Loading...
HomeMy WebLinkAbout2006-04-12 STAFF REPORTS 2C Ok PALM SAP v v, t OggO11AT10 ciL✓PORN� City Council Staff Report DATE: April 12, 2006 CONSENTAGENDA SUBJECT: APPROVING AN AGREEMENT WITH LSA ASSOCIATES, INC. FOR "FOCUSED ENTITLEMENT AND EIR" PLANNING SERVICES FOR THE BMW OF PALM SPRINGS' PROJECTS 3.2871 AND 5.1101, THE PROPOSED VACATION OF AN EXISTING FRONTAGE ROAD ALONG EAST PALM CANYON DRIVE ENDING AT CHEROKEE WAY AND FOR A PRIVATE FRONTAGE ROAD THAT WILL ACCESS A NEW 73,361 SQ.FT. AUTOMOTIVE AND SERVICE FACILITY TO BE BUILT ON AN 8.78 ACRE VACANT LOT AT 3919 EAST PALM CANYON DRIVE, IN THE CITY OF PALM SPRINGS. FROM: David H. Ready, City Manager BY: Thomas J. Wilson, Assistant City Manager— Development Services SUMMARY Staff is requesting that the Council approve an Agreement with LSA Associates, Inc. to provide to the City's Planning Department "Focused Entitlement and EIR" Planning Services for the BMW of Palm Springs' Projects 3.2871 and 5.1101, the proposed vacation of an existing frontage road along East Palm Canyon Drive ending at Cherokee Way and for a private frontage road that will access a new 73,361 sq.ft. automotive sales and service facility to be built on an 8.78 acre vacant lot, not exceed $27,000.00, which will be paid to the City by BMW of Palm Springs. RECOMMENDATION: 1) Adopt Minute Order No. approving an Agreement with LSA Associates, Inc. for"Focused Entitlement and EIR" Planning Services for the BMW of Palm Springs' Projects that will not exceed $27,000.00. 2) Authorize the City Manager to execute all necessary documents in a form acceptable to the City Attorney. Item No. 2 . n . STAFF ANALYSIS: Partners Land Development and VIP Motors have filled applications in behalf of BMW of Palm Springs requesting the vacation of an existing frontage road along East Palm Canyon Drive ending at Cherokee Way and for a private frontage road that will access a new 73,361 sq.ft. automotive sales and service facility on an 8.78 acre vacant lot at 3919 East Palm Canyon Drive, in the City of Palm Springs. The City has received a proposal from LSA Associates, Inc. (copy attached) to provide these services for BMW of Palm Springs Project 3.2871 and 5.1101 not to exceed $27,000.00. Staff is recommending that LSA Associates, Inc. be retained to provide for the City's Planning Department the "Focused Entitlement and EIR" Planning services for this project. /v FISCAL IMPACT: Finance Director Review.`",`,- 'There is no fiscal impact to the City as the applicant has agreed to reimburse the City for all costs involved in this project. r rai w g IDir r of Plan 6erSrvices (e Thomas J. Wil n, Assistant City Manager— Development ervices David H. Ready, City Managr6r Attachments: 1. Minute Order 2. LSA Associates, Inc. Contract Proposal Page 2 of 2 MINUTE ORDER NO. APPROVING AN AGREEMENT WITH LSA ASSOCIATES, INC. FOR "FOCUSED ENTITLE- MENT AND EIR" PLANNING SERVICES FOR THE BMW OF PALM SPRINGS' PROJECTS 3.2871 AND 5.1101, THE PROPOSED VACATION OF AN EXISTING FRONTAGE ROAD ALONG EAST PALM CANYON DRIVE ENDING AT CHEROKEE WAY AND FOR A PRIVATE FRONTAGE ROAD THAT WILL ACCESS A NEW 73,361 SQUARE FOOT AUTOMOTIVE SALES AND SERVICE FACILITY ON AN 8.78 ACRE VACANT LOT AT 3919 EAST PALM CANYON DRIVE, IN THE CITY OF PALM SPRINGS. I HEREBY CERTIFY that this Minute Order, approving an Agreement with LSA ASSOCIATES, INC. Inc. for "Focused Entitlement and EIR" Planning Services for the BMW OF Palm Springs' Projects 3.2871 and 5.1101, not to exceed $27,000.00, was adopted by the City Council of the City of Palm Springs, California, in a meeting which was held on the day of April, 2006. JAMES THOMPSON City Clerk CITY OF PALM SPRINGS CONTRACT SERVICES AGREEMENT FOR: Focused Entitlement and EIR Services for BMW of Palm Springs, Projects No. 3.2871 & 5.1101 GPA THIS CONTRACT SERVICES AGREEMENT (herein "Agreement"), is made and entered into this , 2006, by and between the CITY OF PALM SPRINGS, a municipal corporation,(herein"City")and LSA ASSOCIATES, INC.(herein"Contractor"). (The term Contractor includes professionals performing in a consulting capacity.) The parties hereto agree as follows: 1.0 SERVICES OF CONTRACTOR 1.1 Scope of Services. In compliance with all terms and conditions of this Agreement, the Contractor shall provide those services specified in the "Scope of Services" attached hereto as Exhibit "A" and incorporated herein by this reference, which services may be referred to herein as the "services" or "work" hereunder. As a material inducement to the City entering into this Agreement, Contractor represents and warrants that Contractor is a provider of first lass work and services and Contractor is experienced in performing the work and services contemplated herein and, in light of such status and experience, Contractor covenants that it shall follow the highest professional standards in performing the work and services required hereunder and that all materials will be of good quality, fit for the purpose intended. For purposes of this Agreement, the phrase "highest professional standards" shall mean those standards of practice recognized by one or more first-class firms performing similar work under similar circumstances. 1.2 Contractor's Proposal. The Scope of Service shall include the Contractor's proposal or bid which shall be incorporated herein by this reference as though fully set forth herein. In the event of any inconsistency between the terms of such proposal and this Agreement,the terms of this Agreement shall govern. 1.3 Compliance with Law. All services rendered hereunder shall be provided in accordance with all ordinances, resolutions, statutes, rules, and regulations of the City and any Federal, State or local governmental agency having jurisdiction in effect at the time service is rendered. 1.4 Licenses, Permits. Fees and Assessments. Contractor shall obtain at its sole cost and expense such licenses, permits and approvals as may be required by law for the performance of the services required by this Agreement. Contractor shall have the sole obligation to pay for any fees, assessments, and taxes, plus applicable penalties and interest, which may be imposed by law and arise from or are necessary for the Contractor's performance of the services required by this Agreement, and shall indemnify, defend and hold harmless City against any such fees, assessments,taxes penalties or interest levied,assessed or imposed against City hereunder. 1.5 Familiarity with Work. By executing this Contract, Contractor warrants that Contractor(a) has thoroughly investigated and considered the scope of services to be performed, (b) has carefully considered how the services should be performed, and (c)fully understands the facilities, difficulties and restrictions attending performance of the services underthis Agreement. If the services involve work upon any site, Contractor warrants that Contractor has or will investigate the site and is or will be fully acquainted with the conditions there existing, prior to commencement of services hereunder. Should the Contractor discover any latent or unknown conditions,which will materially affect the performance of the services hereunder, Contractor shall immediately inform the City of such fact and shall not proceed except at Contractors risk until written instructions are received from the Contract Officer. 3.2871 /5.1101 BMW of Palm Springs—LSA Associates Contract 1 of 22 1.6 Care of Work. The Contractor shall adopt reasonable methods during the life of the Agreement to furnish continuous protection to the work, and the equipment, materials, papers, documents, plans,studies and/orother components thereof to prevent losses or damages,and shall be responsible for all such damages, to persons or property, until acceptance of the work by City, except such losses or damages as may be caused by City's own negligence. 1.7 Further Responsibilities of Parties. Both parties agree to use reasonable care and diligence to perform their respective obligations under this Agreement. Both parties agree to act in good faith to execute all instruments, prepare all documents and take all actions as may be reasonably necessary to carry out the purposes of this Agreement. Unless hereafter specified, neither party shall be responsible for the service of the other. 1.8 Additional Services. City shall have the right at any time during the performance of the services,without invalidating this Agreement,to order extra work beyond that specified in the Scope of Services or make changes by altering, adding to or deducting from said work. No such extra work may be undertaken unless a written order is first given by the Contract Officer to the Contractor, incorporating therein any adjustment in (i) the Contract Sum, and/or (ii) the time to perform this Agreement, which said adjustments are subject to the written approval of the Contractor. Any increase in compensation of up to ten percent(10%)of the Contract Sum may be approved by the Contract Officer as may be needed to perform any extra work. Any greater increases, taken either separately or cumulatively must be approved by the City Council. It is expressly understood by Contractor that the provisions of this Section shall not apply to services specifically set forth in the Scope of Services or reasonably contemplated therein, regardless of whether the time or materials required to complete any work or service identified in the Scope of Work exceeds any time or material amounts or estimates provided therein.. 1.9 Special Requirements. Additional terms and conditions of this Agreement, if any, which are made a part hereof are set forth in the"Special Requirements"attached hereto as Exhibit "B" and incorporated herein by this reference. In the event of a conflict between the provisions of E=xhibit"B" and any other provisions of this Agreement, the provisions of Exhibit"B" shall govern. 1.10 Responsible to City. Contractor acknowledges and agrees that the work and services the Contractor will produce for the City, including any initial study, screen check draft environmental impact report, draft environmental impact report, and final environmental impact report,will be prepared in strict and full compliance with the California Environmental Quality Act and the Environmental Quality Act Guidelines(collectively,the"Law"). Contractor further acknowledges and agrees that, consistent with the requirements of the Law, all documents that Contractor prepares must reflect the independent judgment of the City. All work performed and all work product produced shall be subject to review, revision, and approval of the Contract Officer and the final environmental impact report,including the draft environmental impact report,comments thereto,and all related responses to comments, will be subject to approval by the City Council. In addition, Contractor shall not meet with or discuss the work, services, or the contents of any work product with the applicant or a representative of the applicant without the express approval of the Contract Officer nor shall the Contractor take direction from the applicant or the applicant's representative. 2.0 COMPENSATION 2.1 Contract Sum. For the services rendered pursuant to this Agreement, the Contractor shall be compensated in accordance with the "Schedule of Compensation" attached hereto as Exhibit "C" and incorporated herein by this reference, but not exceeding the maximum contract amount of TWENTY-SEVEN THOUSAND AND NO/100 DOLLARS ($27,000.00) herein "Contract Sum"), except as provided in Section 1.8. The method of compensation may include: (i)a lump sum payment upon completion, (ii)payment in accordance with the percentage of completion of the services, (iii)payment for time and materials based upon the Contractor's rates as specified in the Schedule of Compensation, but not exceeding the Contract Sum or(iv)such other methods as may be specified in the Schedule of Compensation. Compensation may include reimbursement for 3.2871 15.1101 BMW of Palm Springs—LSA Associates Contract 2 of 22 actual and necessary expenditures for reproduction costs, telephone expense, transportation expense approved by the Contract Officer in advance, and no other expenses and only if specified in the Schedule of Compensation. The Contract Sum shall include the attendance of Contractor at all project meetings reasonably deemed necessary by the City; Contractor shall not be entitled to any additional compensation for attending said meetings. Contractor hereby acknowledges that it accepts the risk that the services to be provided pursuant to the Scope of Services may be more costly or time consuming than Contractor anticipates, that Contractor shall not be entitled to additional compensation therefore, and the provisions of Section 1.8 shall not be applicable for such services. THE MAXIMUM AMOUNT OF CITY'S OBLIGATION UNDER THIS SECTION 2.1 IS THE AMOUNT SPECIFIED HEREIN. IF THE CITY'S MAXIMUM OBLIGATION IS REACHED BEFORE THE CONTRACTOR'S SERVICES UNDER THIS AGREEMENT ARE COMPLETED, CONTRACTOR WILL NEVERTHELESS COMPLETE THE SERVICES WITHOUT LIABILITY ON THE CITY'S PART FOR FURTHER PAYMENT BEYOND THE MAXIMUM AMOUNT. 2.2 Method of Payment. Unless some other method of payment is specified in the Schedule of Compensation, in any month in which Contractor wishes to receive payment, no later than the first (1st) working day of such month, Contractor shall submit to the City in the form approved by the City's Director of Finance, an invoice for services rendered with supporting documents for reimbursable expenses prior to the date of the invoice. Except as provided in Section 7.3, City shall pay Contractor for all expenses stated thereon which are approved by City pursuant to this Agreement no later than the last working day of the month. 3.0 PERFORMANCE SCHEDULE 3.1 Time of Essence. Time is of the essence in the performance of this Agreement. 3.2 Schedule of Performance. Contractor shall commence the services pursuant to this Agreement upon receipt of a written notice to proceed and shall perform all services within the time period(s)established in the"Schedule of Performance"attached hereto as Exhibit"D", if any, and incorporated herein by this reference. When requested by the Contractor, extensions to the time period(s)specified in the Schedule of Performance may be approved in writing by the Contract Officer, but not exceeding (Refer to Exhibit"D" Highly Aggressive Schedule). 3.3 Force Maieure. The time period(s)specified in the Schedule of Performance for performance of the services rendered pursuant to this Agreement shall be extended because of any delays due to unforeseeable causes beyond the control and without the fault or negligence of the Contractor, including, but not restricted to, acts of God or of the public enemy, unusually severe weather, fires, earthquakes, floods, epidemics, quarantine restrictions, riots, strikes, freight embargoes, wars, litigation, and/or acts of any governmental agency, including the City, if the Contractor shall within ten(10)days of the commencement of such delay notify the Contract Officer in writing of the causes of the delay. The Contract Officer shall ascertain the facts and the extent of delay, and extend the time for performing the services for the period of the enforced delay when and if in the judgment of the Contract Officer such delay is justified. The Contract Officer's determination shall be final and conclusive upon the parties to this Agreement. In no event shall Contractor be entitled to recover damages against the City for any delay in the performance of this Agreement, however caused, Contractor's sole remedy being extension of the Agreement pursuant to this Section. 3.4 Term. Unless earlier terminated in accordance with Section 7.8 of this Agreement, this Agreement shall continue in full force and effect until completion of the services but not exceeding one (1)year from the date hereof, except as otherwise provided in the Schedule of Performance (Exhibit "D"). 3.2871 /5.1101 BMW of Palm Springs—LSA Associates Contract 3 of 22 4.0 COORDINATION OF WORK 4.1 Representative of Contractor. The following principals of Contractor are hereby designated as being the principals and representatives of Contractor authorized to act in its behalf with respect to the work specified herein and make all decisions in connection therewith: Mr. Lyn Calerdine, Principal in Charge Mr. Dale Blount, Senior Planner and Project Manager Mr. George Foscardo, Senior Planner LSA ASSOCIATES, INC. 760-416-2075 Phone — 760-416-3065 Fax It is expressly understood that the experience, knowledge, capability and reputation of the foregoing principals were a substantial inducement for City to enter into this Agreement. Therefore, the foregoing principals shall be responsible during the term of this Agreement for directing all activities of Contractor and devoting sufficient time to personally supervise the services hereunder. For purposes of this Agreement, the foregoing principals may not be replaced nor may their responsibilities be substantially reduced by Contractor without the express written approval of City. 4.2 Contract Officer. The Contract Officer shall be such person as may be designated by the City Manager of City. It shall be the Contractor's responsibility to assure that the Contract Officer is kept informed of the progress of the performance of the services and the Contractor shall refer any decisions which must be made by City to the Contract Officer. Unless otherwise specified herein, any approval of City required hereunder shall mean the approval of the Contract Officer. The Contract Officer shall have authority to sign all documents on behalf of the City required hereunder to carry out the terms of this Agreement. 4.3 Prohibition Against Subcontracting or Assignment. The experience, knowledge, capability and reputation of Contractor, its principals and employees were a substantial inducement for the City to enter into this Agreement. Therefore, Contractor shall not contract with any other entity to perform in whole or in part the services required hereunder without the express written approval of the City. In addition, neither this Agreement nor any interest herein maybe transferred, assigned, conveyed, hypothecated or encumbered voluntarily or by operation of law,whether for the benefit of creditors or otherwise, without the prior written approval of City. Transfers restricted hereunder shall include the transfer to any person or group of persons acting in concert of more than twenty five percent (25%) of the present ownership and/or control of Contractor, taking all transfers into account on a cumulative basis. In the event of any such unapproved transfer, including any bankruptcy proceeding, this Agreement shall be void. No approved transfer shall release the Contractor or any surety of Contractor of any liability hereunder without the express consent of City. The City's policy is to encourage the awarding of subcontracts to persons or entities with offices located within the jurisdictional boundaries of the City of Palm Springs and, if none are available, to persons or entities with offices located in the Coachella Valley("Local Subcontractors"). Contractor hereby agrees to use good faith efforts to award subcontracts to Local Subcontractors, if Local Subcontractors are qualified to perform the work required. In requesting for the City to consent to a subcontract with a person or entity that is not a Local Subcontractor, the Contractor shall submit evidence to the City that such good faith efforts have been made or that no Local Subcontractors are qualified to perform the work. Said good faith efforts may be evidenced by placing advertisements inviting proposals or by sending requests for proposals to selected Local Subcontractors. The City may consider Contractor's efforts in determining whether it will consent to a particular subcontractor. Contractor shall keep evidence of such good faith efforts and copies of all contracts and subcontracts hereunder for the period specified in Section 6.2. 4.4 Independent Contractor. Neither the City nor any of its employees shall have any control over the manner, mode or means by which Contractor, its agents or employees, perform the 3.2871 15.1101 BMW of Palm Springs—LSA Associates Contract 4 of 22 services required herein, except as provided in Section 1.10 or otherwise set forth in this Agreement. City shall have no voice in the selection, discharge, supervision or control of Contractor's employees,servants,representatives or agents,or in fixing their number, compensation or hours of service. Contractor shall perform all services required herein as an independent contractor of City and shall remain at all times as to City a wholly independent contractor with only such obligations as are consistent with that role. Contractor shall not at any time or in any manner represent that it or any of its agents or employees are agents or employees of City. City shall not in any way or for any purpose become or be deemed to be a partner of Contractor in its business or otherwise or a joint venturer or a member of any joint enterprise with Contractor. 5.0 INSURANCE, INDEMNIFICATION AND BONDS 5.1 Insurance. The Contractor shall procure and maintain, at its sole cost and expense, in a form and content satisfactory to City, during the entire term of this Agreement including any extension thereof, the following policies of insurance: (a) Commercial General Liability Insurance. A policy of commercial general liability insurance written on a per occurrence basis with a combined single limit of a least $1,000,000 bodily injury and property damage including coverages for contractual liability, personal injury, independent contractors, broad form property damage, products and completed operations. The Commercial General Liability Policy shall name the City of Palm Springs as an additional insured in accordance with standard ISO additional insured endorsement form CG2010(1185)or equivalent language. The Commercial General Liability Insurance shall name the City, its officers,employees and agents as additional insured. (b) Worker's Compensation Insurance. A policy of workers'compensation insurance in an amount which fully complies with the statutory requirements of the State of California and which includes $1,000,000 employer's liability. (c) Business Automobile Insurance. A policy of business automobile liability insurance written on a per occurrence basis with a single limit liability in the amount of$1,000,000 bodily injury and property damage, Said policy shall include coverage for owned, non-owned, leased and hired cars. (d) Additional Insurance. Additional limits and coverages, which may include professional liability insurance, will be specified in Exhibit "B". All of the above policies of insurance shall be primary insurance. (Reference Section 5.4 regarding sufficiency.) The insurer shall waive all rights of subrogation and contribution it may have against the City, its officers, employees and agents, and their respective insurers. In the event any of said policies of insurance are canceled,the Contractor shall, priorto the cancellation date,submit new evidence of insurance in conformance with this Section 5.1 to the Contract Officer. No work or services under this Agreement shall commence until the Contractor has provided the City with Certificates of Insurance, endorsements or appropriate insurance binders evidencing the above insurance coverages and said Certificates of Insurance, endorsements,or binders are approved by the City. The contractor agrees that the provisions of this Section 5.1 shall not be construed as limiting in any way the extent to which the Contractor may be held responsible for the payment of damages to any persons or property resulting from the Contractor's activities or the activities of any person or person for which the Contractor is otherwise responsible. In the event the Contractor subcontracts any portion of the work in compliance with Section 4.3 of this Agreement the contract between the Contractor and such subcontractor shall require the subcontractor to maintain the same polices of insurance that the Contractor is required to maintain pursuant to this Section. 5.2 Indemnification. Contractor agrees to indemnify the City, its officers, agents and employees against, and will hold and save them and each of them harmless from, any and all actions, suits, claims, damages to persons or property, losses, costs, penalties, obligations,errors, 3.2871 /5.1101 BMW of Palm Springs—LSA Associates Contract 5 of 22 omissions or liabilities,(herein"claims or liabilities")that maybe asserted or claimed by any person, firm or entity arising out of or in connection with the negligent performance of the work,operations or activities of Contractor, its agents, employees, subcontractors, or invitees, provided for herein, or arising from the negligent acts or omissions of Contractor hereunder, or arising from Contractor's negligent performance of or failure to perform any term, provision, covenant or condition of this Agreement, but excluding such claims or liabilities arising from the sole negligence or willful misconduct of the City, its officers, agents or employees, who are directly responsible to the City, and in connection therewith: (a) Contractor will defend any action or actions filed in connection with any of said claims 'or liabilities and will pay all costs and expenses, including legal costs and attorneys' fees incurred in connection therewith; (b) Contractor will promptly pay any judgment rendered against the City, its officers, agents or employees for any such claims or liabilities arising out of or in connection with the negligent performance of or failure to perform such work, operations or activities of Contractor hereunder; and Contractor agrees to save and hold the City, its officers, agents, and employees harmless therefrom; (c) In the event the City, its officers,agents or employees is made a party to any action or proceeding filed or prosecuted against Contractor for such damages or other claims arising out of or in connection with the negligent performance of or failure to perform the work, operation or activities of Contractor hereunder, Contractor agrees to pay to the City, its officers, agents or employees, any and all costs and expenses incurred by the City, its officers,agents or employees in such action or proceeding, including but not limited to, legal costs and attorneys'fees. 5.3 Performance Bond. Concurrently with execution of this Agreement, Contractor shall deliver to City a performance bond in the sum of the amount of this Agreement, in the form provided by the City Clerk, which secures the faithful performance of this Agreement, unless such requirement is waived by the Contract Officer. The bond shall contain the original notarized signature of an authorized officer of the surety and affixed thereto shall be a certified and current copy of his power of attorney. The bond shall be unconditional and remain in force during the entire term of the Agreement and shall be null and void only if the Contractor promptly and faithfully performs all terms and conditions of this Agreement. 5.4 Sufficiency of Insurer or Surety. Insurance or bonds required by this Agreement shall be satisfactory only if issued by companies qualified to do business in California, rated "B"or better in the most recent edition of Best Rating Guide, The Key Rating Guide or in the Federal Register, unless such requirements are waived by the City Manager or designee of the City("City Manager")due to unique circumstances. In the event the City Manager determines that the work or services to be performed under this Agreement creates an increased or decreased risk of loss to the City, the Contractor agrees that the minimum limits of the insurance policies and the performance bond required by this Section 5 may be changed accordingly upon receipt of written notice from the City Manager or designee; provided that the Contractor shall have the right to appeal a determination of increased coverage by the City Manager to the City Council of City within ten (10) days of receipt of notice from the City Manager. 6.0 REPORTS AND RECORDS 6.1 Reports. Contractor shall periodically prepare and submit to the Contract Officer such reports concerning the performance of the services required by this Agreement as the Contract Officer shall require. Contractor hereby acknowledges that the City is greatly concerned about the cost of work and services to be performed pursuant to this Agreement. For this reason, Contractor agrees that if Contractor becomes aware of any facts, circumstances, techniques, or events that may or will materially increase or decrease the cost of the work or services contemplated herein or, if Contractor is providing design services, the cost of the project being designed, Contractor shall promptly notify the Contract Officer of said fact, circumstance, technique or event and the estimated 3.2871 /5.1101 BMW of Palm Springs—LSA Associates Contract 6 of 22 increased or decreased cost related thereto and, if Contractor is providing design services, the estimated increased or decreased cost estimate for the project being designed. 6.2 Records. Contractor shall keep, and require subcontractors to keep, such books and records as shall be necessary to perform the services required by this Agreement and enable the Contract Officer to evaluate the performance of such services. The Contract Officer shall have full and free access to such books and records at all times during normal business hours of City, including the right to inspect,copy,audit and make records and transcripts from such records. Such records shall be maintained for a period of three (3) years following completion of the services hereunder, and the City shall have access to such records in the event any audit is required. 6.3 Ownership of Documents. All drawings, specifications, reports, records, documents and other materials prepared by Contractor,its employees,subcontractors and agents in the performance of this Agreement shall be the property of City and shall be delivered to City upon request of the Contract Officer or upon the termination of this Agreement,and Contractor shall have no claim for further employment or additional compensation as a result of the exercise by City of its full rights of ownership of the documents and materials hereunder. Any use of such completed documents for other projects and/or use of uncompleted documents without specific written authorization by the Contractor will be at the City's sole risk and without liability to Contractor, and the City shall indemnify the Contractor for all damages resulting therefrom. Contractor may retain copies of such documents for its own use. Contractor shall have an unrestricted right to use the concepts embodied therein. All subcontractors shall provide for assignment to City of any documents or materials prepared by them, and in the event Contractor fails to secure such assignment, Contractor shall indemnify City for all damages resulting therefrom. 6.4 Release of Documents. The drawings, specifications, reports, records, documents and other materials prepared by Contractor in the performance of services under this Agreement shall not be released publicly without the prior written approval of the Contract Officer. 7.0 ENFORCEMENT OF AGREEMENT 7.1 California Law, This Agreement shall be construed and interpreted both as to validity and to performance of the parties in accordance with the laws of the State of California. Legal actions concerning any dispute, claim or matter arising out of or in relation to this Agreement shall be instituted in the Superior Court of the County of Riverside, State of California, or any other appropriate court in such county, and Contractor covenants and agrees to submit to the personal jurisdiction of such court in the event of such action. 7.2 Disputes. In the event of any dispute arising under this Agreement, the injured party shall notify the injuring party in writing of its contentions by submitting a claim therefor. The injured party shall continue performing its obligations hereunder so long as the injuring party commences to cure such default within ten (10) days of service of such notice and completes the cure of such default within forty-five (45) days after service of the notice, or such longer period as may be permitted by the injured party; provided that if the default is an immediate danger to the health, safety and general welfare, such immediate action may be necessary. Compliance with the provisions of this Section shall be a condition precedent to termination of this Agreement for cause and to any legal action, and such compliance shall not be a waiver of any party's right to take legal action in the event that the dispute is not cured, provided that nothing herein shall limit City's or the Contractor's right to terminate this Agreement without cause pursuant to Section 7.8. 7.3 Retention of Funds. Contractor hereby authorizes City to deduct from any amount payable to Contractor(whether or not arising out of this Agreement) (i) any amounts the payment of which may be in dispute hereunder or which are necessary to compensate City for any losses, costs, liabilities, or damages suffered by City, and (ii) all amounts for which City may be liable to third parties, by reason of Contractor's acts or omissions in performing or failing to perform Contractor's obligation under this Agreement. In the event that any claim is made by a third party, the amount or validity of which is disputed by Contractor, or any indebtedness shall exist which shall 3.2871 /5.1101 BMW of Palm Springs—LSA Associates Contract 7 of 22 appear to be the basis for a claim of lien, City may withhold from any payment due,without liability for interest because of such withholding, an amount sufficient to cover such claim. The failure of City to exercise such right to deduct or to withhold shall not, however, affect the obligations of the Contractor to insure, indemnify, and protect City as elsewhere provided herein. 7.4 Waiver. No delay or omission in the exercise of any right or remedy by a nondefaulting party on any default shall impair such right or remedy or be construed as a waiver. A party's consent to or approval of any act by the other party requiring the party's consent or approval shall not be deemed to waive or render unnecessary the other party's consent to or approval of any subsequent act. Any waiver by either party of any default must be in writing and shall not be a waiver of any other default concerning the same or any other provision of this Agreement. 7.5 Rights and Remedies are Cumulative. Except with respect to rights and remedies expressly declared to be exclusive in this Agreement, the rights and remedies of the parties are cumulative and the exercise by either party of one or more of such rights or remedies shall not preclude the exercise by it, at the same or different times, of any other rights or remedies for the same default or any other default by the other party. 7.6 Legal Action. In addition to any other rights or remedies, either party may take legal action, in law or in equity, to cure, correct or remedy any default, to recover damages for any default,to compel specific performance of this Agreement,to obtain declaratory or injunctive relief, or to obtain any other remedy consistent with the purposes of this Agreement. 7.7 Liquidated Damages. Since the determination of actual damages for any delay in performance of this Agreement would be extremely difficult or impractical to determine in the event of a breach of this Agreement,the Contractor and its sureties shall be liable for and shall pay to the City the sum of(waived —see Exhibit"B")as liquidated damages for each working day of delay in the performance of any service required hereunder, as specified in the Schedule of Performance (Exhibit"ID"). The City may withhold from any monies payable on account of services performed by the Contractor any accrued liquidated damages. 7.8 Termination Prior to Expiration of Term. This Section shall govern any termination of this Agreement except as specifically provided in the following Section fortermination for cause. The City reserves the right to terminate this Agreement at any time, with or without cause, upon thirty(30)days'written notice to Contractor, except that where termination is due to the fault of the Contractor, the period of notice may be such shorter time as may be determined by the Contract Officer. In addition, the Contractor reserves the right to terminate this Agreement at any time upon, with or without cause, upon sixty (60) days' written notice to City, except that where termination is due to the fault of the City, the period of notice may be such shorter time as the Contractor may determine. Upon receipt of any notice of termination, Contractor shall immediately cease all services hereunder except such as may be specifically approved by the Contract Officer. Except where the Contractor has initiated termination, the Contractor shall be entitled to compensation for all services rendered prior to the effective date of the notice of termination and for any services authorized by the Contract Officer thereafter in accordance with the Schedule of Compensation or such as may be approved by the Contract Officer, except as provided in Section 7.3. In the event the Contractor has initiated termination, the Contractor shall be entitled to compensation only for the reasonable value of the work product actually produced hereunder. In the event of termination without cause pursuant to this Section, the terminating party need not provide the non-terminating party with the opportunity to cure pursuant to Section 7.2. 7.9 Termination for Default of Contractor. If termination is due to the failure of the Contractor to fulfill its obligations under this Agreement, City may, after compliance with the provisions of Section 7.2, take over the work and prosecute the same to completion by contract or otherwise, and the Contractor shall be liable to the extent that the total cost for completion of the services required hereunder exceeds the compensation herein stipulated (provided that the City shall use reasonable efforts to mitigate such damages), and City may withhold any payments to the 3.2871 /5.1101 BMW of Palm Springs—LSA Associates Contract 8 of 22 Contractor for the purpose of set-off or partial payment of the amounts owed the City as previously stated. 7.10 Attorneys'Fees. If either party to this Agreement is required to initiate or defend or made a party to any action or proceeding in any way connected with this Agreement, the prevailing party in such action or proceeding, in addition to any other relief which may be granted, whether legal or equitable, shall be entitled to reasonable attorney's fees. Attorney's fees shall include attorney's fees on any appeal, and in addition a party entitled to attorney's fees shall be entitled to all other reasonable costs for investigating such action,taking depositions and discovery and all other necessary costs the court allows which are incurred in such litigation. All such fees shall be deemed to have accrued on commencement of such action and shall be enforceable whether or not such action is prosecuted to judgment. 8.0 CITY OFFICERS AND EMPLOYEES: NON-DISCRIMINATION 8.1 Non-liability of City Officers and Employees. No officer or employee of the City shall be personally liable to the Contractor, or any successor in interest, in the event of any default or breach by the City or for any amount which may become due to the Contractororto its successor, or for breach of any obligation of the terms of this Agreement. 8.2 Conflict of Interest. No officer or employee of the City shall have any financial interest, direct or indirect, in this Agreement nor shall any such officer or employee participate in any decision relating to the Agreement which effects his financial interest or the financial interest of any corporation, partnership or association in which he is, directly or indirectly, interested, in violation of any State statute or regulation. The Contractor warrants that it has not paid or given and will not pay or give any third party any money or other consideration for obtaining this Agreement. 8.3 Covenant Against Discrimination. Contractor covenants that,by and for itself, its heirs, executors, assigns, and all persons claiming under or through them, that there shall be no discrimination against or segregation of, any person or group of persons on account of race, color, creed, religion, sex, marital status, national origin,or ancestry in the performance of this Agreement. Contractor shall take affirmative action to insure that applicants are employed and that employees are treated during employment without regard to their race, color, creed, religion,sex, marital status, national origin, or ancestry. 9.0 MISCELLANEOUS PROVISIONS 9.1 Notice. Any notice, demand, request, document, consent, approval, or cornmunication either party desires or is required to give to the other party or any other person shall be in writing and either served personally or sent by prepaid, first-class mail, in the case of the City, to the City Manager and to the attention of the Planning Services Director, CITY OF PALM SPRINGS, P.O. Box 2743, Palm Springs, California 92263, and in the case of the Contractor,to the person at the address designated on the execution page of this Agreement. Either party may change its address by notifying the other party of the change of address in writing. Notice shall be deemed communicated at the time personally delivered or in seventy-two(72)hours from the time of mailing if mailed as provided in this Section. 9.2 Interpretation. The terms of this Agreement shall be construed in accordance with the meaning of the language used and shall not be construed for or against either party by reason of the authorship of this Agreement or any other rule of construction which might otherwise apply. 9.3 Integration; Amendment. It is understood that there are no oral agreements between the parties hereto affecting this Agreement and this Agreement supersedes and cancels any and all previous negotiations, arrangements, agreements and understandings, if any, between the parties, and none shall be used to interpret this Agreement. This Agreement may be amended at any time by the mutual consent of the parties by an instrument in writing. 3.2871 /5.1101 BMW of Palm Springs—LSA Associates Contract 9 of 22 9.4 Severability. In the event that any one or more of the phrases, sentences, clauses, paragraphs, or sections contained in this Agreement shall be declared invalid or unenforceable by a valid judgment or decree of a court of competent jurisdiction, such invalidity or unenforceability shall not affect any of the remaining phrases, sentences, clauses, paragraphs, or sections of this Agreement which are hereby declared as severable and shall be interpreted to carry out the intent of the parties hereunder unless the invalid provision is so material that its invalidity deprives either party of the basic benefit of their bargain or renders this Agreement meaningless. 9.5 Corporate Authority. The persons executing this Agreement on behalf of the parties hereto warrant that(i)such party is duly organized and existing, (ii)they are duly authorized to execute and deliver this Agreement on behalf of said party, (iii) by so executing this Agreement, such party is formally bound to the provisions of this Agreement, and (iv) the entering into this Agreement does not violate any provision of any other Agreement to which said party is bound. IN WITNESS WHEREOF, the parties have executed and entered into this Agreement as of the date first written above. CITY OF PALM SPRINGS ATTEST: a municipal corporation By: By: City Clerk David H. Ready City Manager APPROVED AS TO FORM By: City Attorney (Contractor Signatures on following page) 3.2871 /5.1101 BMW of Palm Springs—LSA Associates Contract 10 of 22 CONTRACTOR: LSA ASSOCIATES, INC. Check One: 901 East Tahquitz Canyon Way#A-200 _Individual_Partnership x Corporation Palm Springs, CA 92262 Corporations require two notarized signatures, one from A and one from B: A. Chairman of Board, President, or any Vice President: and B. Secretary, Assistant Secretary, Treasurer, Assistant Treasurer, or Chief Financial Officer). By: By: Signature (notarized) Signature (notarized) Name: Name: Title: Title: Address: Address: State of } State of } County of }ss County of }ss On before me, On before me personally personally appeared appeared personally known to me (or proved to me on personally known to me (or proved to me on the basis of satisfactory evidence) to be the the basis of satisfactory evidence) to be the person(s)whose name(s)is/are subscribed to person(s)whose name(s)is/are subscribed to the within instrument and acknowledged to me the within instrument and acknowledged to me that he/she/they executed the same in that he/she/they executed the same in his/her/their authorized capacity(ies), and that his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of the person(s), or the entity upon behalf of which the person(s) acted, executed the which the person(s) acted, executed the instrument. instrument. WITNESS my hand and official seal. WITNESS my hand and official seal. Notary Notary Signature: Signature: Notary Seal: Notary Seal: 3.2871 /5.1101 BMW of Palm Springs—LSA Associates Contract 11 of 22 EXHIBIT "A" PROJECT UNDERSTANDING AND SCOPE OF SERVICES Consultant agrees to perform the following Scope of Services for Focused Entitlement, Initial Study/Mitigated Negative Declaration, and other professional planning services for the BMW of Palm Springs Projects 3.2871 and 5.1101, Project Understanding The proposed project entails the construction of a new BMW automobile dealership on 8.78 vacant acres along East Palm Canyon Drive, immediately to the west of the existing facility. The project location is shown in Figure 1. The project will construct the following improvements: • 38, 389 square foot sales and service (first floor) • 30,973 square foot of covered parking (second floor) • 22,793 square foot roof deck(third floor). The balance of the site will be used for product display and enclosed service areas. City approvals of this project will include Architectural Review, Conceptual Site Plan approval or equivalent, and sign plan approval. In addition,the City must approve the environmental document. The City may identify additional procedural steps, as necessary. Associated Actions In addition to the basic proposal, the project proposes the conversion of the existing BMW dealership into an Infiniti dealership, conversion of the existing Infiniti dealership into an expansion of the Mercedes Benz dealership, and an updated sign program addressing the two upgraded facilities. In addition, the existing East Palm Canyon Drive frontage road would be converted into a private street serving all three facilities. The frontage road conversion may require a General Plan Amendment, depending on future review by the City. Data to be Provided by Applicant Prior to commencing major work, the applicant will need to provide a detailed project description to the City and LSA. This project description needs to include: • Project location and parcel map (already provided) • Existing site topography as available • Proposed project characteristics including conceptual site plan, description of building improvements (square feet, number of stories, etc), outdoor improvements, — parking lots with number of spaces, conceptual landscape plan, proposed sign program, proposed modifications to existing buildings. (preliminary version already provided). • Proposed project entitlement actions: General Plan Amendment(if required), site plan 3.2871 /5.1101 BMW of Palm Springs—LSA Associates Contract 12 of 22 ' � • T"•�p { f c t• 5� 6 } ��77 T Ito 4; Project :, µ KAI t . , Ai 4 a - Prior to preparation of the environmental document,the applicant will need to provide the following environmental technical studies, as maybe required by the City;these reports need to be reviewed and approved by the City Department with appropriate expertise. 1. Cultural Resources Study 2. Biological Resources Study 3. Traffic Study(if needed) 4. Air Quality Study(if required) 5. Noise Study(if required) 6. Geotechnical Study(if needed) 7. Hydrology Study(if needed). 8. Phase 1 Hazardous Materials Assessment(already completed). Notes on Technical Studies; The City may determine that existing information prepared for the City's General Plan Update is adequate to cover Geotechnical and Hydrology issues at a level adequate for CEQA approval.The recently prepared"Hazards Report"indicates that the site is located outside identified geotechnical hazard zones and flood zones. Given the small scale of the project site, the City may determine that a traffic study and air quality study are not required. Any noise study would focus on neighborhood compatibility. If requested, LSA can provide a scope of work and budget to prepare any of items 1-5; items 6-7,as required, need to be prepared by an engineer with requisite qualifications. Prior to the distribution of the environmental document and any meeting notices,the applicant needs to provide LSA with a list of property owners within 300 feet or other noticing area established by the City. Based upon our experience with other similar projects, LSA anticipates that the primary environmental issues may be related to the interface of the dealership with the surrounding residential uses. We suggest that the City and the applicant consider the development of a neighborhood compatibility program to ensure that neighborhood concerns, particularly regarding noise, will be appropriately addressed. Data to be provided by the City We assume that the City will provide LSA with the following information 1. Approved project description 2. Approved technical studies 3. City Standard Mailing List 4. Examples of City Documents and Formats 5. Review and comment regarding LSA products. LSA SCOPE OF SERVICES Prc ject Management Coordination, and Administration LSA will perform project management duties forthe planning and environmental review component of the project to assure a cost efficient and quality process. The City will oversee the application 3.2871 /5.1101 BMW of Palm Springs—LSA Associates Contract 14 of 22 process and serve as the conduit of information between applicant and LSA. In particular, LSA will: 1. Prepare the environmental initial study and make recommendations regarding the type of environmental document to be required. 2. Prepare public notices as required and maintain the project distribution list. Note:this scope assumes that any newspaper advertisements or mailings will be accomplished by the City, except as noted below. If requested, LSA can pay for such advertisements/mailings with direct costs reimbursement. 3. Prepare draft project staff reports for the Architectural Committee, Planning Commission and the City Council 4. Prepare monthly project documentation and invoicing 5. Prepare and maintain the project schedule LSA will take a proactive approach to ensure the timely resolution of issues. Note: this budget assumes that the project will extend no longer than 8 months. If the project extends further,then the budget for project management will require adjustment due to additional meetings, monthly documentation, etc. Time is of the Essence LSA recognizes that automotive dealerships are extremely important to local government finances, and that time is of the essence in completing this work effort. Critical Focus on Technical Studies Based upon our review of available data, we suggest that that the City, applicant and LSA focus early on identifying the requirement and the scope of work for any additional technical studies, as the critical path leads through these efforts. We suggest that City Departments with expertise attend any such meeting so that there is common agreement on the need for, scope and schedule of any such studies. In our experience,the preparation of any traffic studies is the pacing item in more the one-half of the environmental documents that we prepare. Coordination with City of Palm Springs LSA will prepare for and attend monthly project team meetings, as necessary, with the City and applicant regarding planning and environmental processing of documents, resolution of issues, strategy development, etc. LSA will coordinate with affected departments of the City through meetings and direct contact. Concerns and issues expressed by agency representatives will be documented to ensure that expressed concerns are recorded and addressed. Furthermore, the appropriate City departments, such as Fire, Police, Building,and Engineering,will provide pertinent conditions of approval to LSA for inclusion in the reports as they move forward. Preparation of Environmental Document Working in consultation with the agencies and with technical studies provided by the applicant, LSA will prepare an Initial Study per the City's CEQA guidelines. LSA's proposed budget is based upon a Mitigated Negative Declaration. Given that the project should not require review by State Agencies and does not appear to involve issues of area wide, regional or statewide interest, the project may qualify for an expedited 20 day public review process. LSA will explore this option with the City. LSA will prepare the required CEQA notices to notify required agencies and the general public that 32871 /5.1101 BMW of Palm Springs—LSA Associates Contract 15 of 22 an environmental document is being prepared. These notifications include a Notice of Intent to Adopt a Negative Declaration or a Mitigated Negative Declaration (NOI) and a Notice of Determination (NOD) of the lead agency's final action. LSA will coordinate circulation of the document through the State Clearinghouse, if required, LSA will also coordinate the filing of the NOD with the County of Riverside; the budget assumes that the City or the applicant with pay the requisite filing fee. Generate Staff Reports LSA will the Planning Commission and potential City Council staff reports per City standards and format. The City will provide LSA with sample documents for use in ensuring adherence to those formats. We understand that the Architectural Review Committee does not require a Staff Report. The staff reports will include several components including: • A recommendation for certification of the environmental review, a recommendation for approval/denial (with approval subject to review by planning director if requested), • A recommendation for conditions of approval (if project is recommended for approval), • Receive comments from the Public and the Planning Commission with responses as appropriate, • Findings of Fact for Approval or Denial, and • Amend Recommendations and Findings as directed by the Planning Commission if appropriate. The budget is based upon one presentation before the Planning Commission and one presentation before the Architectural Review Committee.Additional meetings can be attended at cost and would possibly include the City Council. 3.2871 /51101 BMW of Palm Springs—LSA Associates Contract 16 of 22 EXHIBIT "B" SPECIAL REQUIREMENTS City hereby waives Section 5.3 as a requirement of this Agreement. City hereby waives Section 7.7 as a requirement of this Agreement. 3.2871 /5.1101 BMW of Palm Springs—LSA Associates Contract 17 of 22 EXHIBIT "C" SCHEDULE OF COMPENSATION Client agrees to compensate Consultant for such services as shown below. Consultant shall complete the work outlined above in accordance with the fees schedule identified below and shall invoice Client on a monthly basis on the percentage of completion. Consultant proposes to accomplish these tasks on an hourly basis consistent with the billing rates. The following summarizes the proposed tasks described above. TASKS BUDGET Project Management, Meeting Attendance and Administration $ 4,000.00 Initial Stud $ 12,000.00 Notice of Intent $ 500.00 Architectural Committee Meeting $ 1000.00 -Response to Comments/Revise MND 20 Hour Maximum $ 3,000.00 -Planning Commission Staff Report and Meeting $ 5,500.00 Notice of Determination $ 1,000.00 TOTAL CONTRACT COSTS $ 27,000.00 Note: This budget assumes that the City and/or applicant will pay all necessary filing fees(i.e., Fish and Game Fee at the time of filing of the Notice of Determination), and the City will pay for any necessary public notices. The budget is based upon an maximum of 20 hours to prepare the response to any comments. This budget will not be exceeded without the expressed approval of the City of Palm Springs. Authorized additional tasks not included in the above scope of work can be conducted on a time and materials basis according to the attached rates. 3.2871 /5.1101 BMW of Palm Springs—LSA Associates Contract 18 of 22 EXHIBIT"D" SCHEDULE OF PERFORMANCE — HIGHLY AGGRESSIVE The following table shows the typical times for the primary steps listed above and includes the scenario of a longer process that incorporates City Council review. Note that certain tasks are particularly vulnerable to the critical path of tasks outside of LSA's purview. For example, completion of the Initial Study is subject to the availability of various technical studies. CRITICAL.PATH TASK. : RESPONSIBILITY. :TIME LENGTH 1. Notice to roceed city n/a 2. Meetin with Ci and A licant LSA n/a 3. Issue Resolution: GPA Approach, Traffic Approach, Biological All 1-2 weeks Resources, Cultural Resources 4. Preparation of the Initial Study (after review and approval of all LSA 2-3 weeks technical studies 5. Lead Agency review(City) city 1-2 weeks 6. Prepare Distribution List LSA(with input from 1 week (in parallel City and Applicant) with Ste 5). 7. Revise Initial Study Per City Comments LSA 2 days 8. Posting and Circulation of the 3-4 weeks (20 day Notice of Intent(NO]) City minimum County Clerkposting) 9. Architectural Review meeting City During IS/MND review period 10. Planning Commission Staff 3 weeks During Report preparation, review, and LSA IS/MND Review revision Period 11. Planning Commission meetin City Per Calendar 12. Preparation and recirculation of MND if necessary) LSA One month 13. Preparation of City Council Staff 2 weeks (in parallel Report, review, and revision LSA with Item 13 14. City Council meeting (if required) One month (for City scheduling) 15. Notice of Determination preparation, review, revision, LSA 2 days and circulation 3.2871 /5.1101 BMW of Palm Springs—LSA Associates Contract 19 of 22 Palm Springs BMW Dealership Relocation - Highly Aggressive Schedule ID Task Name March April Ma ___a/5 -, _a/i9-, - 31261 4/2 .419,__4/16 - 4/23 4/30-_i 5/7 5114 5121- 5/28 614 6111ne 2 Issue Resolution 3 Resolve General Plan Issue All m 4 Resolve Traffic Study Issue All XS - 5 Resolve Biology Issue 0 All - - O -6 Resolve Cultural Resources - ��--- All 7 I: 8 Environmental Document rA Q 9 Prepare Initial Study(IS) ,l ;�,;, A m 10 City Review -__ ity O C 11 Revise and Complete LSA,City - m 12� Circulate IS(MND):20 days - �. _ O LSA- -n 13_ Prepare Response to Comments - -_-_- LSA 0 m 14 City Review "---==`r city -p O 15 Revise and Complete - - A 16 Planning Commission CertifiesD 17 Notice of Determination ♦ 5129 Q - — In 18 19 1 Architectural Committee Review 4124 _ S 21—J Planning Commission Review = rC [22 Prepare Staff Report --- q - City Review - - - it m Complete Staff Report -_ N Planning Commission Meeting5124 m :General Plan Amendment Process Prepare City Council Staff Report - SA 29 City Staff Review/Approve." sty 30 City Council Meeting ,`��..♦ 617 J Project: BMW Deaiership.mpp Task _ Milestone . Date Sat 3/11106 EXHIBIT "E" LSA IN-HOUSE DIRECT EXPENSES DESCRIPTION OF EXPENSES (included in estimate) Unit Cost Reproduction $0.10 per a e Color Reproduction 8.5x11 $1.00 perjpage LKlea r Re roduction 11x17 $3.00 e Road $0.445 per mile Off-road $0.595 per mile Facsimile $1.00 perpa e . F'lottin $5.00 per linear ft. Diazo Printing $0.20 per s . ft. Film (developing billed separately as a direct cost $5.00 per roll Disposable camera and film (developing billed separately as a direct $10.00 per camera cost Search of Specialized Data Bases $100.00 per inquiry Pen ma /GPS Unit $200.00 per day Arc ma /GPS Unit $150.00 per day Aerial Photos $200.00 per photo Contractor shall submit all supporting documents for reimbursable expenses at time of invoicing for professional services rendered. 3.2871 /5.1101 BMW of Palm Springs—LSA Associates Contract 21 of 22 LSA ASSOC I AI ES INC' PROPOSAL FOR PLANNING SERVICES MARCH E000 CITY OF PALM SPRINGS BMW DEALERSHIP RELOCATION T,SA unUu_r,v BIY .T I1:G RATES EFFECTIVE AUGUST 2005 Job Classification Hourly Rate Planning, Environmental Transportation Air/Noise Cultural Resources Biology GIs Range* Principal Principal Principal Principal Principal Principal Principal $120-225 m 2 Associate Associate Associate Associate Associate Associate Associate $75-175 1p -1 Senior Planner Senior Senior Transportation Senior All- Senior Cultural Senior Biologist/ Botanist/ Senior GlS $75-160 T Enviromnental Planner Planner/Engineer Quality/Noise Resources Manager Wildlife Biologist/ Specialist Specialist Ecologist/Soil Scientist/ h He etulo ist/Arborist N Plarmer Envirorunental Planner Transportation Air Quality/Noise Cultural Resources Biologist/Botanist/Wildlife GIS Specialist S 50-125 D Planner/Engineer Specialist Manager Biologist/Ecologist/Soil = Scientist/Herpetologist/ C Arborist ;0 r Assistant Planner Assistant Assistant Transportation Air—Quality/Norse Cutural Resources Assistant Biologist/ Assistant GIS Envu'omnental Planner Planner/Engineer Analyst Analyst Botanist/Wildlife Biologist/ Specialist W Ecologist/Soil Scientist/ rr Her etolo st/Arborist Z Field Services M Field Director D $50-100 —I Senior Field Crew/Field Crew $ m 35-75 m Office Services n Research Assistant/Technician m $25-50 1 Graphics $70-too m Office Assistant $40-75 D C Word Processing/Pechmcal Editing $60-90 .n Cn to 1 ro 0 0 w The hourly rate for work involving actual expenses in court,giving depositions or similar expert testimony,will be billed at$250 per hour regardless ofjob classifications. 03/11/06(P.IBMWtBMW Proposal doc)