc—_,c) Title:
(This Agreement must be signed in the above space by This Agreement must be signed in the above space by
one of the following:Chairman of the Board,President one of the following:Secretary,Chief Financial Officer or
or any Vice President) any Assistant Treasurer)
State of State of =
County of sss County of =ss
On before me, On before
me,
person ly appeared appeared
t/ eIIo . J�eyha P-"-I Y- personally personally
kBQi" t^ ^�6 (or proved to me on the basis of,satisfactory ]mown to me (or proved to me on the basis of satisfactory
evidence)to be the person whose name('is/,afe subscribed evidence)to be the person(s)whose name(s)is/are subscribed
to the within instrument and acknowledged to me that to the within instrument and acknowledged to me that
he/00 executed the same in kris/Wt it authorized he/she/they executed the same in his/her/their authorized
capacr ' s), and that by his/ signature on the capacity(ies), and that by his/her/their signature(s) on the
rostrum t the perso s),or the entity upon behalf of which the instrument the person(s),or the entity upon behalf of which the
person )acted,exe uted the instrument. person(s)acted,executed the instrument.
SS my and and official seal. WITNESS my band and official seal.
No Notary
Signature: Signature:
Notary Seal: Notary Seal:
W
RRIE A.COOKMM11329414Y PUBLIC-0ALIFOflNIAI
VERSIDE COUNY.Expires November 1a,2005
/l/ Ll L'C
EXHIBIT"A"
-8-
SCOPE OF WORK
The goal of this project is to carry out an expeditious and cost effective assessment of the
Tiburon Computer Assisted Public Safety System, (CAPS) and whether is it meeting the
requirements of the City. ThirdWave will act as an independent third-party entity in the
assessment of the existing system performance. ThirdWave will provide a summary of findings,
with corresponding recommendations, for the consideration of the City Manager and Police
Department.
TASK 1.0 Review Existing Documents
The ThirdWave project team will review existing documentation on the Tiburon CAPS System
implementation, including but not limited to, the Scope of Services document, functional
specifications, etc.
TASK 2.0 Develop Evaluation Punch List
Using documents provided by the City, this task will entail developing a structured punch list of
modules and related functionality for an onsite review of the CAPS System. This will be used as
a checklist in the onsite application reviews in determining whether the CAPS system is
functioning per the Scope of Services document.
Deliverable 1: Evaluation Punch List
TASK 3.0 Onsite CAPS Application Review and Evaluation
This task will entail carrying out a one-day onsite review of the CAPS System, and appropriate
modules which the City believes are not functioning per the Scope of Services document. This
task will require that the City make the appropriate "super user(s)" available for system
demonstration and testing. It is strongly encouraged that Tiburon also make one technical
person available for the one-day testing. (This Scope of Work presumes that one day of testing
will be sufficient, however if an additional day is required, the cost of$2,600 will be added to the
cost of the Work.) The punch list will be provided to the City and the Vendor in advance of the
testing.
TASK 4.0 Document Findings of CAPS Application Review
This task will entail compiling the evaluation results to produce a summary of findings from the
onsite CAPS application review.
TASK 5.0 Recommendations Letter
This task will entail providing a recommendations letter to the City, addressing several issues
and /or possible actions the City might pursue based on the assessment. Possible
recommendations might include:
• Settlement Agreement
• System Replacement
Deliverable 2: Summary of Findings and Recommendation Letter
-9-
EXHIBIT"B"
SPECIAL REQUIREMENTS
The requirements of Section 4.3 for a performance bond are hereby waived.
-10-
EXHIBIT "C"
SCHEDULE OF COMPENSATION
Total compensation for all services and expenses shall not exceed $8,566.00. A breakdown of
the estimated cost by task is as follows:
Task 1.0 $716.00
Task 2.0 $1,020.00
Task 3.0 $2,600.00
Task 4.0 $3,080.00
Task 5.0 $1,150.00
TOTAL $8,566.00
Method of Payment: CITY will compensate CONTRACTOR, for consulting, analytical and
evaluation services, as well as all out-of-pocket expenses including but not limited to shipping,
postage, long distance telephone charges, incurred on CITY's behalf, upon the successful
completion of the entire project. Payment shall be made upon submission of a certified invoice
for allowable cost incurred in the performance of this agreement.
Additional Services: In the event the City requires services in addition to those set forth in this
Agreement, Contractor shall be compensated, pursuant to invoices delivered to City in
accordance with Section 2.2 of this Agreement, at a flat rate to be negotiated by, and subject to
the approval of, the parties, plus expenses, as set forth in this Exhibit "C".
-11-
EXHIBIT"D"
SCHEDULE OF PERFORMANCE
Time is of the essence of this agreement. CONTRACTOR shall perform all services hereunder
as expeditiously as is consistent with professional skill and care, as well as the orderly progress
of the Project work so as not to be the cause, in whole or in part, of delays in the completion of
the Project or in the achievement of any Project milestones, as provided herein. Specifically,
CONTRACTOR shall perform its Services so as to allow for the full and adequate completion of
the Project within One Hundred and Twenty (120) days of receipt of a notice to proceed. If at
any time it appears that the project cannot be completed by the date specified, CONTRACTOR
shall notify CITY of that fact and provide an estimate of the time when the project will be
completed. If CONTRACTOR has been the sole source of delay, and if completion of the
project would be expedited by use of other or additional consulting services, CITY may use the
retained amounts for the purpose and shall be relieved of paying such retention to
CONTRACTOR. If the CONTRACTOR's work is not satisfactory, CITY has the right to take
appropriate action, including but not limited to: (1) meeting with the CONTRACTOR to review
the quality of the work and resolve matters of concern; (2) requiring the CONTRACTOR to
perform the work at no additional fee until it is satisfactory; (3) suspending the delivery of further
work to the CONTRACTOR for an indefinite time; (4)withholding payment; or (5) terminating the
Agreement as set forth in Section 6.7.
Project Schedule
Task 3.0 Onsite CAPS Application Review August 20, 2003
Task 4.0 Document Findings of Application Review August 22, 2003
Task 5.0 Produce and Submit Summary Report of Findings
And Recommendations to City August 29, 2003
-12-