Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
5/4/2005 - STAFF REPORTS (8)
CITY COUNCIL May 4, 2005 CONSENT CALENDAR Subject: FINAL MAP 32233-1 From: David H. Ready, City Manager Initiated by: Public Works and Engineering Department SUMMARY: MSA Consulting, Inc., representing Palm Springs Classic, LLC, a Delaware Limited Liability Company, has prepared a Final Map for subdivision of property into 43 single family home lots, 8 multi-family (high density) residential lots, and various open space and recreational lots located along the east side of Gene Autry Trail, south of Vista Chino, in Sections 7 and 18, Township 4 South, Range 5 East. Approval of the final map will allow the map to be recorded, and building permits to be issued for future construction of the 43 single family home residential lots and 8 multi-family (high density) residential lots (subject to future architectural review and approval by the City) proposed within this development. This is merely an administerial action, as required by the Municipal Code and the Subdivision Map Act. This final map represents the first phase of the Palm Springs Classic development, now know as "Escena Palm Springs". RECOMMENDATION: Adopt Resolution No. "A RESOLUTION OF THE CITY COUNCIL OF THE CITY OF PALM SPRINGS, CALIFORNIA, APPROVING FINAL MAP 32233-1 FOR PROPERTY LOCATED ALONG THE EAST SIDE OF GENE AUTRY TRAIL, SOUTH OF VISTA CHINO, IN SECTIONS 7 AND 18, TOWNSHIP 4 SOUTH, RANGE 5 EAST, AND APPROVING A SUBDIVISION IMPROVEMENT AGREEMENT WITH PALM SPRINGS CLASSIC, LLC, A DELAWARE LIMITED LIABILITY COMPANY." STAFF ANALYSIS: MSA Consulting, Inc., representing Palm Springs Classic, LLC, a Delaware Limited Liability Company, submitted Final Map 32233-1, requesting that the property located along the east side of Gene Autry Trail, south of Vista Chino, in Sections 7 and 18, Township 4 South, Range 5 East, be subdivided into 43 single family home lots, 8 multi-family (high density) residential lots, and various open space and recreational lots on a 375.3 gross acre site. At its meeting of October 13, 2004, the Planning Commission recommended approval of Tentative Tract Map 32233, which was subsequently approved by the City Council, subject to conditions, on November 17, 2004. It has been determined that required conditions have been satisfied, that Final Map 32233-1 is in substantial conformance with the approved Tentative Tract Map, and that Final Map 32233-1 is ready for City Council approval. Item No. 2 . G . Submitted: David J. Barakian Director of Public Works/City Engineer Approved: David H. Ready City Manager ATTACHMENTS: 1. Map 2. Subdivision Agreement OCr02 OWNER'S STATEMENT IN THE CITY OF PALM SPRINGS, COUNTY OF RIVERSIDE, STATE OF CALIFORNIA SHEET 1 OF 9 SHEETS I'SSU HEREBY SPATE HE SEE.TE RITE OARERS OF THE LWo PERSONS WHOSE WITHIN FITS TRACT MAP NO. 32233- 1 RECORDER'S STATEMENT NECDmARY O OWNPOS HEREON.THAT SEE RA THE ONLYMAXWE WxWE TO O ME Is AND RECORDING IN PISS A LITTER TIRE TO SVO SHOWN gT WE COWEM TORE UNFI FILED ME ,vuo pECOpowc of THIS sapoGlslory u SETAE wmILN THE olmxc»VE BORDER HENS BEING A SUBDIVISION OF PARCELS 3 AND 4 OF PARCEL MAP NO. 2791Z AS SHOWN AT W BOOK OF WE HERESY BEIGATE TO PUSHED USE LORD A"THROUGH'E'.INGLESIV<.MR MEET. BY MAP ON FILE IN BOOK 183, PAGES 35 THROUGH 37, INCLUSIVE, OF PARCEL HATS AT PACES AT THE REQUEST OF PUBLIC LU M AND SENTR PURPOSES,AS SHOWN WITHIN IBIS MAP AS A DENUDER THE CITY CLERK OF THE CITY OF PALM SPRINGS OF DElcAUSH OF LOTS W,, "B"AND"C"(ONES AWRY REAL),AND LOT'D-MSS MAPS, RECORDS OF RIVERSIDE COUNTY, TOGETHER WITH PORTIONS OF SECTION ]AND CHINO).THE OWNERS OF HATE 14,46.42,GO,50,51,'S'. FEE AND"M'.M RETAIN THE NORTH HALF OF SECTION IS, TOWNSHIP 4 SOUTH, RANGE 5 EAST, S.B.M. NO WITHIN MIS W.ABUTTING THIS HIGHWAY AGO DURING SUCH TIME WILL NAVE NO RIGHTS nny T'- OF ACCESS DEBBPT THE cNNEAL EASEMENT OF TRAVEL ANY CHACE BF SLUGGERS �V MS`A CONSULTING, LV C. DECEMBER - 200E FEE OF WCCES FJORDS. FEES LEE w THE VACATION THEREOF sHAL 1Ep1AwAlE THIS coxomory V CARRY W WAREA COUNTY ASSE4oR-CLERK-RECORDER OF AccI RIGH15,'Aln ro THE PARR VACATED WE HEREBY DEDICATE TO PUBLIC USE FOR PUBHC MUCY AND READY PURPOSES, ENGINEER'S STATEMENT BY' oEPurc THOSE EASEMENTS SHOWN AS'10 RUE'.ALONG AND ADJACENT TO ALL PRIVATE SREEm,AS SHOWN wxnCN THIS MAP SEBEMSION GUARANIS£BY:NORTH AAIERILw MIT COMPANY TITS MAP VEY N CONFOR BY ME IT LIMBER MY DIRECT SUPERVISION SU AND IS O CASE UPON A WE HEREBY DEDICATE NIGHT PUBLIC I USE EASEMENTS FOR PUBLIC EE AN AND SEWER PURPOSES. FELL SURVEY IN CM LEE ANCEREQU WITH ME TRIBES HOSREQUIREMENTS OF THE SUBDINC.I I.NO ACTEMB AND MGEMd WIDE THE RICNF OF INGRESS AND EGR65 FOR$ERMCE AND EMptGENCf VdICL£5 LOCAL ORDINANCE AT THE REUFSF OF LFNNRR HOMES OF CPLIFORNU,INC.IN NCVEMBER OF 2004_ AND PERSONNEL OWED ETS'F THROUGH SO',INCWSIVE.AS SHOWN WITHIN THIS RAP I HEREBY SPATE THAN ALL MONUMENTS ARE OF THE LHARASTER AND OCCUPY THE POSITIONS TAX COLLECTOR'S CERTIFICATE INDICATED,OR WILL BE IN ACCORDANCE WITH THE TERMS OF THE MONUMENT AGREEMENT FOR WE HERESY pE➢ICAIE TO PUBLIC USE FOR EMERGENCY INGRESS AND EGRESS PURPOSES. ME MAP,AND MET SAD MONUMENTS ARE SUFFICIENT TO ENABLE THE SURVEY TO BE RETRACE A 20 FOOT EASEMENT ACROSS A PORTION OF LOT'AC.AS SHOWN WITHIN THIS MAP I HUMPY STARE THAT THIS MAP SUBSTANTIALLY CONFORMS TO THE APPROVED OR CONORTCNALLY I HEREBY CERTIFY THAT ACCORDING TO THE RECORDS OF MA OFFICE,AS OF MITI LATE. APPROVE SFNTAN MAP,IF ANY THERE ARE NO LIENS AGANST THE PROPERTY SHOWN ON THE WITHIN MAP ER UNPAID WE HEREBY OEICATE TO PUBLIC USE FOR PUBLIC UTILITY AND SEWER PURPOSES. ( SFA1E,COUNTS,MUNICIFOR-OR LOCAL LAWS OR SPECIAL ASSESSMENTS COLLECTED As EASEMENTS OVER HIM'RE THROUGH Y.INCLV51�.AS SHOWN WITHIN THIS MAP. DATE D> QpOFE90/pM, SAKES EXCEPT TAXES ON PECIaI ASSESSAIENIB COLLECTED AS Ta M.NOW A LIEN BUT c� Y NOT YET PAYMENE,WHICH ARE FSUMAR➢TO BE RE HEREBY DEDICATE TO PVBMC USE.FOR SIDEWALK AND 5%Fr AN PURPOSES, /e�/n�����'�/� m Y 0 WE SHE. OVER PORTIONS OF LOTS 44,trfi,47,49,50,51,'S"AND LOT"M", rU*40 EPl c c i i PATE AS SHOWN WITHIN THIS Mh ROBERr 5 M R.CE 26a01 s C26A01 m CAP 3/31/05 E`T S-E1-Uf PAUL McOCNNEIL.COUNTY TAX COLLECTOR WE HEREBY pEIP1N LOTS'F"THROUGH'0",INCWSIVE,INDICATED p5"TITIVATE SIRE£l5" MR ENGINE USE FOR THE ROLL FIRMLY OF OURSELVET,OUR SUCCESSORS ASSIGNEES 0/y\W' A� AND LOT OWNERS WITHIN THIS MAP. Wl9lF 6Y OF LAIWFO DEPUTY WE THEREBY REMN FOR STORM OWN PURPOSES AN'vSwOM SEER THOSE CITY ENGINEER'S STATEMENT EASE d EASEMENTS SHOWN AS PUS',FOR THE SALT BEM OF OURSELVES,OOR SUCCESSORS.ASSIGNEES AND LOT OWNERS WITHIN THIS MAP I HEREBY SATE THAT I HAVE EAMONE➢THE WITHIN MAP OF TRACT MAP NO 322]}1, WE MURRAY RETAIN FOR OPEN STAGE LANDSCAPE AND STORM DEAN PURPOSES, CONSISTING OF 9 GREETS,RAT THE SUBDIVISION SHOWN HEREON IS SUBSTANTIALLY TILE TAX BOND CERTIFICATE EM,"P'THROUGH EC'.INCLUSIVE,ALSO TOM"AL)'AND"AB'.FOR THE SOLE DETROIT SAME AS IT APPEARED ON ME TECTOME GAP OR ANY APPROVED AL I TURNS THEREF; OF OURSELVES.OUR SUCCESSORS,ASSIGNEES AND LOT OWNERS NIACIN IBIS MAP THAT ALL PROVISIONS OF THE STATE SVOBNISION MAP ACT AND ANY MOST ORDINANCES APPLICABLE AT THE RAPE OF APPROVAL OF THE TENTATIVE IMP HAVE BEEN COMPMED WITH. I HEREBY GMTFY THAT A BOND IN ME SUM OF HAS BEEN EXECUTED WE HEREBY RETAIN LO15'AC'THROUGH'AE'.FOR THE SOLE THEM OF OURSELVES, AND THAT 1AM PATTERN MAL SAID MAP IS rEAMICALLY CORRECT AND FILED ARM THE BOARD OF SUPERSTRONG OF THE COUNTS OF EMPEROR,CALIFORNIA. OUR SUCCESSORS,ASSIGNEES AND LOT OWNERS WITHIN THIS MAP Aw' CONDmONED UPON THE PAYMENT OF ALL TAXES,STATE.DOUBLY.MUNICIPAL OR LOCAL DINED R � .y AND ALL SPECAL ASSESSMENTS COLLECTED AS TOR , HICH AT ME ENE OF TEND OF WE HEREBY MEET FOR INGRESS AND EGRESS PURPOSES.AN CREMENT EUROPE A E'6'b4ry THIS MAP WITH LEE COUNTY RECORDER ARE A LIEN AGAINST SAID PROPERTY BUT NOT YET PORTION OF LET'P",FOR ME SOLE BENEFIT OF LGT EAR',THEIR SUCCESSORS AND gi'4oa`V k FAYACLE CUP SAO BOND HAS BEEN DULY APPMATS RE GAS BOARD OF SUPERMSERG ALTWE OGRES'IO VEIN FENT�CNUTHCA ITN OFCALM SARIxcS,A MUHSAAE ORS,RATIax OAND I AGRUCW RCE BESS, R k DATED PALM SPRINGS CLASSIC, LLC, x CITY ENGINEER IXF.3/31/07 Hw C-ze93T CASH rax BOND A OEUWARE LIMRE LIA91Utt COMPANY CCANCYLERK OF THE CAUL AIc00NNELL CIVlU- CLERK OF SITE BOARD OF SUPERVISORS COUNTY TA%LOL1£CTOR BY: LENNAR HOMES OF CALIFORNIA, INC., SAE.LF A cAUFORNA CORPORATION.MANAGING MEMBER CITY CLERK'S STATEMENT RY SC I DEPUTY DEPUTY BY Y C,JANE5 THOMPSON.CITY CLERK AND IX-OFECIO ASSESSOR OF NNE CITY COUNCIL OF THE CITY OF Pwn SPRINGS.STATE OF CALIFORNIA HdEln SPATE THAT SAD CITY COONGL AT IFS ABANDONMENT NOTE NAME TLN M E ANS BE V1lE SUSSoENt• REGULAR PEEING HEED oN THE DAY OF 20 ONLY APPROVE THE WHEN MAP OF TRAGE MAP NO 322E ACCEPT -1,AND DID ACCT ME OFFER OF DELEGATION OF LOTS"A"THROUGH"E",OFFERED FOR STREET AND PUBLIC IMMY PURPOSES; POR M E SUA TO SECTION 66434(C)OF THE SUESTARN MAF ACT,THE RUNG OF THIN LISTBENEFICIARY'$ BENEFICIARY'S STATEMENT THE OFFER OF ACCESS INCHES TO BOND AMY TRPIL AND VISTA CHINO,THE SCREENS SHOWN SHALL CORRECTS AGANDOxrEM,WURN THE BOUNDARY OF THIS NUA OF TIE FJSEMENT As'10'RUE'.OFFERS FOR PUBLIC M LY AND SEWED PURPOSES,THE EASEMENTS OVER ARMED TO RITE CITYOF PALM SPRINGS FOR 11,,,IONIC UTILITY ANO INCIDENTAL REEGENIAL FUNDING CORPORATION,A DESERWRE CORPORATION,BdEF1CARY PER DEED HERE'F"THROUGH'O".INCLUSIVE,DEEMED FOR PERUC MUTT AND SEWER PUTOC ES. PURPOSES PER UNIT NO 01915,RISC 1/24/79,AND PER INAL NO 01916.REL 4/24/79, OF MUST RECORDED EMERY 29,200� AS INSTRUMENT NO 2004-0662642E OF TOGETHER WITH THE RIGHT OF INGRESS AND EGRESS FOR GERMANE AND EIERGENCY VEHICLES ALL OF OFFICIAL RECORD THE FASRJLM BEING ABANDONED 15 NOT SHOWN ON THIS SEE OFFICIAL RECORDS OF RIVERSIDE COUNTY,CAIERNIA AND PERSONNEL,THE 20 FOOL EMERGENCY INGRESS AND EGRESS EASEMENT ACROSS A PONT OF US 'AGE.RITE BEADAId15 OVER LOTS"P"THROUGH-Y INCLUSIVE.OFFERED ,p''//��,, (� /n1�.�- it __ �j PUBLIC ITT AND SAWED PURPOSES,THE vsE1EMs OVER OVER PORnous OF SOILS REPORT BY l 1(iT�ARLFS'H"� BY: .7` rJ.LLC LOTS TH.AD,AT,49,50,31,"S"AND LOT"AA".OFFERED FOR PEERESS AND PEDEATION 1w��� � PURPOSES. nRE FDA AM Al DEp ICgTEVp1 qH0 SHOWHMWIl11N TIES AfAP w PURSUANT TO SECTOR 66490 OF ME SUBDIVISION MAP ACT.A PRFLARMAY SOILS rvuAE L.KMan OlA4N TITIE DnecTnRA NMAE L �e I' 1TLE J.L2 A x x E SUBDIVISION OM coxvEvnNc_ REPORT PROJECT NE 94-OS-]]9.THE NO OM39-03 04-00-703,WAS PREPARE WE HERESY ABANDON PURSUANT i0 SECTION 664]4(G)OF TIE SUBDINSION AIAP ACT. BY EATER SYSTEMS SOUTHWEST. DATED MAY 27, 1994,AND AMENDED AMOUNT 27.BOOS. ME HE'EVERETT FOR STREET AND PUBLIC M MY PURPOSES PER INST.NO.01915 AND Is ON FILE WITH THE CITYOF PALM SPRINGS,ENGINEERING OEPARNEM BENEFICIARY'S STATEMENT IBMa/zaps,AND PER Ixsr No 81916,DEC 4/24/19,AL of OR.LYING1v.IN THE BOUNDARY OF THIS MAP,AND NOT SHOWN HEREON, PS INVESTMENT COMPANY,LC,A MICHIGAN LIMITED LIABILITY COMPANY.BENEFICIARY PER SIGNATURE OMISSIONS IT PER OF MUST RECORDED FEBRUARY G.2004,AS INSYRVMERM NO 200h-0009A22,OF THE TENTATIVE HAP FOR GRID MADE AIM WAS APPROVED BY THE CITY COUNCIL AT IRS CRUCIAL RECORDS OF RIVERSIDE COUNTY,CALIFORN4 DISCOLOR PEEING HELD ON THE ISM PAY OF NOVEMBER.2004 SEE SHEET 2 BY BY DArEI RY. NOTARY'S ACKNOWLEDGMENT NAME FQE "'� CITY CLERK AND EG-OFFIEO ASSESSOR OF TIE D��R➢�nIILE P'�ILN�{[�n1AlAE: TT£ CRY COUNCIL OF THE Cltt OF PALM SPRINGS. sTi SITES 2 J.N. 1609 VAR ANIC. IN THE CITY OF PALM SPRINGS, COUNTY OF RIVERSIDE, STATE OF CALIFORNIA SHEET 2 OF 9 SHEETS TRACT MAP NO. 32233- 1 TALxEvu1 �HT, j BEING A SUBDIVISION OF PARCELS 3 AND 4 OF PARCEL MAP NO. 27912, AS SHOWN BY MAP ON FILE IN BOOK 183, PAGES 35 THROUGH 37, INCLUSIVE. OF PARCEL /Y MAPS, RECORDS OF RIVER5IDE COUNTY, TOGETHER WITH PORTIONS OF SECTION ]AND MONUMENT NOTES /._ ' THE NORTH HALF OF SECTION 18, TOWNSHIP 4 SOUTH, RANGE 5 EAST, S.B.M. N.I"I OLDER A = N CE 24176.DO 0-' MON WELL.PER PWF 0 0 N 103/35-37 k I 95/43-46,ACCEPTED/STIE OW CDR.SEC,] I5 MSA CONSULTING, INC. DECEMBER - 2004 P T SyyYAN ILAE O N C.BRASS RISC STAMPED-A F C 117,BC.44",IN WON.WELL.PER Q SKIM DIN SIGNATURE OMISSIONS IS 67/65-B6 A,MAC IIIII n,-acGAMM As THE CUT ILO OF MIFY TRA IL k VISTA CHINO ROM(NORM ONE OF SEC J) NOTARY'S ACKNOWLEDGMENT �."�� VICINITY MAP PURSUANT W ARECON 66436 OF ME SUBDMSION CUP AM,THE SCRATCHED)OF THE FOLLOWING AMNESIA) Q ED NG W/TAG-AV LD SUN',ON D31 PER R S s]/as-66 e STATE OF CALIFORNIA ) 1+� HIP TO SAME OF EASEMENTS AM/OR OTHER IMEREETS HAVE BEEN OMITIEO,WE MAN INIERESIS C4NNOT RIPEN INTO FEE 111 B 1031 ACCORDED S ME N 1/4 CAR SEC ] SS CAMANDA ELECTRIC POWER COMPANY AND CALIFORNIA WATER AND TELEPHONE COMPANY, 4Q FO 1 1/2'TO \'I/SPIKE 6 TAG RGE 25658.ON 09' IN IRON WF1L PER COUNTY OF 4,;CGG5 1 w.�ov Rand HOLDERS OF RJ EASEMENT FOR PUBLIC IIIIpnES,PER INST NO 75553.P.EL 0/26/6D,OUR R S 67/85-Bfi&P.LI B 103/35-3] ACCEPTED S THE WE CDR SEC ]R Du ORDAYpign P 4I SIN AND BEFORE ER Ly A}{L Yn`♦7053 A NOTARY PUBLIC IN NJO FOR AAp SLATE.PERSONALLY ROJ Tx 6iI PALIA SPRINGS PpNORAIAA,HOLDER OF ANON-EXCLUSIVE GS0.fEM FOR ROM,PUBLIC OS F➢ 1"I P V!/iRG ITS 4145.FLUSH.PER P M1I B 163/}5- UTMES AND INCIDENTAL PURPOSES,PER USE NO 921M RED 10/26/60 0 R k RS 96/43-AN ACCEPTED AS ME E 1/4 CAA SEC ]3] PERSONALLY KNOWN TO OF (G.-:P:}\CO F/ '.IC U P.RI EDT Ci :A(THIN OE(_MEAT N TO BE THE PERSONAS METH NAME(G)IS/NE SUBSCRIBED ME TO THE WITHIN IN - AUT AND COACHEAGREES VALLEY WATER DISTRICT.ES HER IN OF O EASEMENT FOR DRNNAGE INGRESS. © N-1'I SWFTAGME E 1 46,FLUSH,ECi PIAB I8}/}5-}]. ACKNDWL£DGEO TB M 1HAT HE/SXEfTEY EXECUTED (Q SAME IN HIERWEN M AUtHORIZE➢ EGR69 AND INCIDENTAL PURPOSES,PER INS! NO 106771. REC 12/19/6D,BR. ACCEPTED S ME E t/l6 CDR.OF SEG J CPPACIIYENTR AND NWST A XISF WHICH fIEiR SPEASSORE(S CT ME INSTRUMENT INS PEMENT ), OR ME ENTRY UPON BEHALF OF VIXICH THE PERSAN(L}pCIEO,IXECUIED THE INSTRUMENT RIVERSIDE COUNTY FLOOD CONTROL AND\'DATER PMES CONSERVATION[FL NILi,HOLDERNO-42 OF EASEMENTS 9/ FOR FLOOD QJ R 1 1/2" P,S TLC"REV CO SURV",DN.2p'IN GONE.BE PEP CONTROL,INGRESS.EGRESS AND INCIDENTAL PURPOSES PER INST.NO 1999-42J]B],REC 9/24/99.OR. AA 96/43-SB h PMB 103/35-3].ACCEPTED S ME BE LAIR AEC ] DAY COMMISSION IXPIREA ISI15I T MY PRINCIPAL PUCE AF BUSINESS D WHITEVIATER RIVER CHANNEL HELD SOWN ATRUMIEM MAT OAhU 10/17/65,RIVERSIDE COUNTY WIENERS AM1 HAND AND OFFlCIAL SGL 1 SURVEYOR MAP NO AN-N ❑8 M 2"BRSS DISC STAMPED US 2567,ON 05 IN WELL,PER IS RIVGISE qL MONTE, PMB 03 35-3]k RS 5fi 29- ME 1 / / 32,ALLEPIEO AS ME BE CDR SEC 18 14'NQAMG�A OERERT WATER AGENCY, 7Fl,R OF S/ EASEMENT W E FOR INGRESS AND EGRESS. HIPAhY IIBLIL IN FDR SAID STATE PER INST NO 1999-92]JOb.RED 9/24/99,WE. Q9 ED 2'GRACE DISC STAMPED L ] pIJ.OS'IN IRON WELT PER RE 56/29-32,ACCEPTED AS E 1/4 CDR SEC/l U:l J ( �A O�SS BIRO F,PRODUCTS, CORPORATION,HOLDER OF AN FAG 12/FOR WATER ORANAGE (PRINT NAI.1E) AND P.ELJTIDN,PER INST NO 2003-943229,REC 12/2/03,OR. ID N 2"BRJ55 DISC AigIAPEO LPS 1972,AEf IN CONE, 0 PER R 5 fiJ/85-86.ACLEFTED AS TIE S 1/4 CDR SEC ] NOTARY'S ACKNOWLEDGMENT EASEMENT NOTES STATE OF CALEDONA )SS Q k PS HE /85-85.ACCEPTED ASVME SW,CDR 6SEA 2]M yy�� 1 CENTERLINE AN AN ID CALIFORNIA FOP PMBITL MODES,ONE UNKNOWN IN FAVOR OF AS INATNU ELECTRIC75553, COVNIY4 oOFIQS rtN��$) POWER COMPANY AMID CPLO WATER NJO TELEPHONE CBAI PrWY,flEL 0/26/60.A INST NO ]5553,O.R 12 N 1"Ip W/TAG R.CE 9503,FLUSH OLD E OF POSITBN. FR aIL 64 ;LQ03 , BEFORE ME SOMIA f.vAec,14 Q p NON-EXCWSIVE EASEMENT FOR ROM,PUBLIC MLDIES AND INCIDENTAL PURPOSES,90 IN WIDTH, PEN PMB 103/35-37 A ry TART PUBLIC Elf a Silp STATE. PERSONALLY�P ENED IN FAVOR OF PALM SPRINGS PANORAMA,RED.10/26/60,AS INST NO 92186.0 R I-, My SO TO.low' /{1�m L('}uGb fQ�l {7�. 13 N 1"IP.W/TAG RLE 9503,MUSH,022 E OF POSITION, PERSONALLY KNOWN TO ME(BR.M520�IQ'M1Tbv",C• N,P,L,F ,CELLO_) �AN EASEMENT NR DRAINAGE,INCITERS, EGRESS AND INCIDENTS PURPOSES. IN FAVOR OF PER ROLE 163/35-37 TO BE THE PERSONA)WHOSE NAME(5)RI SUBSCRIBED TO ME WITHIN INETRUMEN]AND ACKNOWLEDGED TO ME MAY NSFR WAM EY IXELIREA ME SAME IN HIG,4 GCMER AUTHORIZED ME COACHELA VALLEY WATER DISTRICT.REC INNS/GO,AS INET NO 106771, DR. 14 ED 2'IF W/TAG RC E 11 GAD,FLUSH,PER P IF 183/35-37& DAPAIDYGE),AND THAT BY HAAcN/MSY SIGNANREC)ON ME INETROMEM ME PERSONAS). Q RS 87/05-06,ACCEPTED A ME CM OF SEC ] OR ME DRIER UPON BEHALF OF WHICH ME pER50NC)ACHE➢,EMOOTED ME INSTRUMENT 4 AN EASEMENT AM SDREEIE.UNDERGROUND SEWERS AND PMBUL MORES.50 IN WHOM. MY COMMIS' EXPIRES HA4 .10,E IN FAVOR OF THE GUY OF PALM SPRINGS,RED 11/27/68,A INST NO 115111,BR IS Fp 2 0RA55 DISC STAMPED AC CS.06rtr5.11'.ON OS IN IRON DELL. Fl 7 MY PRINCIPAL PLACE GF BUSINESS Q PER AM8 163/35-3],ACCEPTEO A ME C/L BC OF GENE A�TRAIL MA My C BE COM MY HANG AND OFFlCIAL A I 5 AN FIS PROM FOR pUBLL MLPEA, HIGHWAYS AND INLIDENTpL PVRP05 F5,IN �(^J(V'I 1E LO$ANGdL6S COUNTY FAVOR OF ME CITY OF PALM SPRINGS, RED 3/10/70.A INEIL NO DRIBS OR 1fi N 3/I P NECAG'R C F.C.d 0C I'.EWSH,PER R.S.96/43-N, NTARY�6.11. - 6 AN DEENCER FOR STUFF,PUBLIC MLTES ARE INCIDENTAL PURPOSES,IN FAVOR OF THE CRY OF PAW ACCEPTED AS THE ITL OF ME SW LINE OF ME RIV CD.MEM CONTROL N ELC IN VC/I NCR WAR SATE SPRINGS.REL.4/24/J9,A INET N0.01915 OR (ABANDONED ON THIS MAP SEE SHEET 1.) SAUK h THE SILT ONE OF ME SE 1/4 SEC ] SON/A E GAtc-IA J AT EASEMENT FOR STREET,PUBUC THUNDER AND INCIDFMA.PORPDSES,IN FAVOR OF THE CRY OF PAW IJ F➢. I P.,OPSA.ON 05 IN IRON WET-NO REF,ACCEPTED AS (PRIM NAME) SPRINGS,RISC 4/24/]9,A INST NO 81916 OUR ACRACONEO ON IRIS ISAM SEE AHEED I.) TIE C/L EC OF GENE AUNTY TRAIL.PER PIR B 183/35-37 NOTARY'S ACKNOWLEDGMENT AA AN FIRE"FDR STREET$HIGHWAY,UNDERGROUND SFIERA,PUBUC UTIm wSTAITSIONA ADD INCIDENTAL 1e ED RE BRASS DISC PUNCHED"C P.S 61+57Us5",DO o"IN ON WELL. SEATO OF GYSyµh R,'"HAW4 PURPOSES,IN FAVOR OF ME Litt OF PALM SPRINGS.REC 3/13/89,AS[NBC NO.76285,OR. PER PMB. IB3/3s-3],ACCEPTED AA ME C�L BC OF GENE ANM TRAIL O L9'RELY OF THEE.UNEOFSEL.J,AWNG T E V L OF GENE PUTRY TRAIL. COUNTY OF l9AK.�CuIA )EE AN EASEMENT FOR INGRESS AND EGRESS,20 IN WHOM,IN FAVOR OF DESERT 19 N 2"ERASS DISC STRIPED"CPS 63+OSSJ",ON OS'IN AND WELL WATER AGENCY,PER 9/2/99.A HOF HO, ALE-427786,OR PER PALE 103/35-3J,ACCEPTED S THE C/L EC OF GENE ANRY TRAIL aN�gp�.C � Pot BEETRE MCIPTO'BAYIAv +2959' FRY N UC/il�/�p FAR SNO SATE.PERFARED � A EASEMENT FOP.ATORM OTANI INCOMES.EGRESS AND INCIDENTAL PURPOSES, Q ED-2'GOALS DISC STAL'.PED-CPS 91 M 05 IN LION G,�6n l7O IN FAVOR OF RIVERSIDE COUNTY FLOOD CONTROL AND WATER CONDENSATION DISTRICT, WELL.PER P M B 1833/35-3].CEMENT A ME C/L EC OF GENE PERSONALLY KNOWN TO ME(WE MCV'LT IC TIC MI TIT_C1"�nrMCFALT, C/:CM.LO RED 9/24/99,AS INS T NO 1999-42]]BJ,OUR AUY TRAIL 010NORTH 35 M'N OF E FIST-WESTFRtER OU SECTION LINE N BE ME Pc-RSON(S)WHOSE NAMES) UNARE SUBSCRIBED TD ME WITHIN INSTRUMENT AND ARCODWLAGGm TO ME THAT HE/SHE/MEY IXECUTET ME FAME IN HIS/HFNT IR AUTHORIZED A AN EAEMFNT FOR WATER ORANAGE AND RETENNON IN FAVOR OF END PRODUCS Q ED 2"BRASS RAG STAMPED"CPS 1A3+4422",ON 05 IN MON WELL CAPACTYIIES).AND THAT B!MIS/HENGAAR SIONAMREIS)ON THE HISTAMINICTHE PERSONAE). ORDER ESTION,REC. 12/2/O3.A INST NO,20M-94ORDS,OF PER M B 97/62-64.ACCEPTED AS ME C/L BC OF GENE AUTY TRAIL OR ME ENTRY UPON BEHALF OF WHICH ME PERSONAE)ACTED,EXECUTED THE INSTRUMENT 12 AN EADEAENT FOP.INGRESS ANI EGRESS 40 IN GUAM,RESERVED FOR THE BENEFIT 22 ED 2'A.DISC STATED,AD A 105+GS,C',ON A"IN IRON.WELL. MY LOIA IAISSION EXPIRES MY PRINCIPAL PLACE OF BUSINESS OF PARCEL 4,A SHOWN ON PARCOL MAP NO 27912,ON FEE IN BOOK 183, ❑PER M R 97/5-64 ACCEPTER A ME GEL EC OF GENE AUiRY TRAIL WINTERS MY HAND AND OFFIL L SEAL ' PAGES 35-37.INCWSNE,OF PARCEL.MAPS,0 R. 13 ATIA)L4,OAIB LDUNh. _ ' AN EASEMENT FOR FLOOD CONTROL 200 IN\VIOIH.IN FAVOR OF ME RIVERSIDE COUNTY FLOOD 0 N 2 BRP55 DISC,BLAMED E AS 110-51.8 C" ON OR IN NNE WELL, e x}I RSA CONTROL AND WATER CONSERVAIDN DISTRICT AS SHOWN ON ME WHREWATER RIVER CHANNEL THEM PER AI6 9]/fi2-64,ALLEPDEp A ME C/L B C.OF GENE AVRiY TRAIL / SURVEY AMOMENT CUP DATE) 10/17/65,ON WLE AM ME CHICAGO COUNTY SURVEYOR 24 ED 2"ORA 0 AIDED SA DISC STAMPER"CPS 112+590 .ON O5- IN A111 ADA)A)/ ©'(Jlr�f / MAP NO SCOWL AND PER INST.NO,1999-a2]TB>REC.9/24/99.0 R PER R.S 67/85-86,ACLEPTEG IS ME C/L EC OF GENE AUTY TEAL (PRIM NAME) N. 1609 TABLE OF CONTENTS 1.Construction Obligations . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 1 1.1 Works of Improvement . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 1 1.2 Other Obligations Referenced in Conditions of Tentative Map Approval . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 1 1.3 Intent of Plans . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 2 1.4 Survey Monuments . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 2 1.5 Performance of Work . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 2 1.6 Changes in the Work . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 2 1.7 Defective Work . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 2 1.8 No Warranty by City . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 2 1.9 Authority of the City Engineer . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 2 1.10 Documents Available at the Site . . . . . . . . . . . . . I . . . . . . . . . . . . . . . . . . . . . . . 3 1:11 Inspection . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 3 1.12 Compliance with Law . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 3 1.13 Suspension of Work . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 3 1.14 Final Acceptance of Works of Improvement . . . . . . . . . . . . . . . . . . . . . . . . . . . . 3 2. Time for Performance . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 3 2.1 Commencement and Completion Dates . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 3 2.2 Phasing Requirements . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 4 2.3 Force Majeure . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 4 2.4 Continuous Work . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 4 2.5 Reversion to Acreage . . . . . . . . . . . . . . . . . _.. . . . . . . . . . . . . . . . . . . . . . . . . . . 4 2.6 Time of the Essence . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 4 3. Labor . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 4 3.1 Labor Standards . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 5 3.2 Nondiscrimination . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 5 3.3 Licensed Contractors . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 5 3.4 Workers' Compensation . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 5 4. Security . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 5 4.1 Required Security . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 5 4.2 Form of Security Instruments . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 5 4.3 Subdivider's Liability . . . . . . . . . . . . . . . . . . . . . . . . . . . . .. . . . . . . . . . . . . . . . . . 6 4.4 Letters of Credit . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 6 4.5 Release of Security Instruments . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 7 5. Cost of Construction and Provision of Inspection Service . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 7 5.1 Subdivider Responsible for All Related Costs of Construction . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 7 5.2 Payment to City for Cost of Related Inspection and Engineering Services . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 7 6. Acceptance of Offers of Dedication . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 8 i 1,La 7. Warranty of Work . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 8 8. Default . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 8 8.1 Remedies Not Exclusive . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 8 8.2 City Right to Perform Work . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 8 8.3 Attorney's Fees and Costs . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 8 9. Indemnity . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 8 10 General Provisions . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 9 10.1 Successors and Assigns . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 9 10.2 No Third Party Beneficiaries . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 9 10.3 Entire Agreement; Waivers and Amendments . . . . . . . . . . . . . . . . . . . . . . . . . . . 9 11. Corporate Authority . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . . 9 C 1 11 s 4 SUBDIVISION IMPROVEMENT AGREEMENT THIS SUBDIVISION IMPROVEMENT AGREEMENT(this "Agreement") is entered into this day of , 2005, by and between the CITY OF PALM SPRINGS, a municipal corporation of the State of California ("CITY'), and PALM SPRINGS CLASSIC, LLC, a Delaware Limited Liability Company("Subdivider"). RECITALS A. Subdivider is the owner of, and has obtained approval of a subdivision map for Tract Map No. 32233-1, located in the City of Palm Springs, County of Riverside, State of California (the "Property"), as described on Exhibit "A". The map contains conditions of approval for the development of the Property(the "Conditions") as described on Exhibit "B". B. Pursuant to the Conditions, Subdivider, by the Map, has offered dedication to the City of Palm Springs Lots "A" through "E", inclusive, for street, public utility and sewer purposes; an easements for public utility and sewer purposes shown as "10' PUE", along and adjacent to all private streets; easements for public utility and sewer purposes, together with the right of ingress and egress for service and emergency vehicles and personnel, over Lots "F"through "O", inclusive; a 20 feet wide easement for emergency ingress and egress purposes across a portion of Lot"AC"; easements for public utility and sewer purposes over Lots"P"through "Y", inclusive; and easements for sidewalk and pedestrian purposes over portions of Lots 44, 46, 47, 49, 50, 51, "S", and Lot"AA"; and City desires to accept said dedication and certain other improvements as described in this Agreement. C. Subdivider has delivered to City and City has approved plans and specifications and related documents for certain "Works of Improvement" (as hereinafter defined) which are required to be constructed and installed in order to accommodate the development of the Property. D. Subdivider's agreement to construct and install the Works of Improvement pursuant to this Agreement and its public dedications and other improvements, as described in this Agreement, are a material consideration to City in approving the parcel map for the Property and permitting development of the Property to proceed. COVENANTS Based upon the foregoing Recitals which are incorporated herein by reference and in consideration of City's approving the Map for the Property and permitting development of the Property to proceed, Subdivider agrees to timely perform all of its obligations as set forth herein. 1. Construction Obligations. 1.1 Works of Improvement. Subdivider agrees, at its sole cost and expense, to construct or install or cause to be constructed or installed the street, drainage, domestic water, sanitary sewer and other improvements(herein sometimes collectively referred to as the"Works of Improvement"), as the same may be supplemented and revised from time to time as set forth herein(said plans and specifications, together with all related documents, are referred to herein as the "Plans"). The estimated construction cost for the Works of Improvement is $2,032,000.00. 1.2 Other Obligations Referenced in Conditions of Tentative Map Approval. In addition to the foregoing, Subdivider shall satisfy all of the conditions of approval on the Tentative Map for the Property. The conditions of approval associated with the Tentative Map are included as Exhibit "B" attached hereto. 1 1.3 Intent of Plans. The intent of the Plans referenced in Section 1.1 is to prescribe a complete work of improvement which Subdivider shall perform or cause to be performed in a manner acceptable to the City Engineer (or his/her designee) and in full compliance with all codes and the terms of this Agreement. Subdivider shall complete a functional or operable improvement or facility, even though the Plans may not specifically call out all items of work required for the contractor to complete its tasks, incidental appurtenances, materials, and the like. If any omissions are made or information necessary to carry out the full intent and meaning of the Plans, Subdivider or its contractor shall immediately notify its design engineer who will seek approval of the City Engineer for furnishing of detailed instructions. In the event of any doubt or question arising regarding the true meaning of any of the Plans, reference shall be made to the City Engineer whose decision thereon shall be final. Subdivider recognizes that the Plans consist of general drawings. All authorized alterations affecting the requirements and information given on the Plans shall be in writing and approved by the City Engineer.The Plans shall be supplemented by such working orshop drawings as are necessary to adequately control the work.Without the City Engineer's prior written approval,no change shall be made by Subdivider or Subdivider's contractor to any plan, specification, or working or shop drawing after it has been stamped as approved. 1.4 Survey Monuments. Before final approval of street improvements, Subdivider will place survey monument(s) as shown on the Map in accordance with the provisions of the State Subdivision Map Act and the Subdivision Ordinance of the City of Palm Springs. Subdivider shall provide security for such obligation as provided in Section 4.1(a)(iii) and, after setting the monument(s), Subdivider shall furnish the City Engineer of the City of Palm Springs written notice of the setting of said monument(s) and written proof of having paid the engineer or surveyor for the setting of said monument(s). 1.5 Performance of Work. Subdivider shall furnish or cause to be furnished all materials, labor, tools, equipment, utilities, transportation, and incidentals required to perform Subdivider's obligations under this Agreement. 1.6 Changes in the Work. The City Engineer, without invalidating this Agreement and without notification to any of the sureties or financial institutions referenced in Paragraph 4, may order extra work or may make changes by altering or deleting any portion of the Works of Improvement as specified herein or as deemed necessary or desirable by the City Engineer as determined necessary to accomplish the purposes of this Agreement and to protect the public health, safety, or welfare. The City Engineer shall notify Subdivider or Subdivider's contractor in writing (by Correction Notice)at the time a determination has been made to require changes in the work. No field changes performed or proposed by Subdivider or its contractor shall be binding on City unless approved in writing by the City Engineer. 1.7 Defective Work. Subdivider shall cause its contractor to repair, reconstruct, replace, or otherwise make acceptable any work found by the City Engineer to be defective. 1.8 No Warranty by City. The Plans for the Works of Improvement have been prepared by or on behalf of Subdivider or its consultants or contractors, and City makes no representation or warranty, express or implied, to Subdivider or to any other person regarding the adequacy of the Plans or related documents. 1.9 Authority of the City Engineer. In addition to the authority granted to the City Engineer elsewhere in this Agreement,the City Engineer shall have the authority to decide all questions which may arise as to the quality and acceptability of materials furnished and work performed, and all questions as to the satisfactory and acceptable fulfillment of the terms of this Agreement by Subdivider and Subdivider's contractor. 2 1.10 Documents Available at the Site. Subdivider shall cause its contractor to keep a copy of all approved Plans at the job site and shall give access thereto to the City's inspectors and engineers at all times. 1.11 Inspection. Subdivider shall have an authorized representative on the job site at all times during which work is being done who has full authority to act for Subdivider, or its design engineer, and Subdivider's contractor(s) regarding the Works of Improvement. Subdivider shall cause its contractor to furnish the City with every reasonable facility for ascertaining whether or not the Works of Improvement as performed are in accordance with the requirements and intent of this Agreement, including the Plans. If the City inspector requests it, the contractor at any time before acceptance of the Works of Improvement shall remove or uncover such portions of the finished work as may be directed which have not previously been inspected.After examination,the contractor shall restore said portions of the work to the standards required hereunder. Inspection or supervision by the City shall not be considered as direct control of the individual workmen on the job site. City's inspector shall have the authority to stop any and all work not in accordance with the requirements contained or referenced in this Agreement. The inspection of the work by City shall not relieve Subdivider or the contractor of any obligations to fulfill this Agreement as herein provided, and unsuitable materials or work may be rejected notwithstanding that such materials or work may have been previously overlooked or accepted. 1.12 Compliance With Law. In addition to the express provisions of this Agreement and the Plans, Subdivider shall cause construction of the Works of Improvement to be completed in accordance with all other applicable federal, state, and local laws, ordinances, rules and regulations. 1.13 Suspension of Work. City Engineer shall have authority to order suspension of the work for failure of the contractor to comply with law pursuant to Section 1.11. In case of suspension of work for any cause whatever, Subdivider and its contractor shall be responsible for all materials and shall store them properly if necessary and shall provide suitable drainage and erect temporary structures where necessary. 1.14 Final Acceptance of Works of Improvement. After Subdivider's contractor has completed all of the Works of Improvement, Subdivider shall then request a final inspection of the work. If items are found by the inspector to be incomplete or not in compliance with this Agreement or any of the requirements contained or referenced herein, City will inform the contractor of such items. After the contractor has completed these items, the procedure shall then be the same as specified above for the contractor's initial request for final inspection. If items are found by City's inspector to be incomplete or not in compliance after two(2)"final" inspections, City may require the contractor, as a condition to performing further field inspections, to submit in writing a detailed statement of the work performed subsequent to the date of the previous inspection which was found to be incomplete or not in compliance at that time. No inspection or acceptance pertaining to specific parts of the Works of Improvement shall be construed as final acceptance of any part until the overall final acceptance by City is made. Final acceptance shall not constitute a waiver by City of defective work subsequently discovered. The date on which the Works of Improvement will be considered as complete shall be the date of the Notice of Acceptance. 2. Time for Performance. 2.1 Commencement and Completion Dates. Subject to Section 2.2 and 2.3 below, Subdivider shall (i)commence with construction and installation of the Works of Improvement thirty 3 30 da s following City's approval of the Plans("Commencement Date"); and(ii)complete or cause to be completed all of the Works of Improvement two (2) vears after the Commencement Date. Extensions of time for completion of the Works of Improvement may be granted upon approval by the City Engineer or his designee. Extension of time may be granted upon mutual agreement of the City Engineer and Subdivider, either verbally or in writing, as required by the City Engineer or his designee. 2.2 Phasinq Requirements. Notwithstanding the provisions of Section 2.1, City reserves the right to control and regulate the phasing of completion of specific Works of Improvement as required to comply with applicable City ordinances, regulations, and rules relating to the timely provision of public services and facilities. In addition to whatever other remedies City may have for Subdivider's failure to satisfy such phasing requirements, as the same now exist or may be amended from time to time, Subdivider acknowledges City's right to withhold the issuance of further building permits on the Property until such phasing requirements are satisfied. Prior to issuance of building permits, Subdivider shall provide satisfactory evidence that all applicable requirements that are a condition to issuance of building permits have been satisfied. Such requirements may include the payment of fees,construction of improvements,or both. Final inspections or issuance of Certificates of Occupancy may be withheld from the Subdivider by the City, if, upon a determination by the City Engineer or his designee, completion of specific Works of Improvements or other requirements associated with the development of the Property have not been completed to his satisfaction. 2.3 Force Majeure. Notwithstanding the provisions of Section 2.1, Subdivider's time for commencement and completion of the Works of Improvement shall be extended for the period of any enforced delay caused due to circumstances beyond the control and without the fault of Subdivider, including to the extent applicable adverse weather conditions, flood, earthquakes, strikers, lockouts, acts or failures to act of a public agency(including City), required changes to the scope of work required by City, and similar causes; provided, however, that the period of any enforced delay hereunder shall not include any period longer than five(5)days prior to City's receipt of a written notice from Subdivider or its Contractor detailing the grounds for Subdivider's claim to a right to extend its time for performance hereunder. City Engineer shall evaluate all claims to Force Majeure and his decision shall be final. 2.4 Continuous Work. After commencement of construction of the Works of Improvement (or separate portion thereof), Subdivider shall cause such work to be diligently pursued to completion, and shall not abandon the work for a consecutive period or more than thirty(30) days, events of Force Majeure excepted. 2.5 Reversion to Acreaqe. In addition to whatever other rights City may have due to Subdivider's failure to timely perform its obligations hereunder, Subdivider recognizes that City reserves the right to revert the Property to acreage subject to the limitations and requirements set forth in California Government Code Sections 66499.11-66499.20-314. In this regard, Subdivider agrees that if the Works of Improvement have not been completed on or before the later of two (2) years from the date of this Agreement or within the time allowed herein, whichever is the later, and if City thereafter initiates proceedings to revert the Property to acreage, pursuant to Government Code Section 66499.16 Subdivider hereby consents to reversion and agrees that any improvements made by or on behalf of Subdivider shall not be considered in determining City's authority to revert the Property to acreage. 2.6 Time of the Essence. Time is of the essence of Subdivider's performance of all of its obligations under this Agreement, 3. Labor. 4 't1S 3.1 Labor Standards. Subdivider shall be responsible for causing all contractors and subcontractors performing any of the Works of Improvement to comply with all applicable federal and state labor standards, including to the extent applicable the prevailing wage requirements promulgated by the Director of Industrial Relations of the State of California Department of Labor. 3.2 Nondiscrimination. Subdivider agrees that no contractor or subcontractor performing any of the Works of Improvement shall discriminate against any employee or prospective employee with respect to such work in hiring, promotion, seniority, or any other terms and conditions of employment on the grounds of race, creed, color, national origin, ancestry, religion, sex, or marital status. 3.3 Licensed Contractors. Subdivider shall cause all of the Works of Improvement to be constructed by contractors and subcontractors with valid California Contractors'licenses for the type of work being performed. 3.4 Worker's Compensation. Subdivider shall cause every contractor and subcontractor performing any of the Works of Improvement to carry Workers'Compensation Insurance as required by the Labor Code of the State of California and shall cause each such contractor and subcontractor to submit to City a Certificate of Insurance verifying such coverage prior to such contractor or subcontractor entering onto the job site. 4. Security. 4.1 Required Security. (a) At the time Subdivider executes this Agreement, Subdivider shall furnish to City the following bonds, letters of credit, instruments of credit (assignment of deposit account) or other security acceptable to City in its sole and absolute discretion and satisfying the requirements of the applicable provisions of this Section 4 below(hereinafter"Security Instruments"): (i) A Security Instrument securing Subdivider's faithful performance of all of the Works of Improvement("Faithful Performance Security Instrument"), in the amount of$2,032,000.00 equal to 100% of the estimated construction cost referenced in Section 1.1. (ii) A Security Instrument guaranteeing the payment to contractors, subcontractors, and other persons furnishing labor, materials, and/or equipment ("Labor and Materials Security Instrument")with respect to the Works of Improvement in an amount equal to $1,016,000.00 equal to 50% of the estimated construction cost referenced in Section 1.1. (iii) A Security Instrument guaranteeing the payment of the cost of setting monuments as required in Section 1.4 in the amount of$35 000.00 equal to 100% of the cost thereof. This Agreement shall not be effective for any purpose until such Security Instruments are supplied to and approved by City in accordance herewith. (b) Required Security Instrument for Maintenance and Warrantv. Prior to the City Council's acceptance of the Works of Improvement and recordation of a Notice of Completion, Subdivider shall deliver a Security Instrument warranting the work accepted for a period of one(1)year following said acceptance ("Maintenance and Warranty Security Instrument"), in the amount of$304,800.00 equal to 15% of the estimated construction cost set forth in Section 1.1 or a suitable amount determined by the City Engineer. 4.2 Form of Securitv Instruments. All Security Instruments shall be in the amounts required under Section 4.1 (a) or 4.1(b), as applicable, shall meet the following minimum 5 �; 41 requirements and otherwise shall be in a form provided by City or otherwise approved by the City Attorney: (a) Bonds. For Security Instruments provided in the form of bonds, any such bond must be issued and executed by an insurance company or bank authorized to transact surety business in the State of California.Any insurance company acting as surety shall have a minimum rating of A-IX, as rated by the current edition of Best's Key Rating Guide published by A.M. Best's Company, Oldwick, New Jersey, 08858. Any bank acting as surety shall have a minimum rating of AA, as rated by Moody's or Standard & Poor's. (b) Letters of Credit. For Security Instruments which are letters of credit, any letter of credit shall be an original separate unconditional, irrevocable, negotiable and transferable commercial letter of credit issued by a financial institution with offices in the State of California acceptable to City. Any such letter of credit shall specifically permit City to draw on same by unilateral certification of the City Engineer of the City that Subdivider is in default under its payment or performance obligations hereunder or in the event Subdivider fails to deliver a replacement letter of credit not less than thirty (30)days prior to the date of expiration of any such letter of credit and shall further be subject to the provisions of Section 4.4. (c) Instrument of Credit. For Security Instruments which are Instruments of Credit, any Instrument of Credit shall be an assignment of deposit account assigning as security to City all of Subdivider's interest in funds on deposit in one or more bank accounts with financial institutions acceptable to City. (d) General Requirements for all Security Instruments. (i) Payments under any Security Instruments shall be required to be made (and, with respect to bonds, litigation shall be required to be instituted and maintained) in the City of Palm Springs, State of California (and the Security Instrument shall so provide). (ii) Each Security Instrument shall have a minimum term of one (1)year after the deadline for Subdivider's completing the Works of Improvement, in accordance with Section 2.1 (other than Instruments of Credit, which shall have no defined term or expiration date). (iii) Each Security Instrument shall provide that changes may be made in the Works of Improvement pursuant to the terms of this Agreement without notice to any issuer or surety and without affecting the obligations under such Security Instrument. 4.3 Subdivider's Liabilitv. While no action of Subdivider shall be required in order for City to realize on its security under any Security Instrument, Subdivider agrees to cooperate with City to facilitate City's realization under any Security Instrument, and to take no action to prevent City from such realization of any Security Instrument. Notwithstanding the giving of any Security Instrument or the subsequent expiration of any Security Instrument or any failure by any surety or financial institution to perform its obligations with respect thereto, Subdivider shall be personally liable for performance under this Agreement and for payment of the cost of the labor and materials for the improvements required to be constructed or installed hereby and shall, within ten (10) days after written demand therefor, deliver to City such substitute security as City shall require satisfying the requirements in this Section 4. 4.4 Letters of Credit. (a) In the event a letter of credit is given pursuant to Section 4.2(b), City shall be entitled to draw on any such letter of credit if a replacement letter of credit (expiring in not less than one (1) year, unless City agrees to a lesser term in City's sole and absolute discretion) is not delivered not ID" 1?® 6 less than thirty(30)days prior to the expiration of the original letter of credit, such substitute letter of credit being in the same amount and having the terms and conditions as the initial letter of credit delivered hereunder, issued by a financial institution acceptable to City as of the date of delivery of the replacement letter of credit. (b) In the event of draw by the City on a letter of credit, the City may elect, in its sole and absolute discretion, to apply any such funds drawn to the obligations secured by such letter of credit or to hold such funds in an account under the control of the City,with no interest accruing thereon for the benefit of the Subdivider. If the City elects to hold the funds in an account pursuant to the foregoing, City may thereafter at any time elect instead to apply such funds as provided in the foregoing. Subdivider agrees and hereby grants City a security interest in such account to the extent required for City to realize on its interests therein and agrees to execute and deliver to City any other documents requested by City in order to evidence the creation and perfection of City's security interest in such account. 4.5 Release of Securitv Instruments. (a) City shall release the Faithful Performance Security Instrument and Labor and Materials Security Instrument when all of the following have occurred: (i) Subdivider has made written request for release and provided evidence of satisfaction of all other requirements in this Section 4.5; (ii) the Works of Improvement have been accepted; (iii) Subdivider has delivered the Maintenance and Warranty Security Instrument; and (iv) subject to the following sentences after passage of the time within which lien claims are required to be made pursuant to Article 3 (commencing with Section 3114) of Chapter 2 of Title 15 of Part IV of Division 3 of the California Civil Code. If lien claims have been timely filed, City shall hold the Labor and Materials Security Instrument until such claims have been resolved, Subdivider has provided a statutory bond, or otherwise as required by applicable law. (b) City shall release the Maintenance and Warranty Security Instrument upon Subdivider's written request upon the expiration of the warranty period, provided no claims are outstanding at that time regarding defective work. 5. Cost of Construction and Provision of Inspection Service. 5.1 Subdivider Responsible for All Costs of Construction. Subdivider shall be responsible for payment of all costs incurred for construction and installation of the Works of Improvement. In the event Subdivider is entitled to reimbursement from City for any of the Works of Improvement, such reimbursement shall be subject to a separate Reimbursement Agreement to be entered into between Subdivider and City prior to construction of the works. 5.2 Payment to Citv for Cost of Related Inspection and Enqineerinq Services. Subdivider shall compensate City for all of City's costs reasonably incurred in having its authorized representative make the usual and customary inspections of the Works of Improvement. In addition, Subdividershall compensate Cityfor all design, plan check,evaluating any proposed or agreed-upon changes in the work. The procedures for deposit and payment of such fees shall be as established by the City Council. In no event shall Subdivider be entitled to additional inspections or a final inspection and acceptance of any of the Works of Improvement until all City fees and charges have been fully paid, including without limitation, charges for applicable penalties and additional required inspections. 7 � . 6. Acceptance of Offers of Dedication. The City Council shall pass as appropriate resolution or resolutions accepting all offers of dedication shown on the Map for the Property, with acceptance to become effective upon completion and acceptance by City of the Works of Improvement. Such resolution(s)shall authorize the City Clerk to execute the Certificate made a part of the Map regarding said acceptance of the offer of dedication. 7. Warranty of Work. Subdivider shall guarantee all Works of Improvement against defective materials and workmanship for a period of one (1)year from the date of final acceptance. If any of the Works of Improvement should fail or prove defective within said one(1)year period due to any reason other than improper maintenance, or if any settlement of fill or backfill occurs, or should any portion of the Works of Improvement fail to fulfill any requirements of the Plans, Subdivider,within fifteen(15)days after written notice of such defects, or within such shorter time as may reasonably be determined by the City in the event of emergency, shall commence to repair or replace the same together with any other work which may be damaged or displaced in so doing. Should Subdivider fail to remedy defective material and/or workmanship or make replacements or repairs within the period of time set forth above, City may make such repairs and replacements and the actual cost of the required labor and materials shall be chargeable to and payable by Subdivider. The warranty provided herein shall not be in lieu of, but shall be in addition to, any warranties or other obligations otherwise imposed by law. 8. Default. 8.1 Remedies Not Exclusive. In any case where this Agreement provides a specific remedy to City for a default by Subdivider hereunder, such remedy shall be in addition to, and not exclusive of, City's right to pursue any other administrative, legal, or equitable remedy to which it may by entitled. 8.2 City Riqht to Perform Work. In addition to whatever other rights or remedies it may have for Subdivider's default hereunder, in the event Subdivider shall fail to timely perform any work required to be performed under this Agreement and such failure shall continue for a period of twenty (20) days after receipt of written notice of default from City, or thereafter Subdivider shall fail to diligently and continuously pursue the cure of any such default to completion, City shall have the right to enter into the Property and perform any of the uncompleted work by force account or contract or both and thereupon recover from Subdivider or any Security Instrument, or both, the full cost and expense thereby incurred by City. 8.3 Attorney's Fees and Costs. In the event that Subdivider fails to perform any obligation under this Agreement, Subdivider agrees to pay all costs and expenses incurred by City in securing performance of such obligations, including costs of suit and reasonable attorney's fees. In the event of any dispute arising out of Subdivider's performance of its obligations under this Agreement or under any of the Security Instruments referenced herein, the prevailing party in such action, in addition to any other relief which may be granted, shall be entitled to recover its reasonable attorneys fees and costs. Such attorneys fees and cost shall include fees and costs on any appeal, and in addition a party entitled to attorney's fees and costs shall be entitled to all other reasonable costs incurred in investigating such action, taking depositions and discovery, retaining expert witnesses, and all other necessary and related costs with respect to the litigation. All such fees and costs shall be deemed to have accrued on commencement of the action and shall be enforceable whether or not the action is prosecuted to judgment. 9. Indemnity. Subdivider agrees to indemnify, defend, and hold harmless City and City's officers, employees, and agents from and against any and all claims, liabilities, losses, damages, causes of action, and obligations arising out of Subdivider's failure to perform the construction and installation of the Works of Improvement in accordance with the requirements contained or referenced in this Agreement. Said indemnity obligation shall apply to personal injury, death, 8 `X' 2- a"` W� Edn .e property damage, economic loss, and any other monetary damage or penalty to which City may be subjected, including without limitation, attorney's fees and costs and the costs of realizing on any Security Instrument provided by Subdivider pursuant to the terms hereof. Such indemnity obligation shall not extend to any loss resulting from City's sole negligence or willful misconduct. 10. General Provisions. 10.1 Successors and Assiqns. This Agreement shall be binding upon all successors and assigns to Subdivider's right, title, and interest in and to the Property and any portion thereof. 10.2 No Third Party Beneficiaries. This Agreement is intended to benefit only the parties hereto and their respective successors and assigns. Neither City nor Subdivider intend to create any third party beneficiary rights in this Agreement in any contractor, subcontractor, member of the general public, or other person or entity. 10.3 Entire Agreement; Waivers and Amendments. This Agreement integrates all of the terms and conditions mentioned herein, or incidental hereto, and supersedes all negotiations and previous agreements between the parties with respect to all or part of the subject matter hereof, except as may be expressly provided herein.All waivers of the provisions of this Agreement must be in writing and signed by an authorized representative of the party to be charged, and all amendments hereto must be in writing and signed by the appropriate representatives of both parties. 11. Corporate Authority. The persons executing this Agreement on behalf of the parties hereto warrant the (1) such party is duly organized and existing, (ii) they are duly authorized to execute and deliver this Agreement on behalf of said party, (iii)by so executing this Agreement, such party is formally bound to the provisions of this Agreement, and (iv) the entering into of this Agreement does not violate any provisions of any other Agreement to which said party is bound. (Signatures on Next Page) 9 IN WITNESS WHEREOF, the parties hereto have executed this Subdivision Improvement Agreement as of the date first above written. ATTEST: CITY OF PALM SPRINGS, CALIFORNIA By James Thompson, City Clerk David H. Ready, City Manager RECOMMENDED BY: APPROVED/AS TO FORM: David Barakian, City Engineer By: SUBDIVIDER: Title:_ PALM SPRINGS CLASSIC, LLC, a Delaware Limited Liability Company By: Lennar Homes of California, Inc., a California Corporation, Managing Member (Check One: _individual, _partnership, X corporation) By: _ Signature By: Tory -6po(s View P2 5i bcol Name'and Title By: Signature By: Name and Title Mailing Address: 391 North Main Street, Suite 301 Corona, California 92880 f951) 817-3500 10 CALIFORNIA ALL-PURPOSE ACKNOWLEDGEMENT State of California County of Riverside On ky-; I 1 � , 2005 before me, Jillian Newman a Notary Public, personally appeared Tom Banks, personally known to me to be the person whose name is subscribed to the within instrument and acknowledged to me that he executed the same in his authorized capacity, and that by his signature on the instrument the person, or the entity upon behalf of which the person acted, executed the instrument. WITNESS my hand and offieial seal. - JILUAN NEWM N CommWWrr rf 1435099 s@MyComm. Noiary PuWIC-CalHomla orange Count' [[ ��Aug 15,2007I Notary Seal ENGINEER'S NOTES ENGINEER'S NOTES (CONI SHEET 3 OF 9 SHEETS THE Bt$rc aMtlC FOR TRIIS NIIAP Is THE NORIREA1 HNC Or TL-NDR1xEgx ICANTER IN THE CITY OF PALM SPRINGS, COUNTY OF RIVERSIDE, STATE OF CALIFORNIA AS_ �N04 PNO E-�SNo z s12,PER LAND la;=�;ALENT AS N 895111-w TRACT MAP N0. 32233— 1 INRI.ONT�TNE 0 INCIG]ES FOUND 1"JP W/FAG PCE 25555.DO 05',PER P.MS. 183/35-3], R/VI INpICARS"I,I.NOTES OTNUKOEE BEING A SUBDIVISION OF PARCELS 3 AND 4 OF PARCEL MAP NO. 27912, AS SHOWN cwHo GOAcxELu vAluv WATER DISTRICT 0 ND¢ATES SET T'IP.ANN PV ,IC PLUG STgMPm'TO E E 26TC1".FwSx. BY MAP ON FILE IN BOOK 183, PAGES 35 THROUGH 37, INCLUSIVE, OF PARCEL PUE INm unlit NL GATS PuFLG ,KDR, � ]�J UEE'S GOTTEN ATTEnmsE MAPS, RECORDS OF RIVERSIDE COUNTY, TOGETHER WITH PORTIONS OF SECTION ]AND (D 0 INDIGTES SET INDICATES RESTRICTED 1-1 /1[[ ACCESS RICH,DEDICATED HEREON DI N/a"ET DISH STNdOm'recE 2swr,e.usx. THE NORTH HALF OF SECTION IS, TOWNSHIP 4 SOUTH, RANGE 5 EAST. S.B.M. E OIL ANC TAG IN TOP OF CURE ON THE PRODONGATON OF AL SEE mT LOPE, @ O IN AC.PI.Yi(RN.CO.SIO TPE'E'MOH) S(-) INDICATE RECORD OATH PER PARCEL me RN 27912, �V MSA Cl INC. DECEMBER - 2004 nA Pm'GLOE 26w1',IN HER OF THE UNCON LOU GGRNERS Q3 O — P PM E 15]/]5-]].AND MFAERREp n SET U R 1'IRH PLASTIC PLUG STAMPED"R GE 28401'.11 NAIL IND TAG IN NO. LOOTING OTT [-] INDICATES RECORD C.PER RS 6]/ES-e6. ®� STALPm'R GE 25401"OR NIL ANG TAN IN FENCING NATERIAL,TAGGED'R CE ZFFCl-. 3. AS APPROPRIATE.AT REAR LOT CORNERS All ANCLE POINTS,UNLESS OTHERWISE NOT. c-> INCIGIFS RECORD GW PEP RS O6/a]-aC. -h IxDIGrTs RECORD Ogrn PER Ma RT/6z-6a G. ,eoo TRIAL0RO4.-m5.5]a'Yx�s xD LETTERED FEARS-31 LIIR RI INDICATES RECORD OATO PER 0 R RE- o . TE Sl.UGES-f0 LOCK Z IN oozYSS W LOT 5F, SCALE 1"=4oC' m r [WI EFOCE LETTE•ED tars-12 LORD 0 12 INDICATES RECORD GTA PER OR C5- AN CC Iv'15' 653455 m /J ]6 �6 b'P3 x m1 LDIS(UBEPECIFlm PNJOA UIN LDR n O m m [06sv7] T GO ' a __CITY OF CATHEDRAL CITY_ (zos,n) ' <]z�z>.' = (N LR233r 11 °rnxe aeN (N o y r v_(995 Po<)_SAN JOAOUIN Dql—} 6 CITY OF PALM SPRINGS w n„N T -fix a LOT V 0vn<0 �o*Ee' CLUBHOUSE VIEW DRIVE n m L • mTAP I G m m N �u�me �rmN�rza € Ln �Gll SITE POTODOC1. OFtl° TOT•w• CLUBHOUSE VIEW DRIVE '� ELF coxrr HT N INOT IF p'8 xEc�—/—/ 4s'uR p N s n.Nbli9q� Lor nALCALA WAY L T •�Zsz LUa-rI — ©F�j. O aECW � 0 uamlx e 0 9Nhp�64'�Qp P z_ai.' �Ov IPNGiw LOT R. 1 '•g '°rn9� W - I ° Ca O1 '(� �. Lm CJn'P q®�` W � A,TO sN f LINE DATA e �a`s �o' 'c`� �4'�. :'�� O-; I_,. per• �•I _ «: LO,>v Y3 © E`i O ¢nG a Q�° - to w 6SzI�`w zsee.,x `T� G z ESPLANADE LANE - G lK a T LS x os1]1�c ueos - G 9t •./ --- -- — — 8�o LOT W m a x"as esi )lisoo zar - w.�aTY,LEE , wT a n� J / w Ia m :O Nx JJ�W —L0 Ir^ �a9 W ro T J m wx xk Pm¢nzux �./ / a IN A nl lnoosoo) ? O H =.£ �"'�- = cw" :1- / � 11 a u36 Pn F< Pz W w r'AR 0p� S 1 / z IIx NP Om-H H..sa6w1 e < W LOTS gyp w� Iz w' y�W � /yse-� 11 11 O1 eoo E W O M DAP• / 5 No'v I_W D4s2ss > I 'a6e O•,pJ' �, , W l �� `A P`'_ /,.i" xN 111afizir q RA 11 si' e t, W m SEE DETAIL'A' x w cross LOT ee W pW / Lrro / ON SHEET 4 SEE DETAIL•F• ( Sn 0 ;gL^' e 0 _J V IN so oisl.w)Iv n ON SHEET 4 LOT � p P� 1 0000< LOT / m m Tos PLUS E%ECUTIVE' \ _ [x 000• TOP 1d (x ovos. `or 'i I2 10 J /_ / SEE DETAIL•B• D II"u 17.1 s'zc DRIVE-— - - -= ("_e'_ az)__ .,r6sIPm 0 (Isv sty'�nL 6 m/%P ON SHEET 4 �g J s lx 5SF N:w (N oo'os'es w x zy E NO ^g'� - sx w aeiT6 6 / S 11 � JF k 15� M onn°inie-e szz aioy _ / SEE DETAIL•G• N ET2 v_w ISO8I(II _ O¢FaT 0 `w=• NA °m 1s1 ON SHEET4 Lao 18-ssw vzi sV r R *s w:]rRs.'LLIC, I �Loi R m %0 .o pPHtpf�j lm/- / au >a 0 s/ 51 REP JJ— Dune �•®� .. N. Z Ov a 5 / m vswrAJ ARC TABLE 2 ' `I'llFra ,x° DELTA RnOwS I ego e•eT © .'`c " �/ - y.R.Hw = ma261n11 N5JA3U (�1 Imo' IT) - �' % P SEE SHEET 2 FOR MONUMENT NOTES, EXECUTIVE�s-�-E °�AJI RUE AN AV BIRD CENTER DR." y o E, /sas ut _ mazy loD poop oo)1 (Inzrv') V/ _ (N I.1 - ) !�T-��%E r EASEMENT NOTES AND VICINITY MAP _ Izr45 ys) (00000)I IF.2i) DRIVE �I wr 4e — ,r, u1 s (aseRo4 all f". szs P6o oO o �—i \ SEE SHEET 4 FOR DETAILS OE _ SEE DETAIL•E• / S i P smLWAu C——I —T�q �3 a g? /6 Y5 O - SEE SHEETS 5-B FOR 1 s�zs- loon oo' z0H 1 _ H DETAILED LOT DIMENSIONS U1rrw9 P000 00' Izm ssll ON SHEET 4 p J 5 �' s 2s vw I I= ®pl6® IOC a�e�, /. 300 liT J II L,1s — ' _ / SON SH ET 8 EE DETAIL • O INDICATES SHEET NUMBER GO 01 11 IC INNUTNT TONS IA us -- OA 15 „Ha Rl 0.,Ol-w z l') . ILzpL r�� _ c� —1i+an iw w ils�— 20 { nILEGURANswOm fin mz 0sszn "Coen szs 60 SEE DETAIL•D•T OI— 21 M ovassr w lila sz'I ,� NOTE- cn - m \VLLIn ON SHEET 4 4N.Wu.PJ9M® NO Ca n 11V m TPwr wmwx sHmm As TEUUxom IE'VO 'Is mrmGawus ■■■ MII... 7/6 2- 4 RICF ONNESHIP AT THE TIrs OT RFfARpNG CF TMs WP. �.-s 'f J.N. 1609 4f l - Uo e� /Cz N eeso'«•W 1141A7 SHEET 4 G 9 SHEET Nxzn ' C+„sl I a,w' k P z I IN THE CITY OF PALM SPRINGS, COUNTY OF RIVERSIDE, STATE OF CALIFORNIA F sraxcuc �I z gII LOe FD•�YISTA CHINO o BEING A SUBDIVISION OF PARCELS 3 AND 4 OF PARCEL MAP N0. 21912, AS SHOWN NUTNIND \z a1 b LOsss T°ncC' p1(P ]] BY MAP ON FILE IN BOOK 183. PAGES 35 THROUGH 37, INCLUSIVE, OF PARCEL z _____ TG e x zx'ss'` zz IN z' I`x = - MAPS, RECORDS OF RIVERSIDE COUN TOGETHER WITH PORTIONS OF SECTION V AND THE NORTH HALF OF SECTION 18, TOWNSHIP 4 SOUTH, RANGE 5 EAST, S.B.M. f ivy sszsl LOT•1' (ID¢d�l a` 61 u +_NB_ 11}rI1 I5 MSS'. CONSULTING, INC.'S¢u w DECEMBER - 2004 WUr 6F¢-- wDETAIL'E• I ¢o¢ u/� aee'<c wV1 u95¢o' ARTISAN . ..w WAY ^ LOT / e< s fservarz s1iEEl) \3F4 //2\ \ e 7 w ]mm— LINE DATA LME DATA Iu �^ sP(DID' I -LN VISTA CHINO ,e,z �mlcm tf> r,moe<g `' �_' oEwutt T1L of w<¢ v/,ww�0. _ see 6 z _ obi f.oi \ �x �21 / n� x¢F�9.,art 0 Ea� s9F n „ 9 1 �¢a o wlU _ _ :� = 6 10 \ sx* R- w w _ T �rcrts cwc W rvscossmr ?� w 1 \ ¢EuvfExr -IIDODu - 'I z . u a 281 aF LOT•s• "' N°��_�� can w � �o oa..,¢a¢w (rt&wsE.�D m w IF s� o N w,PAow s N UO 'a(Ps(x)c¢c ../a )en'E �N s P.M.B.s9®4/SJ®�9 aa�° P"w lOT 0 �I sE . \ DETAIL D. v¢zn y"`r„En� n. ] \ \ 1=50• Y��P/ `PJalc ,C ]e(P)a S i E%ye'35'E\\ _IINN N c � \ SOT-` \ DETAIL'F' 44 \ ; `E6P \ v. e \ CUflV� E— p 1, a (x nia;a;"w) ,xs.ia)]o E ,E s, 'l0 9 I/ 5o. I"° ¢¢� -- Ell '®- XD ss Los'AA• old I 11,0 _ t8 �.� T \ (a](v\ Py Pare. \mPE„"=P.-E �h _ UUI _- kk 0 IF N ice.\. \m \ O \ ss os _ - N �Ga "°e`.s�+ENr � v. OS�a,>a}% � �yy \ EEo°s,'w+ �� . ''o,?z. \$ S \s. - C`J SEE SHEET 2 FOR MONUMENT NOTES, P.\ 9�� vp'a�. \ s=P\ EASEMENT NOTES AND YICINRV MAP s \ NS 'fa 9'/ ¢'� \ g, o l p SEE SHEET 3 FOR ENGINEERS NOTES 2 - ,o.l Z 011 AND BOUNDARY DIMENSIONS \ �¢o '$.vq+_ w\i \ SEE SHEETS 6-G FOR C +e N��< 3 11 DETAILED LOT DIMENSIONS \ n `� ` a w'so�x £ \ _ U::::lE 3 s 'Oo 9Uo pPPI0<0 ]<a 1\p a 1 0 - , \ \ \ � ff =ss Ol f6 SCNE 1-50' �\ „1 \ DETAIL•S• DETAIL•A• af 0- sous 1'0 s.,'=50' J.N. 1609 SEE SHEET 2 FOR MONUMENT NOTES, IN THE CITY OF PALM SPRINGS, COUNTY OF RIVERSIDE, STATE OF CALIFORNIA SHEET 5 OF 9 SHEETS N EASEMENT NOTES AND VICINITY MAP SEE SHEET 3 FOR ENGINEER'S NOTES TRACT MAP NO. 32233- 1 i '��,� LID AND BOUNDARY DIMENSIONS To 0 Ste 5r¢cI 4 FOR Deltii$ BEING A SUBDIVISION OF PARCELS 3 AND 4 OF PARCEL MAP NO. 2791Z AS SHOWN BY MAP ON FILE IN —— —————\ -� E O DENOTES SHEET NUMBER 800K 183, PAGES 35 THROUGH 37, INCLUSIVE, OF PARCEL MAPS, RECORDS OF RIVERSIDE COUNTY, TOGETHER WITH PORTIONS OF SECTION ]AND THE NORTH HALF OF SECTION 18, TOWNSHIP 4 SOUTH, RANGE 5 EAAS Odd 5 O LINE DATA CURVE TABLE _ Li F1 MSA CONSULTING, INC. DECEMEER - 2004 "s,E Li �\ Q� _ 1 EICHLER— \ I, Is - - LOT•P• �. O — //¢ I<o .uU3,R7s. SEEs ze WAY N ez ss� _ (oiis sa.esl o � . m'` o(y r Ix LF Lis es w Izu }I - 1: �� s'e messer o ''� , 2IP a DAVIDSONWAY \ N LOT'W \'0 2pX\ \\ °10 s- ll/ J GRANDVIEW STREET J (Pxrva,c sam) ryN . Q W �o: \ p��lpppp ` w <� c. \\o\f`'\ < 4<s eOe G p�GJ�,� \C WAYfl � 0\ \ [ ) A¢ ��lsx 5o'C lso /�=w o 0 eYOA\ \ °�I g( "rem SEE DETAIL'B' a » wm - P \ \ s ^3 \ o AT BOTTOM �Q W.t-oTc-1 Nsgr \\ Gc<g +.. x srtre)o,zE MIDDLE m < fia_? J \ S gs'dJ ie)sa'm -�r1, sc"j9 LOT MOTIF '�J�p \ c« SEE DETAIL'D' WAY s _ \` a �(n) 3 0, w (oam sv>cs) AT BOTTOM LEFT J __ v 77 I� \ao tie \ c'° te) x oo<ro�w /5� 7 �/ g s _ rees) _—_ sec. 18 $p ,•.* 2 < G x, \- x raa'a w <e sec.e __ _ z 0i \\i a,. x,o mw i"s Iel Gzw y 42 41 a as a9 aes 3T 'j dE ry i2 r s,ae+z•i - 00 1 SEE DETAIL'C' \ / z n3 ,o s lu u - AT SHEET \ " wx` i a z OUs V 31 OT32 3T 335J.,O s<c N NH--1 \�2 \4]0 m l'�` e6 5 8 1 F(/f T \ 5`, / \ 3 c49 �J u. ssrnox uxE \\u 33 B°v 'u ,j �., B T 30 roWVE lorervn „'3a /, o�/ \� 1 �'n B �F9P[A� 29 h's'ma � _ 5`zJ LOT s p`\\ x oz �oxxv' res�[s{6 w I L,I. oo� 'wlRyy�5�s \ 5l)1,Iv z' �5 S o �18 \` iA�OS \\/� cco �Sej iD rN10F[,NE —° e e hn so' o' \e 5 es \\ 5\ E$CENA WAY LLL»> w ISE6te' cev - 001 ' ° x r a SEE DETAIL'B' J 13 ro 9 ` e io 41 - rw s sexes'` w 19 \\\ AT SHEET 4 (vsxTsaus) F. nil GYz' [ x �P\i °c\ LOT•v e 16 1y5 _ �o " =ess ., vixva [[F (u Dr. Z \I Ol..—E) a 16 z1 �i - HpNs � s,tzps sCG./rzi e. S P\ \ P 1 LOT AA' 19 ' w s W cs, m<r moo ,ssoz csz se u' nzco sceoo' cra oe a' szs uo ps9Y < > c.< sanr <voo' uses' F�;z',. z,,?� °i fj s^„ �Gf\o�, \ osss c LF :� as sassm- ,zr oa zmns D ' GO cw ,vse'os- an oo' eoes' DETAIL'B' C �o Z xor ro sr,: D9/L\ T T�\ A ---------------------- RADIAL DATA ssspcE ------- E o < za e EJ e P fl Is z DETAIL I- 3 NOT TO scn�c lm LOT 9 w, R. LOT = ,q� e ` N• ^ W •AB' �t � -0 Y\ / Q` \2jv' \ \ -®' 0 DETAIL'A' 6c CN, �'rv6 \�r<nwrwsrtcu�crim-cn 'per D l s m norm srn�e ec zo me a;so re - o �oSs a' %oo �Lo6.W. 7rS °r ry 11E �� sx're�j I Cy uiw2 y /. 7IP 9J 92 99 9® 8 s J 17 - I LOT•AC•usiuui H PAR. e F scnLE Y'-z9o' ` 1 p., r 79 20 'a J J.N. 1609 F IN THE CITY OF PALM SPRINGS, COUNTY OF RIVERSIDE, STATE OF CALIFORNIA SHEET 6 OF 0 SHEETS 6^,ago SEE SHEET 2 FORTES MONUMENT NOTES TRACT MAP NO. 32233- 1 \ EASEMENT NOTES AND VICINITY MAP w SEE SHEET B Y DI ENGINEER'S NOTES snE corvvnzo m osswT AND BOUNDARY DIMENSIONS BEING A SUBDIVISION OF PARCELS 3 AND 4 OF PARCEL MAP N0. 27912, AS SHOWN v ¢wtt,ern NIT \ SEE SHEET 4 FOR DETAILS € LOT "B" BY MAP ON FILE IN BOOK 183, PAGER 35 THROUGH 37, INCLUSIVE, Of PARCEL n xo Rcc J1— n'Fy\ oan Ac MAPS, RECORDS OF RIVERSIDE COUNTY, TOGETHER WITH PORTIONS OF SECTION ]AND \\ 46p r THE NORTH HALF OF SECTION 18, TOWNSHIP 4 SOUTH, RANGE 5 EAST, S.B.M. y�E !O , SEE DETAIL GA\^'oP \ zoz AT LEFT w> SF'�i s. o �a MSA CONSULTING, INC. DECEMBER - 2004IN ,No'c,pE " 14 SEE SHEET T IN —�e.r srw ees sT -----_—�sExnax uxE ,D ( J�'".�'lza.o>_�e !DETAIL \ - pis,>e xoi TO_rzc \ GBANDVIEW STPEET `a�ta b o Kj�� & 02m` S W ¢$" LOaIZ v Z. SEE DETA(L'G' GOY ti 1Our s>ncsl LINE DATA '\ea — �," AT MIDDLE gIGHTI KEWAY IN.2e. \ua e cP/s �i c WAY NO uN� (aaw's=n�� ,'Pue IT 1PICASSO > > G s oa° wnv .e ,/ e�V ere,to<} v ZIN I ss _ r s5�'s�'c .<s aC�. 11 06 �6' —<cn c G.T9� aS ^�, WAY 'si`rzi �f ` \ \ .c x`s<..ao w o3 1n� <D'!\� •�' { S, `%g;sM1O ` n�`; w m DETAIL— o \\\� o°,•.� ,iz Irel E„ '°• _ -- 1.,_cN� o6sw o000 \\ o \ \ w ^SEE DETAIL B a'" (gLC4\' -- Jam—pEazOG` �\ 4S \ MONDRIAN AT BOTTOM Q°� £>' LOTI AB WAY of WAY \IN,000. uiai I LEFT =` R �� zz4o. r �� 11 21111 ,c, \ \ 4S� cocaiscres) o zss'r w \\\ uv O. cq DETAIL•D• +�¢GHi�'' 1 CM I- - \\,<V\os\ SEE DETAIL'A•G ty� rveT a su¢ ,y '¢w - \ AT TOP LEFT p sn G H '1 x �Aes1y SEE DETAIL RIGHT to 7 Q o NON . o<merzl e`� �`4oAf o�sssp'H 9p oe rAT LOWER BIGHT 46 xe " w 6' i\^ w a ' \ \)N erv'ae'u w a ems`T m s9sm I ,o Lo / m \ Fs.iG,, s �i J us \ pzs s:E ys. aYw _ OO m 0 1.os \\ 4�r? q� \ aslw ca) l x� GEARY 2e: " 1a w 1+soc \ D� `ose Snc�F�3G•g'. / y s DETAIL•G• 20 G{ WAY I _ \/T �i'j �w£ t_ \may, >6^fly ! U \ ,p' �$J'e `re ? NOT io 5W£ -E1') - \�\� a�g s a m a `,cre>LOT NH. o �J Loa N t<ze xar,os� ,i sr,os uT No.n',re eaoru- — _ ------ o,--_--- --_— CURVE DATA \ 5 �sz x e n.oi �5e- SEE DETAIL'D• n _ \mm,\ AT MIDDLE ° �G_P c m O 9 FgEY / N \ LOlso`AB• ."�' WAY E ISzo ` \\ SEE DETAIL'C•-_I AT BOTTOM 6 1 gr 5 L - rase .. = NA P ,R\W SEE SHE \; \ LOT•P`�'�° ^' 6 p Oc'�sJ in y - - \E\ \ IoariresPAcH `e io 3 n N a,oxw L(1UO2 _ 66 HIM \ \\ _ In CURVE DATA \ \ `Cod / ' le) / :\N Q1,11s' N - \ \ I w itrvc7xe NNE oil sz' \ 1 �j s,-, �zoo7 R'i \ E 1, 4 _ _ \ ssev w sti L SngG. O zs o I \ \� ev,/ v �� oNIoe S9-I�w9 a LOT•AB• �T�b I� Or /�Y" No: III 1� —�, cz11 .i Fol � mrv44 °p'�i _ 9 hF • ro=a sausl,.;�.. sa o<�" OU` �5 a�'�<a a 4n �s� r� SEE SHEET5 00° i'b. e ry LOT•AB• C o 1Nw .Q 45 1e';A, nF` \e- �6✓S wO. Imw sv..c0 p] O - I-.u_��1T�',1� jami �U- R e \�\ ..e19 LR� COTTIEq 1 \ O IlIo46 s ^'`:Y =E O - —(mY —U _ DETniL•F' liiii WAY \ / JJ N E _ - NOT To I✓I T 3L71 - �? ao1 �I 037 G a ^ 9P b. �ea�_C - to vu_ m.c Luo' zD 1„ 0 9� x e woo G a 41.1 oo'1 ve No)e<ns SKYLAR o0 10, II N NGG]�ofuJaO LANE N °' oDETAIL'B• I N L-ait cE DETAIL'G• cs< vv se' woad ,omc ��' 1� scaiE 1"=mo' d na o� ut z<os,< .,ze ao ,n„ xoT 0su,e i rvm To swc - I'ANU�6 xJ.N. 1609 oo J ` IN THE CITY OF PALM SPRINGS, COUNTY OF RIVERSIDE, STATE OF CALIFORNIA s s -�--- SHEET 7 OF 9 SHEETS 1 nl h,. T�I z=— =�— STA C�I�q= TRACT MAP NO. 32233- 1 L „a(((s�— yl a5 -.Azu' LOT Lag �z �1l l=G_Lp1.D. ` FJEIN4 A ]UBDIVIBIUN OF YARD EL]' ] qNU 4 VY YgRLEL MAP IVU. L%YI<, AS SMGIY,V fl1 MAY G!i YILG IN `�'T��\ w¢`` BOOK 183, PAGES 35 THROUGH 37, INCLUSIVE, OF PARCEL MAP$ RECORDS OF RIVERSIDE COUNTY, TOGETHER WITH AD o`SEE DETAIL'E•5t tmfli'R`sicz) �t J'f W 3- PORTIONS OF SECTION )AND THE NORTH HALF OF SECTION 18, TOWNSHIP 4 SOUTH, RANGE 5 EAST, S.B.M. ¢ I O SHEET 4saz _,A. E „ , .c D s c>Als 'O. \ SEE DETAIL•F• 1p rua�--- -r_ �_ °Tam '' �, vON SHEET 4 �5 MSA CONSULTING, INC. DECRNOER - 2004 In v) �BIYo� 2 i ` DATA CURVE DATA cD - i -g 7 s p-ea3Y Lill \ COD / N���. LINE DA C OLD z- �cR)26 c>S qp] _ �a a Js e�r„�' .'�(.,� dok ss '� D5 ` c59 48 15 N ° I IExclry - - oo' L N r+ f''q' N x> _ '� c < <oAyFT w, <° LOT•I. O FIB Q x B°Rsza ww ' e AA RON£ \ IS eG, '".M ` Y -�3> -Ue Ai 12- Dm T.scvEETALB• _ iin es � ------ ------ r'` =atP„w.»E�Em�ls �e - - w isl„ 's;� '+' °��'e,9,, ` --x ails° 6 . ,°s>. D GTI Z J k °Iv) s. k C 'e da +'s'°' \ \\ a }-I e -- °s I O Ij(`7,�I 1: „a A° "� x ��� �,.w f lDO �: G. d w 65o °I °_' nl' - I" _ c ry2P��, e'. -`°01'p v u_G ;GAD z W :All - °a N IN �o9e - sselA fa)6 e q . ¢:'fiKhm ga _A AT - w hov - y'I N Jlm'ml h w c- o o o mo=eh eya �;e szo _ _ - cn H--------- ---------- ii'isrw 90 e< ,� z AYy.�O o Gli 1 Q c 14,E' 1' _ - N Q o i zi w IT,,,, 2 SEE DETAIL•D' o •YO p W 3 FVy` n 11 + I v/,5 0�x ON SHEET 4 �`No Y¢ <CCF .� 9T ,R LINE DATA x Oil TO5 I ,- ` G' +. oE`F =;k 4 \ l� \&i. - u,Icn+ u1�x ovos'6�c _ z'l 172 DO All S �' .v IG)G 46 •s J '. PAi'•'* �;z\ `.\9s �d {'e2, :� iH ovaeis E us°> - - sa es w(el 5 n`}W ex36 AC o I' o LOT-AB- O$. 'R O fn e z i�z - z,�> - _ Tile a f 31 KI 31 DO `o A > x�sszss Im ice- izx + -_---_----_ mpo,zAii P n <oz .?i �� Dr rvss;s,s-E Ise sr F I11. 0 LD OG00' R``O 4> ARTISAN WAY SEE DETAIL IS' 5 cv `� 'Y `� Ix 1- [tq)is n' IT Ge.� LOT'I• ` ` svG'Is'a ovnao:w G, TO Ai GOT AT TOP RIGHT "'•z > ` 2 In°cun-e °i.i n e j ' 'v; "�v)" \y��, _ _ :°I AliIi AD E - tiA 1111 2, GO GO _ 9 s [ �km LOT'AF'� ` / ,57 Ix Oil m DO ze-I •G >uzou7„>1II k A Ca dz pB O I I (e �¢ I a655 IT_ GATT 3 J �G°°° I'D17 e9 cf os°a5yw ,°s6f>.Ir�° 1T1 H en ' �{.� �'�:` V/ ISso, _ _ o°' H.I49. .P]al/Gm a9 ix e{ \ I II / II - ?,�9z ��`P w ,� ` rvzs w sm ?z W Ivea, o0T.R. x es .GG GO AG 0' ING SEE DETAIL•F•ON SHEET 4 5 Ali ecH� a]x s'sr G ;Pk 9 ��\� ry uio'aa z Ii - z0e) 3. eD In eses'1r c 2.11 LOT•5•R 'ly LOT'U• sa>s CYAN LANE �� \\ 11w,e �. ell eso Di Di w 4ii 51 IN. �4^ ` ".y\�,oa '�„� _ wlxi W Lorye w�° 9ryFH rFh+ nw qo ° a''s'`5..: �nP - - GOOD' ;,S GI 1r al LOT•c• '17� es5lel "o b� ,ssss' so as�q)zs a lPvnnres inn z Fy - °zvs ��„y 6 w l4°>r _ tG°n'As s�mlcn _ `I $,• 01 x Iii . - _ ` ". 6\ LOT°AB" L0 °AD' Q x;z,e'xt- GI N _ H qm o 1 \ /�� ,>is c Ac .NynU�� 5 x aS 011 D]-I -{ _Ali s r \ �`AS - IDaErvzsvnc0 \�``\Jh, ooTl •T• opt `k "\ 4°� )\ Gve sGODA 50 wwm a @4z� ai''a, � � I - Gzc�a I \£ - - coi TS ID 12 ~min. Ti :n: I` \'``I d - r454. ssa. `LH Lli N le-44'3i-W II 7CD 201 _GOD 1175 -- __ \`yl s/ 'Ix°vs:xrw I & " ¢mh a'F=` �9 -° GO I�.Gills,m- e' i ��I 'a _ y r o_i0 s Ci y� C° `\KEI�LOGO WAY E z,55 ell TAGes so' yy y 6 TACHEVAH A evn'sA W W1.ss' \\,A 1 n __—__ GOO J- T ` w m �OGI . __ - y� ��✓G'p 3 5 7 8 ,Gq12A GO 0. d3f D SEE DETAIL•A'2 3 _, IG • H.S.E.10B/GE-`c' 46 // J� I AT RIGHT a e o i o N y� ems{ N�':9 v.o ."V. n i :i- -®• - 211, SEE SHEET e fff '.a z 'TI o } $ Js�x �e z ` a; - se- 0 c°�DGT3 SEE SHEET 9 © ;D GRANDSVIEW STREET s /IIio o: @3 SEE SHEET 2 FOR MONUMENT NOTES, -- 4IiIl BEAgINOzD�GA 4fi 17 EASEMENT NOTES AND VICINITY MAP sev ,D, ez w<,D oG IIpj1Ml�!III D D p S, +,�. ce> °a20' eos' SEE SHEET 3 FOR ENGINEER'S NOTES 4e5 13'G sre r I'=too' DETAIL'R ' 011e AND EOUNDARV DIMENSIONS �E nor r0 sn a SEE SHEET 4 FOR DETAILS d.x. 1609 SHEET 8 OF 9 SHEETS pq IN THE CITY OF PALM SPRINGS, COUNTY OF RIVERSIDE, STATE OF CALIFORNIA TRACT MAP NO. 32233- 1 BEING A SUBDIVISION OF PARCELS 3 AND 4 OF PARCEL MAP NO. 2791Z AS SHOWN BY MAP ON FILE IN BOOK 183, PAGES 35 THROUGH 37, INCLUSIVE, OF PARCEL SEE SHEET 2 FOR MONUMENT NOTES, MAPS, RECORDS OF RIVERSIDE COUNTY, TOGETHER WITH PORTIONS OF SECTION 7 AND EASEMENT NOTES AND VICINITY MAP THE NORTH HALF OF SECTION 18. TOWNSHIP 4 SOUTH, RANGE 5 EAST, S.B.M. SEE SHEET 3 FOR ENGINEER'S NOTES IVn MSA CONSULTING, INC. DECEMBER - 2004 AND BOUNDARY DIMENSIONS LOT'AS' eo 1pj 95 ss oo ssoo nrza z=Ac (°as saAcs) SEE DETAIL•A• 'st 40 CURVE DATA AT BOTTOM _ _ ° '� tt n41 I >t o9 F P too Bsr °ec`A s U wi� r x xrzsn—_ --i dz>zrs_s9 a ° mze .;. t+.aos sF `= >.i>ts _ F ym 37 s°o x— ----- e _w. Il --_ _ u .° uc P� _ 50 w ta'us.20 ss ts.11e sF z °6 P to F°E i'as_ ��� to<>:s.00 `�> _ 37-1 w—.d v .__z�'Sn- oN m 5 ss-w m n_tw �y `o° �U2lU%s`° e ° AL WAV z c1 011x - oy N�r // ' � \\ °� N�eRJ°2.w DS�� / — m( \\ iA o t° au 5, IN @s s C4 nyr3 A O%�ox^" i t° Fue �\\a>, `-1— s:- e taso31 sF. ryey (TgA,OUS� io.w C Ns _ _<>, l - 5 1-11F e2 m=I` 5°"I — aA 33 - �� °Pl pis. a n �\\GJ�•i 2\ >>555F(J iC _ ( /S� a°b� cl[ _ j w ` W<,.\ /uys 1 uC,> a5°°' 0 _ _ GPo pts F % \m �°A'rvq /os5 /ha"' '€yam LOT.J, esm Ac m sa'1 8 s \��=;?,hm `I'�-= zt.w zzs> a t° 5F Rll °z`� LOT'k• "as \ ,.�3 28 °iz °°5.05 uo oo Fu_ LINE DATA CLUBHOUSE VIEW DRIVE �'`0O' o� of;D u t a —UG ",cm `11215I Ellezo ,-vo- LOT'AA' �52r tl� 50 m'we \ 11 _ — N >W t ut a IwFx srac9 =ami°• zP >.t rm a S 111[ x _ - 40°3— `aB t xs O / V 51'> Z a�i $0 14 6> Itss s -®- wA � ESPLANADE LANE ',N N DETAIL`Ar \ N rue O N N SCPI£ t"=50' IL J.N. 1609 DD IN THE CITY OF PALM SPRINGS, COUNTY OF RIVERSIDE, STATE OF CALIFORNIAHEET 9 OF 9 SHEETS DO FORNIA ,a m TRACT MAP NO. 32233- 1 N 0 38 BEING A SUBDIVISION OF PARCELS 3 AND 4 OF PARCEL MAP NO. 279T2, AS SHOWN W 37 BY MAP ON FILE IN BOOK 183, PAGES 35 THROUGH 37, INCLUSIVE, OF PARCEL Q u,3og sr - MAPS, RECORDS OF RIVERSIDE COUNTY. TOGETHER WITH PORTIONS OF SECTION 7 AND THE NORTH HALF OF SECTION IS, TOWNSHIP 4 SOUTH, RANGE 5 EAST. S.B.M. ALCALA WAY -' Z LOT•L•�= '° '°_ ,€" �Vny MSA CONSULTING, INC. DECEMBER - 2004 Q IPah�m°s"�`aEm we„ sr J SEE SHEET 2 FOR MONUMENT NOTES. °o J",Po4�'y�\ p al•c ° EASEMENT NOTES AND VICINITY MAP (N \ 9 <U`ad sis°s�E c SEE SHEET 3 FOR ENGINEER'S NOTES \\�da\ Y AND BOUNDARY DIMENSIONS G 32 \ °a't� /- \ sv$ LOT•AB• SCALE I" 50' 33s ,N' 0.P E „ ,zT6z6.° I°nor SP,�EI N ,v Pxe ,es ,e s` I N�Ov EZ*`�< • Fm ARC TABLE O 2GN .rl o eo us 17 6e1 AU tyro �!/fy,�/ _ y r3'�A'x nv IS •a��^, o rr dw—^hA-_ z \ � CLUBHOUSE VIEW O e `i? - _29 ea,11 Ill n Zose I. U'<� lPxrv<re a x 27S 4 -@ \\io'�n�\wzw S uG / sps - u.s5 sr _ LOT'AA' 501 " \ M A, XC9 sP _ C:0365 _ 0 a16 - _^ $p N eT,°'3l'E , OPPN P S as 60S 4C CRf °,°0 13J C0' \ w mar 23 13 8 "-SEE rAIL $}W °4 6��.sATDRIGHT•A P°z \ \\E\Al i x�z <o z \ �211 �.. W � ,o . 22E eJ3i/ !i s'< o'P0 16 m POD, 27 I 35 LOT'AA' � >aso ro.11u. i 6 (°=u, 21 SPACE) "ussazn >.,so Gas ` e iA.l sr LINE DATA < o Ix i.,s » OT. /A czs -\1 I 34 s,>>a 81 r` "esa.rz <ais.0,s k' ao5.vw s a DT.P• >.w G?;y�\,E /I� / © - _ ,r,0 P. N °ri' S ' Ej \ DETAIL'B• -1 $ '15 \ x ao scut II £CCUBryOU tca o l'�s'asi sz ry 3s s. a e fig_ DETAIL•A' VIEW OgryE 1Z.,c9 ima, scuE J.N. 1609 Resolution No. 2125-2., Page 3 TA4 TENTATIVE TRACT MAP 32233 41 ---.—,-THE PALM SPRINGS CLASSIC, ESCENA 1T,C 1000 GENE AUTRY TRAIL NORTH APIN 677-220-007 ET. SEQ., SECTION 7, 18. FINAL CONDITIONS dF APPROVAL APPROVED: NOVEMBER 17, 2004 EXPIRES: NOVEMBER 16, 2006 Before final acceptance of the project, all conditions listed below shall be completed to the satisfaction of the City Engineer, the Director of Planning, the Chief of Police, the Fire Chief or their designee, depending on which department recommended the condition. Any agreements, easements or covenants required to be entered into shall be in a form approved by the City Attorney. PLANNING: Project Specific Conditions: 1. The project is located in an area defined as having an impact on fish and wildlife as defined in Section 711.4 of the Fish and Game Code; therefore a fee of$1,314.00 plus an administrative fee of $50.00 shall be submitted by the applicant in the form of a money order or a cashier's check payable to the Riverside County Clerk prior to Council action on the project. This fee shall be submitted by the City to the County Clerk with the Notice of Determination. Action on this application shall not be final until such fee is paid. 2. The final development plans shall be submitted in accordance with Section 94.03.00 of the Zoning Ordinance. Final development plans shall include site plans, building elevations, floor plans, roof plans, landscape plans, irrigation plans, exterior lighting plans, sign program, mitigation monitoring program, site cross sections, property development standards and other such documents as required by the Planning Commission. Final development plans shall be submitted within two (2) years of the City Council approval of the preliminary planned development district. 3. The city reserves the right to review, or conditionally approve final PDD and Tentative Tract Maps. Additional conditions will be based upon the submittal and based upon the approved Planned Development application, design review and City codes and ordinances. 4. Final landscaping, irrigation, exterior lighting, and fencing plans shall be submitted for approval by the Department of Planning and Zoning prior to issuance of a building permit. Landscape plans shall be approved by the Riverside County Agricultural Commissioners Office prior to submittal. Page 1 or r Resolution No. 21252 J Page 4 Tentative Tract Map 32233 November 17, 2004 Conditions of Approval Page 2 5. Prior to issuance of a grading permits, Fringe Toed Lizard Mitigation fees shall be paid. 6. Prior to issuance of a building permit, the applicant must provide a standard avigation easement and non-suit covenant in a form prescribed and approved by the City Attorney, with reference to present and future owners of all lots and all parcels for all land uses. 7. The applicant shall submit a draft declaration of covenants, conditions and restrictions ("CC&R's") to the Director of Planning and Zoning for approval in a form to be approved by the City Attorney, to be recorded prior to submittal of a final map and approval prior to building permits. The CC&R's shall be enforceable by the City, shall not be amended without City approval, shall require maintenance of all property in a good condition and in accordance with all ordinances. 8. The applicant shall submit to the City of Palm Springs, a deposit in the amount of $2,500.00, for the review of the CC&R's by the City Attorney. 9. The CC&R's shall have a disclosure statement regarding the location of the project relative to roadways, airport noise and adjoining M-1-P zoned developed and vacant properties. Said disclosure shall inform perspective buyers about traffic, airport noise, future industrial development and other activities which may occur in this area. This is an addition to the standard avigation and easement and nonsuit covenant. 10. An exterior lighting plan in accordance with Zoning Ordinance Section 93,21.00, Outdoor Lighting Standards, shall be submitted for review and approval by the Director of Planning and Zoning prior to the issuance of building permits for each phase or development area. Manufacturer's cut sheets of all exterior lighting on the building, in the landscaping, and in the parking lot shall be submitted for approval prior to issuance of a building permit. If lights are proposed to be mounted on buildings, down-lights shall be utilized. A photometric study shall be required for all parking areas, driveways and entries. 11. This project shall be subject to Chapters 2.24 and 3.37 of the Municipal Code regarding public art. The project shall either provide public art or payment of an in lieu fee. In the case of the in-lieu fee, the fee shall be based upon the total building permit valuation as calculated pursuant to the valuation table in the Uniform Building Code, the feeing being 1/2% for commercial projects or 1/4% for residential projects with first $100,000 of total building permit valuation for individual single-family units exempt. Should the public art be located on the project site, said location shall be reviewed and approved by the Director of Planning and Zoning and the Public Arts Commission, and the property owner shall enter into a recorded agreement to maintain the art work and protect the public rights of access and viewing. 12. Pursuant to Park Fee Ordinance No. 1632 and in accordance with Government Code Section 66477 (Quimby Act), all residential development shall be required to contribute to mitigate park and recreation impacts such that, prior to issuance of residential building U '' ,6 i r Resolution No. 21252 Page 5 Tentative Tract Map 32233 November 17, 2004 Conditions of Approval Page 3 permits, a parkland fee or dedication shall be made. Accordingly, all residential development shall be subject to parkland dedication requirements and/or park improvement fees. The parkland mitigation amount shall be based upon the cost to acquire and fully improve parkland. 13. The project will bring a significant number of additional residents to the community. The City's existing public safety and recreation services, including police protection, criminal justice, fire protection and suppression, ambulance, paramedic, and other safety services and recreation, library and cultural services are near capacity. Accordingly, the City may determine to form a Community Services District under authority of Ord. C. Section 53311 et seq, or other appropriate statutory or municipal authority. Developer agrees to support the formation of such assessment district and shall waive any right of protest, provided that the amount of such assessment shall be established through appropriate study and shall not exceed $500 annually with a consumer price index escalator. The district shall be formed prior to sale of any lots or a covenant agreement shall be recorded against each parcel. 14. Prior to any ground disturbing activity, including clearing and grubbing, installation of utilities, and/or any construction related excavation, an Archaeologist qualified according to the Secretary of the Interior's Standards and Guidelines, shall be employed to survey the area for the presence of cultural resources identifiable on the ground surface. 15, A Native American Monitor shall be present during all ground-disturbing activities and that, should buried deposits be encountered, that the Monitor have the authority to halt destructive construction and that the Monitor notify a Qualified Archaeologist to investigate and, if necessary, prepare a mitigation plan for submission to the State Historic Preservation Officer and the Agua Caliente Cultural Resource Coordinator for approval. 16. One copy of any cultural resource documentation generated in connection with this project, including reports of investigations, record search results and site records/updates shall be forwarded to the Tribal Planning, Building, and Engineering Department. 17. The developer shall construct off-site sidewalk improvements on the south side of Vista Chino between Via Roberto Miguel and Gene Autry Trail. The sidewalk shall be constructed at a time when the Planning Commission determines it is appropriate, based upon residential demand. Factors to be considered are to include number of dwelling units proposed for development and proximity of said units to the intersection of Vista Chino and Gene Autry Trail. 18, Construct Bus Shelters consistent with the Sunline Transit Agency that are custom designed in keeping with the character of the project. The custom bus shelters shall not have any advertising and shall be maintained by the project unless a separate maintenance agreement with the developer and Sunline Transit Agency is entered into for Sunline Transit Agency to provide maintenance. Conditions ofApproval Page 4 19. Construct equestrian trail and bikeway along the Whitewater Wash as identified in the General Plan. The final alignment shall be coordinated with CVWD, RCFCWCD, and the City as part of the Final Planned Development District. 20. As a part of the Final Development District, a Wildlife Management Plan will be submitted for approval to the Airport Authority and the Director of Planning and Zoning. 21. Applicant shall provide a revised project description and design standards within thirty (30) days of City Council approval 22. All existing and proposed overhead utility lines that are less than 35 kV on/or adjacent to this project shall be undergrounded. The location and size of the existing overhead facilities shall be provided to the Engineering Department along with written confirmation from the involved utility companies that the required deposit to underground the facilities has been paid prior to issuance of a grading permit. All undergrounding of utilities shall be completed prior to issuance of certificate of occupancy. 23. All residential development shall be subject to parkland dedication requirements and/or park improvement fees. The dedication, payment of fees or combination thereof shall be required prior to issuance of building permits. Parkland mitigation amounts shall be based upon the costs to acquire and fully improve parkland and shall be adopted by ordinance or resolution. 24. The Mitigation Monitoring Program from Case No 5.0666-B, The Palm Springs Classic, shall be incorporated into these Conditions of Approval by Reference. General Conditions: 25. The proposed development of the premises shall conform to all applicable regulations of the Palm Springs Zoning Ordinance, Municipal Code, or any other City Codes, ordinances and resolutions which supplement the zoning district regulations, except as specifically modified in this approval. 26. The owner shall defend, indemnify, and hold harmless the City of Palm Springs, its agents, officers, and employees from any claim, action, or proceeding against the City of Palm Springs or its agents, officers or employees to attach, set aside, void or annul, an approval of the City of Palm Springs, its legislative body, advisory agencies, or administrative officers concerning Case 5.0666 - B- PD-231. The City of Palm Springs will promptly notify the applicant of any such claim, action, or proceeding against the City of Palm Springs and the applicant will either undertake defense of the matter and pay the City's associated legal costs or will advance funds to pay for defense of the matter by the City Attorney. If the City of Palm Springs fails to promptly notify the applicant of any such claim, action or proceeding or fails to cooperate fully in the defense, the applicant shall not, I,I)dIt November 17, 2004 Conditions of Approval Page 5 thereafter, be responsible to defend, indemnify, or hold harmless the City of Palm Springs. Notwithstanding the foregoing, the City retains the right to settle or abandon the matter without the applicant's consent but should it do so, the City shall waive the indemnification herein, except, the City's decision to settle or abandon a matter following an adverse judgement or failure to appeal, shall not cause a waiver of the indemnification rights herein. 27. That the property owner(s) and successors and assignees in interest shall maintain and repair the improvements including and without limitation sidewalks, bikeways, parking areas, landscape, irrigation, lighting, signs, walls, and fences between the curb and property line, including sidewalk or bikeway easement areas that extend onto private property, in a first class condition, free from waste and debris, and in accordance with all applicable law, rules, ordinances and regulations of all federal, state, and local bodies and agencies having jurisdiction at the property owner's sole expense. This condition shall be included in the recorded covenant agreement for the property if required by the City. 28. Prior to issuance of a grading permit, a Fugitive Dust and Erosion Control Plan shall be submitted and approved by the Building Official. Refer to Chapter 8.50 of the Municipal Code for specific requirements. 29. The grading plan shall show the disposition of all cut and fill materials. Limits of site disturbance shall be shown and all disturbed areas shall be fully restored or landscaped. 30. Drainage swales shall be provided adjacent to all curbs and sidewalks - 3' wide and 6" deep. The irrigation system shall be field tested prior to final approval of the project. Section 14.24.020 of the Municipal Code prohibits nuisance water from entering the public streets, roadways or gutters. 31. All proposed trees within the public right-of-way and within 10 feet of the public sidewalk and/or curb shall have City approved deep root barriers installed per City of Palm Springs Engineering specifications. POLICE DEPARTMENT: 32, Developer shall comply with Section 11 of Chapter 8.04 of the Palm Springs Municipal Code. WASTE DISPOSAL SERVICES: 33. The location of the trash enclosure is acceptable subject to approved construction details approved by the Director of Building and Safety consistent with approved City details. BUILDING DEPARTMENT: 34. Prior to any construction on-site, all appropriate permits must be secured. i r Resolution No. 21252 Page 8 Tentative Tract Map 32233 November 17, 2004 Conditions of Approval Page 6 FIRE: 35, Fire Department Access: A secondary Fire Department access road shall be provided and maintained in the Southern portion of TTM 32558 on the Cathedral City side. 36. Turn-Around Requirements: Dead-end fire apparatus access roads in excess of 150 feet in length shall be provided with approved provisions for the turning around of fire apparatus. The City of Palm Springs approved turn around provision is a cul-de-sac with an outside turning radius of 43 feet from centerline. (902.2.2.4 CFC). On the existing plan these need to be addressed at Lot 6 on TTM 32557, on Street K, which is shown on Sheet 1 of TTM 32233. Also on Streets W and Y which are shown on Sheet 2 of the same TTM. On Sheet 3, Street HH is also excessive in length. 37. Turning Radius: Inside turning radii for roundabouts needs to be a minimum of 30 feet. Any medians or islands need to be size accordingly. The turning radius for Lot 414 on Sheet 3 appears to be undersized. Please show dimensions upon re-submittal. 38. Water Systems and Hydrants: Underground water mains and fire hydrants shall be installed, completed, tested and in service prior to the time when combustible materials are delivered to the construction site. (903 CFC). Prior to final approval of the installation, contractor shall submit a completed Contractor's Material and Test Certificate to the Fire Department. (9-2.1 NFPA 24) 39. Residential fire hydrants: Residential fire hydrants shall be installed in accordance with DWA specifications and standards. No landscape planting, walls, or fencing are permitted within 3 feet of fire hydrants, except groundcover plantings. 40. Site Plan: Provide the fire department with two copies of an approved site plan. Approved locations for fire hydrants will be marked on this site plan, with one copy being returned to the applicant. The second copy will be retained by the fire department. 41. Access During Construction: Access for fire fighting equipment shall be provided to the immediate job site at the start of construction and maintained until all construction is complete. Fire apparatus access roads shall have an unobstructed width of not less than 20 feet and an unobstructed vertical clearance of not less than 13'6". Fire department access roads shall have an all weather driving surface and support a minimum weight of 73,000 lbs. (Sec. 902 CFC) 42. Relocate the well site away from the Vista Chino entry. ENGINEERING: STREETS Resolution No. 21252 Pa e 9 Tentative Tract Map 32233 November 17, 2004 Conditions of Approval Page 7 1. Any improvements within the public right-of-way require a City of Palm Springs Encroachment Permit. 2. Developer shall obtain State permits and approval of plans for all work done on State Highway 111 (Gene Autry Trail). A copy of Caltrans requirements shall be submitted to the City Engineer prior to the issuance of any grading or building permits. 3. Submit street improvement plans prepared by a Registered Civil Engineer to the Engineering Division. The plan(s) shall be approved by the City Engineer prior to issuance of any grading or building permits. STATE HIGHWAY 111 (GENE AUTRY TRAIL) 4. Dedicate additional right-of-way to provide the ultimate half street width of 55 feet along the entire frontage, together with a property line - corner cut-back at the southeast corner of Gene Autry Trail and Vista Chino in accordance with City of Palm Springs Standard Drawing No. 105, unless otherwise already dedicated by Parcel Map 30928. 5. Dedicate additional right-of-way with a right-of-way line concentric with the back of sidewalk adjacent to the proposed bus turn-out, unless otherwise already dedicated by Parcel Map 30928. 6. Dedicate an easement for sidewalk and bicycle path purposes along the entire frontage for the portions of the bicycle path that leave the public right-of-way, unless otherwise already dedicated by Parcel Map 30928. 7. Abutters rights of access to Gene Autry Trail shall be dedicated to the City of Palm Springs except at specifically approved locations. 8. Remove the existing curb and gutter as necessary to construct a 180 feet long by 12 feet wide bus turn-out, with adjacent 12 feet wide, colored concrete sidewalk, at the northeast corner of Gene Autry Trail and Classic Drive in a location to be agreed upon by the City and Sunline Transit Agency. Construction of a bus stop shelter shall be required, with a design compatible to project architecture as approved by Sunline Transit Agency and the Director of Planning Services. Bus stop furniture and other accessories, as required by Sunline Transit Agency, shall be provided by the developer. This condition shall be null and void if completed by others prior to approval of a final map within Tentative Tract Map 32233. 9. Construct a 12 feet wide Class I meandering bicycle path (Caltrans Design Manual, Chapter 1000 - Bikeway Planning and Design) along the entire frontage. The bicycle path shall be constructed of colored Portland cement concrete. The admixture shall be Desert Sand, Palm Springs Tan, or approved equal color by the Engineering Division. This condition shall be null and void if completed by others prior to approval of a final map within Tentative Tract Map 32233. Resolution No. 21252 Page 10 Tentative Tract Map 32233 November 17, 2004 Conditions of Approval Page 8 10. Modify the existing left-turn lane to provide a 150 feet long southbound left-turn storage lane at Gene Autry Trail and Chia Road, or as may be modified by the Traffic Report and approved by the City Engineer. Existing median improvements, including landscaping, lighting and irrigation, shall be modified to the satisfaction of the City Engineer. This condition shall be null and void if completed by others prior to approval of a final map within Tentative Tract Map 32233. 11. Modify the existing left-turn lane to provide a 400 feet long southbound left-turn storage lane at Gene Autry Trail and Tachevah Drive, or as may be modified by the Traffic Report and approved by the City Engineer. Existing median improvements, including landscaping, lighting and irrigation, shall be modified to the satisfaction of the City Engineer. This condition shall be null and void if completed by others prior to approval of a final map within Tentative Tract Map 32233. 12. Coordinate the location of the intersection of Gene Autry Trail and Classic Drive with the City Engineer and the Executive Director of the Airport. Upon approval of the intersection location, relocate the existing northbound left-turn lane location as required to access the airport commercial properties, and provide a 375 feet long southbound left-turn storage lane at Gene Autry Trail and Classic Drive, or as may be modified by the Traffic Report and approved by the City Engineer. Existing intersection improvements, median improvements, including landscaping, lighting and irrigation, shall be removed, reconstructed or modified to the satisfaction of the City Engineer. Modification and reconstruction of the existing parking lot and driveways at the airport necessary to facilitate the relocated intersection shall be completed to the satisfaction of the City Engineer and the Executive Director of the Airport. This condition shall be null and void if completed by others prior to approval of a final map within Tentative Tract Map 32233. VISTA CHINO 13. Dedicate an easement for sidewalk and bicycle path purposes along the entire frontage for the portions of the bicycle path that leave the public right-of-way, unless otherwise already dedicated by Parcel Map 30928. 14. Dedicate additional right-of-way with a right-of-way line concentric with the back of sidewalk adjacent to the proposed bus turn-out, unless otherwise already dedicated by Parcel Map 30928, 15. Abutters rights of access to Vista Chino shall be dedicated to the City of Palm Springs except at specifically approved locations. 16. Remove the existing curb and gutter as necessary to construct a 180 feet long by 12 feet wide bus turn-out, with adjacent 12 feet wide, colored concrete sidewalk, at the southeast corner of Vista Chino and Gene Autry Trail in a location to be agreed upon by the City and Sunline Trandit Agency. Construction of a bus stop shelter shall be required, with a design compatible to project architecture as approved by Sunline Transit Agency and the Director of Planning Services. Bus i r Resolution No. 21252 Page 11 Tentative Tract Map 32233 November 17, 2004 Conditions of Approval Page 9 stop furniture and other accessories shall be furnished, as required by Sunline Transit Agency. This condition shall be null and void if completed by others prior to approval of a final map within Tentative Tract Map 32233. 17. Construct a 12 feet wide Class I meandering bicycle path (Caltrans Design Manual, Chapter 1000 - Bikeway Planning and Design) along the entire frontage. The bicycle path shall be constructed of colored Portland cement concrete. The admixture shall be Desert Sand, Palm Springs Tan, or approved equal color by the Engineering Division. This condition shall be null and void if completed by others prior to approval of a final map within Tentative Tract Map 32233. 18. Construct a 14-feet wide landscaped, raised median island as specified by the City Engineer from Gene Autry Trail to the easterly property line (approximate with the existing Whitewater Channel levee). Provide a 225 feet long westbound left-turn storage lane at Vista Chino and Gene Autry Trail. Easterly of the Whitewater Channel levee, provide a striped median with a minimum 150 feet long westbound left-turn lane at Vista Chino and North Drive. Left-turn pocket storage lengths and transitions shall be designed in accordance with the current Caltrans Highway Design Manual. Additional paving and street widening along the north side of Vista Chino shall be provided as necessary to construct the required median improvements. This condition shall be null and void if completed by others prior to approval of a final map within Tentative Tract Map 32233. SAN JOAQUIN DRIVE 19, Dedicate additional right-of-way at the northerly end of San Joaquin Drive to provide an off-set cul-de-sac or turn-around, or as otherwise approved by the Fire Marshall and City Engineer. The cul-de-sac shall have a minimum curb radius of 58 feet, as required by the City of Cathedral City, or as otherwise approved by the Fire Marshall and City Engineer. This condition shall be null and void if completed by others prior to approval of a final map within Tentative Tract Map 32233. 20. Construct a 6 inch curb and gutter, 18 feet west of centerline along the entire frontage and throughout the off-set cul-de-sac or turn-around, as approved by the Fire Marshall and City Engineer, in accordance with City of Palm Springs Standard Drawing No. 200. This condition shall be null and void if completed by others prior to approval of a final map within Tentative Tract Map 32233, 21. Construct a 20 feet wide driveway approach in accordance with City of Palm Springs Standard Drawing No. 201 within the cul-de-sac at the northerly end of San Joaquin Drive for service and emergency vehicle access into the development as required by the City Engineer and/or Fire Marshall. 22. Construct a 6 inch thick concrete driveway from the driveway approach within the cul-de-sac at the northerly end of San Joaquin Drive across Lot 552 as necessary to provide access from San Joaquin Drive to the on-site street system as required by the City Engineer and/or Fire Marshall. 011 �14 r Resolution No. 21252 Page 12 Tentative Tract Map 32233 November 17, 2004 Conditions of Approval Page 10 An alternative to concrete pavement may be approved, subject to review and approval by the Fire Marshall. 23. Construct a minimum pavement section of 2'/ inch asphalt concrete pavement over 4 inch aggregate base with a minimum subgrade of 24 inches at 95% relative compaction, or equal, from clean sawcut edge of pavement to edge of proposed gutter along the entire frontage in accordance with City of Palm Springs Standard Drawing No. 110 and 300. If an alternative pavement section is proposed, the proposed pavement section shall be designed by a California registered Geotechnical Engineer using "R" values from the project site and submitted to the City Engineer for approval. This condition shall be null and void if completed by others prior to approval of a final map within Tentative Tract Map 32233. ON-SITE STREETS 24. Dedicate an easement extending from back of curb to back of curb to the City of Palm Springs for public utility and sewer purposes, and for service and emergency vehicles and personnel ingress and egress, over the private streets. 25. Dedicate an easement, 20 feet wide, for service and emergency vehicles and personnel ingress and egress, over Lot 552 as necessary to provide access from San Joaquin Drive to the on-site street system. 26. Construct a wedge curb, acceptable to the City Engineer, 18 feet on both sides of centerline along the entire frontages, and throughout the cul-de-sacs. 27. Construct a wedge curb, acceptable to the City Engineer, 14 feet on both sides of centerline along the entire frontages of those on-site streets identified as Streets "00" (adjacent to Lots 292-294 [north end] and adjacent to Lots 305 and 306 [south end]), "PP" (adjacent to Lots 224 and 225 [north end] and adjacent to Lots 252 and 253 [south end]), "SS' (adjacent to Lots 211 and 212 [west end], and "W". Parking shall be restricted along one sides of these streets, as necessary to maintain a 20 feet wide clear access way. Regulatory Type R26 "No Parking" signs or red curb shall be installed on one side of these streets to prohibit on-street parking. A Home Owners Association shall be responsible for regulating and maintaining required no parking restrictions, which shall be included in Codes, Covenants and Restrictions required for the development. 28. All on-site cul-de-sacs shall be constructed in accordance with City of Palm Springs Standard Drawing No. 101. A minimum 43 feet inside radius shall be required for all on-site cul-de-sacs. 29. All on-site "knuckles" shall be constructed in accordance with City of Palm Springs Standard Drawing No. 104. 30. On-site streets without a cul-de-sac or other approved turn-around shall not extend a distance of 150 feet or more from the intersecting street. On-site streets with a length exceeding 150 feet shall provide a hammerhead turn-around or other access as approved by the Fire Marshall. I Resolution No. 21252 I p��a I ernfative Tract Map 32233 November 17, 2004 Conditions of Approval Page 11 31. Construct a minimum pavement section of 2% inch asphalt concrete pavement over 4 inch crushed miscellaneous base with a minimum subgrade of 24 inches at 95% relative compaction, or equal. If an alternative pavement section is proposed, the proposed pavement section shall be designed by a California registered Geotechnical Engineer using "R" values from the project site and submitted to the City Engineer for approval. SANITARY SEWER 32. All sanitary facilities shall be connected to ,the public sewer system. New laterals shall not be connected at manholes. 33. Submit sewer improvement plans prepared by a Registered Civil Engineer to the Engineering Division. The plans shall be approved by the City Engineer prior to issuance of any grading or building permits. 34. Construct an 8 inch sewer main within Mission Drive and San Joaquin Drive as necessary to extend public sewer service to the development. 35. Construct an 8 inch sewer main within all on-site streets and connect to the existing public sewer system in Gene Autry Trail and/or San Joaquin Drive. All sewer mains constructed by the developer and to become part of the public sewer system shall be televised prior to acceptance of the sewer system for maintenance by the City. 36. Payment of applicable sewer assessment or sewer surcharge fees (if any) shall be paid prior to issuance of building permits. GRADING 37. Submit a Grading Plan prepared by a California registered Civil Engineer to the Engineering Division for review and approval. The Grading Plan shall be approved by the City Engineer prior to issuance of a grading permit. A Fugitive Dust Control Plan shall be prepared by the applicant and/or its grading contractor and submitted to the Engineering Division for review and approval. The applicant and/or its grading contractor shall be required to comply with Chapter 8.50 of the City of Palm Springs Municipal Code, and shall be required to utilize one or more "Coachella Valley Best Available Control Measures" as identified in the Coachella Valley Fugitive Dust Control Handbook for each fugitive dust source such that the applicable performance standards are met. The applicant's or its contractor's Fugitive Dust Control Plan shall be prepared by staff that has completed the South Coast Air Quality Management District (AQMD) Coachella Valley Fugitive Dust Control Class. The applicant and/or its grading contractor shall provide the Engineering Division with current and valid Certificate(s) of Completion from AQMD for staff that have completed the required training. For information on attending a Fugitive Dust Control Class and ups& y Resolution No. 21252 Page 14 Tentative Tract Map 32233 November 17, 2004 I Conditions of Approval I Page 12 information on the Coachella Valley Fugitive Dust Control Handbook and related "PM10" Dust Control issues, please contact Elio Torrealba at AQMD at (909) 396-3752, or at etorrealba@AQMD.gov. A Fugitive Dust Control Plan, in conformance with the Coachella Valley Fugitive Dust Control Handbook, shall be submitted to and approved by the Engineering Division prior to approval of the Grading plan. The first submittal of the Grading Plan shall include the following information: a copy of a final approved conformed copy of Conditions of Approval; a copy of a final approved conformed copy of the Site Plan; a copy of current Title Report; a copy of Soils Report; and a copy of the associated Hydrology Study/Report. DRAINAGE 38. All stormwater runoff passing through and falling onto the site shall be accepted and conveyed through the property, consistent with an approved hydrology/hydraulic study. 39. Drainage easements shall be reserved on the Final Map where and as required to convey off- site stormwater runoff across the property, in accordance with an approved hydrology/hydraulic study. On-site drainage easements shall be privately maintained by a Homeowners Association, 40. The project is subject to flood control and drainage implementation fees and/or construction of drainage facilities in accordance with the approved Master Drainage Plan for the Palm Springs Area. Validated costs incurred for the design and construction of storm drainage improvements adjacent to or within the project as shown in the Master Drainage Plan may be credited toward the drainage fee otherwise due. Coordination with Riverside County Flood Control & Water Conservation District (RCFC) shall be required to determine acceptable methods of providing storm drainage improvements consistent with the Master Drainage Plan. Credit for or deletion of required drainage implementation fees will require review and approval by RCFC of proposed storm drainage systems, detention and retention basins, and storm drain outlet systems into the Whitewater Channel. If required as a condition of credit for or deletion of storm drainage implementation fees, a cooperative agreement between the property owner(s), the City of Palm Springs and RCFC shall be made whereby storm drainage easements for Master Drainage Plan facilities are provided to RCFC within the project, and storm drainage improvements are designed and constructed to the satisfaction of the City Engineer and RCFC. MAP 41. A Final Map shall be prepared by a California registered Land Surveyor or qualified Civil Engineer and submitted to the Engineering Division for review and approval. A Title Report prepared for subdivision guarantee for the subject property, the traverse closures for the existing parcel and all lots created therefrom, and copies of record documents shall be submitted with the Final Map to the Engineering Division as part of the review of the Map. The Final Map shall be approved by the City Council prior to issuance of building permits. 42. In accordance with Section 66434 (g) of the Government Code, the westerly 15 feet of public Ui .'G Resolution No. 21252 Page 15 Tentative Tract Map 32233 November 17, 2004 Conditions of Approval Page 13 right-of-way for San Joaquin Drive may be abandoned upon the filing of a Final Map identifying the abandonment of the right-of-way granted to the City of Palm Springs. Prior to approval of a Final Map, the developer shall coordinate with each public utility company and determine specific requirements as to the abandonment and/or relocation of existing underground utilities that may exist within the portion of the public right-of-way to be abandoned. Prior to approval of a Final Map, the developer shall provide to the City Engineer a letter of approval regarding the proposed abandonment of the westerly 15 feet of San Joaquin Drive right-of-way from each public utility agency. 43. In accordance with Government Code Section 66493 (f), an application for reapportionment of the existing assessments related to Assessment District 155 levied against the properties shall be performed at the expense of the property owner, or the existing assessments shall be paid in full, prior to City Council approval of the Final Map. TRAFFIC 44. The total number of 1,450 single family and multi-family units, and 450 room resort hotel allowed within the development, as originally approved by Planned Development Unit (PD) 231, shall be decreased by the total number of additional residential units approved by the City of Cathedral City associated with Tentative Tract Maps 32557 and 32558 such that the overall total number of units, and the traffic generated therefrom, does not increase from the original total of units analyzed for the purposes of approval of PD 231. 45. The developer shall coordinate and prepare a traffic signal installation phasing plan. In accordance with developer proposed on-site phasing of residential construction, the installation of required traffic signals shall be phased as traffic signal warrants are met. Irregardless of a traffic signal installation phasing plan, any traffic signal shall be installed at any time and upon notice by the City Engineer that traffic conditions warrant installation, or the City's own analysis indicates warrants exist for its installation. The design of all required traffic signals shall be completed prior to approval of a final map. The developer is responsible for the installation of a traffic signal, subject to the approval of Caltrans and/or the City Engineer, as required, at the following locations: A. Gene Autry Trail and Chia Road B. Gene Autry Trail and Classic Drive C. Vista Chino and North Drive 46, In coordination with the design and installation of traffic signals along Gene Autry Trail, a traffic signal interconnect system, subject to the approval of Caltrans and/or the City Engineer, shall be provided on Gene Autry Trail from Vista Chino to Ramon Road. In conjunction with the design of required traffic signals, a traffic signal interconnect system shall be designed from Vista Chino to Ramon Road, as directed by the City Engineer and approved by Caltrans. Reimbursement for 65.86% of the cost of the design and installation of the traffic signal interconnect system may be made through a reimbursement agreement between the City, Caltrans (if required) and the applicant. O" "0 Conditions of Approval Page 14 47. Based on the Traffic Impact Study prepared by Endo Engineering, dated March 2003, the following mitigation measures shall be addressed prior to issuance of a building permit on any of the proposed parcels: A. Pay the proportionate fair share contribution of $22,425 (14.95%) of a traffic signal at Gene Autry Trail and Via Escuela. B. Pay the proportionate fair share contribution of$18,140 (18.14%) of the cost to construct a northbound right-turn lane on Farrell Drive at Vista Chino. C. Pay the proportionate fair share contribution of 18.14% of the cost to construct a southbound left-turn lane on Farrell Drive at Vista Chino. An engineer's estimate of the cost to construct the required improvement shall be provided to the City Engineer for review and approval. D. Pay the proportionate fair share contribution of 4.9% of the cost to construct a southbound left-turn lane on Farrell Drive at Ramon Road. An engineer's estimate of the cost to construct the required improvement shall be provided to the City Engineer for review and approval. E. Pay the proportionate fair share contribution of 6.61% of the cost to construct a southbound through lane on Cathedral Canyon Drive at Ramon Road. The fair share contribution shall be held in trust for the City of Cathedral City until such time as the intersection improvements are constructed. An engineer's estimate of the cost to construct the required improvement shall be provided to the City Engineer for review and approval. 48. Submit traffic striping plans for improvements to Vista Chino prepared by a California registered Civil Engineer to the Engineering Division for review and approval. All required traffic striping improvements shall be completed in conjunction with required street improvements, to the satisfaction of the City Engineer. 49. Construction signing, lighting and barricading shall be provided for on all projects as required by City Standards or as directed by the City Engineer. As a minimum, all construction signing, lighting and barricading shall be in accordance with State of California, Department of Transportation, "Manual of Traffic Controls for Construction and Maintenance Work Zones" dated 1996, or subsequent additions in force at the time of construction. 50. This property is subject to the Transportation Uniform Mitigation Fee which shall be paid prior to issuance of building permits. RESOLUTION NO. 21252 A RESOLUTION OF THE CITY COUNCIL OF THE CITY OF PALM SPRINGS, CALIFORNIA, APPROVING FINAL MAP 32233-1 FOR PROPERTY LOCATED ALONG THE EAST SIDE OF GENE AUTRY TRAIL, SOUTH OF VISTA CHINO, IN SECTIONS 7 AND 18, TOWNSHIP 4 SOUTH, RANGE 5 EAST, AND APPROVING A SUBDIVISION IMPROVEMENT AGREEMENT WITH PALM SPRINGS CLASSIC, LLC, A DELAWARE LIMITED LIABILITY COMPANY A05086 WHEREAS, the Planning Commission, at its meeting of October 13, 2004, recommended approval of Tentative Tract Map 32233, prepared by MSA Consulting, Inc., representing Palm Springs Classic, LLC, a Delaware Limited Liability Company, for the above described property; and WHEREAS, the City Council at its meeting of November 17, 2004, approved Tentative Tract Map 32233 subject to conditions; and WHEREAS, the owner offers for dedication to the City of Palm Springs Lots "A" through "E", inclusive, for street, public utility and sewer purposes; easements for public utility and sewer purposes shown as "10' PUE", along and adjacent to all private streets; easements for public utility and sewer purposes, together with the right of ingress and egress for service and emergency vehicles and personnel, over Lots "F" through "O", inclusive; a 20 feet wide easement for emergency ingress and egress purposes across a portion of Lot "AC"; easements for public utility and sewer purposes over Lots "P" through "Y", inclusive; easements for sidewalk and pedestrian purposes over portions of Lots 44, 46, 47, 49, 50, 51, "S", and Lot "AA'; and Lot "Al"' in fee title. NOW THEREFORE BE IT RESOLVED by the City Council of the City of Palm Springs as follows: 1. That Final Map 32233-1 is in substantial conformance with approved Tentative Tract Map 32233; and 2. That requisite conditions associated with Tentative Tract Map 32233 have been satisfied; and 3. That Final Map 32233-1 is in conformance with the General Plan; and 4. That Final Map 32233-1 conforms to all requirements of the Subdivision Map Act of the State of California; and 5. That the offers of dedication to the public on Final Map 32233-1 shall be accepted by the City Clerk of the City of Palm Springs; and 6. That the City Manager is hereby authorized to enter into a Subdivision Improvement Agreement with the subdivider and to accept subdivision improvement security in conformance with the requirements therein for construction of required public improvements; and Resolution No. 21252 Page 2 7. That the City Clerk shall cause to have recorded with the Riverside County Recorder the Subdivision Improvement Agreement; and 8. That Final Map 32233-1 is hereby approved for purposes therein defined. ADOPTED THIS 4th day of May, 2005. I i I David H. Ready, City Manager ATTEST: James Thompson, City Clerk CERTIFICATION STATE OF CALIFORNIA ) COUNTY OF RIVERSIDE ) ss. CITY OF PALM SPRINGS ) I, JAMES THOMPSON, City Clerk of the City of Palm Springs, hereby certify that Resolution No. 21252 is a full, true and correct copy, and was duly adopted at a regular meeting of the City Council of the City of Palm Springs on May 4, 2005, by the following vote: AYES: Members Foat, Mills, McCulloch, Pougnet and Mayor Oden NOES: None ABSENT: None ABSTAIN: None James Thompson, City Clerk City of Palm Springs, California