Loading...
HomeMy WebLinkAboutA6252 - THE ADAMS COMPANY CONSULTANT FOR AIRPORT GRANT CONSULTING SERVICES AGREEMENT The Adams Companies,LLC THIS AGRENT FOR CONSULTING SERVICES ("Agreement") is made and entered into on April,?, 2019, by and between the City of Palm Springs, a California charter city and municipal corporation ("City"), and The Adams Companies, a Limited Liability Company, ("Consultant"). City and Consultant are individually referred to as "Party" and are collectively referred to as the"Parties". RECITALS A. City requires the services of an independent fee consultant as required for FAA grant project, for review of the construction management services for the Airport Ticket-Wing renovation, ("Project"). B. Consultant has submitted to City a proposal to provide independent fee consulting to review construction management services of the RS&H proposal, to City under the terms of this Agreement. C. Based on its experience, education, training, and reputation, Consultant is qualified and desires to provide the necessary services to City for the Project. D. City desires to retain the services of Consultant for the Project. In consideration of these promises and mutual agreements, City agrees as follows: AGREEMENT 1. CONSULTANT SERVICES 1.1 Scone of Services. In compliance with all terms and conditions of this Agreement, Consultant shall provide Independent Fee Consulting, services to City as described in the Scope of Services/Work attached to this Agreement as Exhibit "A" and incorporated by reference (the "services" or "work"). Exhibit "A" includes the agreed upon schedule of performance and the schedule of fees. Consultant warrants that all services and work shall be performed in a competent, professional, and satisfactory manner consistent with prevailing industry standards. In the event of any inconsistency between the terms contained in the Scope of Services/Work and the terms set forth in this Agreement,the terms set forth in this Agreement shall govern. 1.2 Compliance with Law. Consultant services rendered under this Agreement shall comply with all applicable federal, state, and local laws, statutes and ordinances and all lawful orders,rules, and regulations. 1.3 Licenses and Permits. Consultant shall obtain at its sole cost and expense such licenses, permits, and approvals as may be required by law for the performance of the services required by this Agreement. 1 ORIGINAL BID Revised:1/31/18 720599.1 A_ _EVOR AGREEMENT 1.4 Familiarity with Work. By executing this Agreement, Consultant warrants that it has carefully considered how the work should be performed and fully understands the facilities, difficulties, and restrictions attending performance of the work under this Agreement. 2. TIME FOR COMPLETION The time for completion of the services to be performed by Consultant is an essential condition of this Agreement. Consultant shall prosecute regularly and diligently the work of this Agreement according to the agreed upon schedule of performance set forth in Exhibit "A." Consultant shall not be accountable for delays in the progress of its work caused by any condition beyond its control and without the fault or negligence of Consultant. Delays shall not entitle Consultant to any additional compensation regardless of the party responsible for the delay. 3. COMPENSATION OF CONSULTANT 3.1 Compensation of Consultant. Consultant shall be compensated and reimbursed for the services rendered under this Agreement in accordance with the schedule of fees set forth in Exhibit"A". The total amount of Compensation shall not exceed$5,000. 3.2 Method of Payment. In any month in which Consultant wishes to receive payment, Consultant shall submit to City an invoice for services rendered prior to the date of the invoice, no later than the first working day of such month, in the form approved by City's finance director. Payments shall be based on the hourly rates set forth in Exhibit "A" for authorized services performed. City shall pay Consultant for all expenses stated in the invoice that are approved by City and consistent with this Agreement, within thirty (30) days of receipt of Consultant's invoice. 3.3 Changes. In the event any change or changes in the Scope of Services/Work is requested by City, Parties shall execute a written amendment to this Agreement, specifying all proposed amendments, including, but not limited to, any additional fees. An amendment may be entered into: A. To provide for revisions or modifications to documents, work product, or work,when required by the enactment or revision of any subsequent law; or B. To provide for additional services not included in this Agreement or not customarily furnished in accordance with generally accepted practice in Consultant's profession. 3.4 Appropriations. This Agreement is subject to, and contingent upon, funds being appropriated by the City Council of City for each fiscal year. If such appropriations are not made,this Agreement shall automatically terminate without penalty to City. 4. PERFORMANCE SCHEDULE 4.1 Time of Essence. Time is of the essence in the performance of this Agreement. 2 Revised:1/3 111 B 720599.1 4.2 Schedule of Performance. All services rendered under this Agreement shall be performed under the agreed upon schedule of performance set forth in Exhibit "A." Any time period extension must be approved in writing by the Contract Officer. 4.3 Force Maieure. The time for performance of services to be rendered under this Agreement may be extended because of any delays due to unforeseeable causes beyond the control and without the fault or negligence of Consultant, if Consultant notifies the Contract Officer within ten (10) days of the commencement of such condition. Unforeseeable causes include, but are not limited to, acts of God or of a public enemy, acts of the government, fires, earthquakes, floods, epidemic, quarantine restrictions, riots, strikes, freight embargoes, and unusually severe weather. After Consultant notification, the Contract Officer shall investigate the facts and the extent of any necessary delay and extend the time for performing the services for the period of the enforced delay when and if, in the Contract Officer's judgment, such delay is justified. The Contract Officer's determination shall be final and conclusive upon the parties to this Agreement. 4.4 Term. Unless earlier terminated in accordance with Section 4.5 of this Agreement, this Agreement shall continue in full force and effect for a period of twelve weeks (weeks/months), commencing on April 9, 2019, and ending on July 9, 2019, unless extended by mutual written agreement of the parties. 4.5 Termination Prior to Expiration of Term. City may terminate this Agreement at any time, with or without cause, upon thirty (30) days written notice to Consultant. Where termination is due to the fault of Consultant and constitutes an immediate danger to health, safety, and general welfare, the period of notice shall be such shorter time as may be determined by the City. Upon receipt of the notice of termination, Consultant shall immediately cease all services except such as may be specifically approved by the Contract Officer. Consultant shall be entitled to compensation for all services rendered prior to receipt of the notice of termination and for any services authorized by the Contract Officer after such notice. Consultant may terminate this Agreement,with or without cause,upon thirty (30) days written notice to City. 5. COORDINATION OF WORK 5.1 Representative of Consultant. The following principal of Consultant is designated as being the principal and representative of Consultant authorized to act and make all decisions in its behalf with respect to the specified services and work: Gary Adams (name), President (title). It is expressly understood that the experience,knowledge, education, capability, and reputation of the foregoing principal is a substantial inducement for City to enter into this Agreement. Therefore, the foregoing principal shall be responsible during the term of this Agreement for directing all activities of Consultant and devoting sufficient time to personally supervise the services under this Agreement. The foregoing principal may not be changed by Consultant without prior written approval of the Contract Officer. 5.2 Contract Officer. The Contract Officer shall be the City Manager or his/her designee ("Contract Officer"). Consultant shall be responsible for keeping the Contract Officer fully informed of the progress of the performance of the services. Consultant shall refer any 3 Revised:1/31/18 720599.1 decisions that must be made by City to the Contract Officer. Unless otherwise specified, any approval of City shall mean the approval of the Contract Officer. 5.3 Prohibition Against Subcontracting or Assignment. The experience, knowledge, education, capability, and reputation of Consultant, its principals and employees, were a substantial inducement for City to enter into this Agreement. Therefore, Consultant shall not contract with any other individual or entity to perform any services required under this Agreement without the City's express written approval. In addition, neither this Agreement nor any interest may be assigned or transferred, voluntarily or by operation of law, without the prior written approval of City. 5.4 Independent Contractor. Neither City nor any of its employees shall have any control over the manner, mode, or means by which Consultant, its agents or employees,perform the services required, except as otherwise specified. Consultant shall perform all required services as an independent Consultant of City and shall not be an employee of City and shall remain at all times as to City a wholly independent Consultant with only such obligations as are consistent with that role; however, City shall have the right to review Consultant's work product, result, and advice. Consultant shall not at any time or in any manner represent that it or any of its agents or employees are agents or employees of City. 5.5 Personnel. Consultant agrees to assign the following individuals to perform the services in this Agreement. Consultant shall not alter the assignment of the following personnel without the prior written approval of the Contract Officer. Acting through the City Manager, the City shall have the unrestricted right to order the removal of any personnel assigned by Consultant by providing written notice to Consultant. Name: Title: Gary Adams President 6. INSURANCE Consultant shall procure and maintain, at its sole cost and expense, policies of insurance as set forth in the attached Exhibit "B", incorporated herein by reference. 7. INDEMNIFICATION. 7.1 Indemnification. To the fullest extent permitted by law, Consultant shall defend (at Consultant's sole cost and expense), indemnify, protect, and hold harmless City, its elected officials, officers, employees, agents, and volunteers (collectively the "Indemnified Parties"), from and against any and all liabilities, actions, suits, claims, demands, losses, costs, judgments, arbitration awards, settlements, damages, demands, orders, penalties, and expenses including legal costs and attorney fees (collectively "Claims"), including but not limited to Claims arising from injuries to or death of persons (Consultant's employees included), for damage to property, including property owned by City, from any violation of any federal, state, 4 Revised:1/31118 720599.1 or local law or ordinance, and from errors and omissions committed by Consultant, its officers, employees, representatives, and agents, that arise out of or relate to Consultant's performance under this Agreement. This indemnification clause excludes Claims arising from the sole negligence or willful misconduct of the City, its elected officials, officers, employees, agents, and volunteers. Under no circumstances shall the insurance requirements and limits set forth in this Agreement be construed to limit Consultant's indemnification obligation or other liability under this Agreement. Consultant's indemnification obligation shall survive the expiration or earlier termination of this Agreement until all actions against the Indemnified Parties for such matters indemnified are fully and finally barred by the applicable statute of limitations or, if an action is timely filed, until such action is final. This provision is intended for the benefit of third party Indemnified Parties not otherwise a party to this Agreement. 7.2 Design Professional Services Indemnification and Reimbursement. If the Agreement is determined to be a "design professional services agreement" and Consultant is a "design professional"under California Civil Code Section 2782.8,then: A. To the fullest extent permitted by law, Consultant shall indemnify, defend (at Consultant's sole cost and expense), protect and hold harmless City and its elected officials, officers, employees, agents and volunteers and all other public agencies whose approval of the project is required, (individually"Indemnified Party"; collectively"Indemnified Parties") against any and all liabilities, claims,judgments, arbitration awards, settlements, costs, demands, orders and penalties (collectively"Claims"), including but not limited to Claims arising from injuries or death of persons (Consultant's employees included) and damage to property, which Claims arise out of, pertain to, or are related to the negligence, recklessness or willful misconduct of Consultant, its agents, employees, or subcontractors, or arise from Consultant's negligent, reckless or willful performance of or failure to perform any term, provision, covenant or condition of this Agreement ("Indemnified Claims"), but Consultant's liability for Indemnified Claims shall be reduced to the extent such Claims arise from the negligence, recklessness or willful misconduct of the City and its elected officials, officers, employees, agents and volunteers. B. The Consultant shall require all non-design-professional sub-contractors, used or sub-contracted by Consultant to perform the Services or Work required under this Agreement, to execute an Indemnification Agreement adopting the indemnity provisions in sub- section 7.1 in favor of the Indemnified Parties. In addition, Consultant shall require all non- design-professional sub-contractors, used or sub-contracted by Consultant to perform the Services or Work required under this Agreement, to obtain insurance that is consistent with the Insurance provisions as set forth in this Agreement, as well as any other insurance that may be required by Contract Officer. 8. RECORDS AND REPORTS 8.1 Reports. Consultant shall periodically prepare and submit to the Contract Officer reports concerning the performance of the services required by this Agreement, or as the Contract Officer shall require. 5 Revised:1/31/18 720599.1 8.2 Records. Consultant shall keep complete, accurate, and detailed accounts of all time, costs, expenses, and expenditures pertaining in any way to this Agreement. Consultant shall keep such books and records as shall be necessary to properly perform the services required by this Agreement and enable the Contract Officer to evaluate the performance of such services. The Contract Officer shall have full and free access to such books and records at all reasonable times, including the right to inspect, copy, audit, and make records and transcripts from such records. 8.3 Ownership of Documents. All drawings, specifications, reports, records, documents, and other materials prepared by Consultant in the performance of this Agreement shall be the property of City. Consultant shall deliver all above-referenced documents to City upon request of the Contract Officer or upon the termination of this Agreement. Consultant shall have no claim for further employment or additional compensation as a result of the exercise by City of its full rights or ownership of the documents and materials. Consultant may retain copies of such documents for Consultant's own use. Consultant shall have an unrestricted right to use the concepts embodied in such documents. 8.4 Release of Documents. All drawings, specifications, reports, records, documents, and other materials prepared by Consultant in the performance of services under this Agreement shall not be released publicly without the prior written approval of the Contract Officer. 8.5 Cost Records. Consultant shall maintain all books, documents,papers, employee time sheets, accounting records, and other evidence pertaining to costs incurred while performing under this Agreement. Consultant shall make such materials available at its offices at all reasonable times during the term of this Agreement and for three (3) years from the date of final payment for inspection by City and copies shall be promptly furnished to City upon request. 9. ENFORCEMENT OF AGREEMENT 9.1 California Law. This Agreement shall be construed and interpreted both as to validity and to performance of the parties in accordance with the laws of the State of California. Legal actions concerning any dispute, claim, or matter arising out of or in relation to this Agreement shall be instituted in the Superior Court of the County of Riverside, State of California, or any other appropriate court in such county, and Consultant covenants and agrees to submit to the personal jurisdiction of such court in the event of such action. 9.2 Interpretation. This Agreement shall be construed as a whole according to its fair language and common meaning to achieve the objectives and purposes of the Parties. The terms of this Agreement are contractual and the result of negotiation between the Parties. Accordingly, any rule of construction of contracts (including, without limitation, California Civil Code Section 1654) that ambiguities are to be construed against the drafting party, shall not be employed in the interpretation of this Agreement. The caption headings of the various sections and paragraphs of this Agreement are for convenience and identification purposes only and shall not be deemed to limit, expand, or define the contents of the respective sections or paragraphs. 6 Revised:1/31/18 720599.1 9.3 Waiver. No delay or omission in the exercise of any right or remedy of a non- defaulting party on any default shall impair such right or remedy or be construed as a waiver. No consent or approval of City shall be deemed to waive or render unnecessary City's consent to or approval of any subsequent act of Consultant. Any waiver by either party of any default must be in writing. No such waiver shall be a waiver of any other default concerning the same or any other provision of this Agreement. 9.4 Rights and Remedies are Cumulative. Except with respect to rights and remedies expressly declared to be exclusive in this Agreement, the rights and remedies of the parties are cumulative. The exercise by either party of one or more of such rights or remedies shall not preclude the exercise by it, at the same or different times, of any other rights or remedies for the same default or any other default by the other party. 9.5 Legal Action. In addition to any other rights or remedies, either party may take legal action, in law or in equity, to cure, correct, or remedy any default, to recover damages for any default, to compel specific performance of this Agreement, to obtain injunctive relief, a declaratory judgment, or any other remedy consistent with the purposes of this Agreement. 10. CITY OFFICERS.AND EMPLOYEES: NON-DISCRIMINATION 10.1 Non-Liability of City Officers and Emplovees. No officer or employee of City shall be personally liable to the Consultant, or any successor-in-interest, in the event of any default or breach by City or for any amount which may become due to the Consultant or its successor, or for breach of any obligation of the terms of this Agreement. 10.2 Conflict of Interest. Consultant acknowledges that no officer or employee of the City has or shall have any direct or indirect financial interest in this Agreement nor shall Consultant enter into any agreement of any kind with any such officer or employee during the term of this Agreement and for one year thereafter. Consultant warrants that Consultant has not paid or given, and will not pay or give, any third party any money or other consideration in exchange for obtaining this Agreement. 10.3 Covenant Against Discrimination. In connection with its performance under this Agreement, Contractor shall not discriminate against any employee or applicant for employment because of actual or perceived race, religion, color, sex, age, marital status, ancestry, national origin(i.e.,place of origin, immigration status, cultural or linguistic characteristics, or ethnicity), sexual orientation, gender identity, gender expression, physical or mental disability, or medical condition (each a "prohibited basis"). Contractor shall ensure that applicants are employed, and that employees are treated during their employment, without regard to any prohibited basis. As a condition precedent to City's lawful capacity to enter this Agreement, and in executing this Agreement, Contractor certifies that its actions and omissions hereunder shall not incorporate any discrimination arising from or related to any prohibited basis in any Contractor activity, including but not limited to the following: employment, upgrading, demotion or transfer; recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship; and further,that Contractor is in full compliance with the provisions of Palm Springs Municipal Code Section 7.09.040, 7 Revised:1/31/18 720599.1 including without limitation the provision of benefits, relating to non-discrimination in city contracting. 11. MISCELLANEOUS PROVISIONS 11.1 Notice. Any notice, demand, request, consent, approval, or communication that either party desires, or is required to give to the other party or any other person shall be in writing and either served personally or sent by pre-paid, first-class mail to the address set forth below. Notice shall be deemed communicated seventy-two (72) hours from the time of mailing if mailed as provided in this Section. Either party may change its address by notifying the other party of the change of address in writing. To City: City of Palm Springs Attention: City Manager/City Clerk 3200 E. Tahquitz Canyon Way Palm Springs, California 92262 To Consultant: The Adams Companies, LLC 2602 S. Jacob Street Gilbert,AZ 85295 11.2 Integrated Agreement. This Agreement contains all of the agreements of the parties and supersedes all other written agreements. 11.3 Amendment. No amendments or other modifications of this Agreement shall be binding unless through written agreement by all Parties. 11.4 Severability. Whenever possible, each provision of this Agreement shall be interpreted in such a manner as to be effective and valid under applicable law. In the event that any one or more of the phrases, sentences, clauses, paragraphs, or sections contained in this Agreement shall be declared invalid or unenforceable by valid judgment or decree of a court of competent jurisdiction, such invalidity or unenforceability shall not affect any of the remaining phrases, sentences, clauses, paragraphs, or sections of this Agreement, which shall be interpreted to carry out the intent of the parties. 11.5 Successors in Interest. This Agreement shall be binding upon and inure to the benefit of the Parties' successors and assignees. 11.6 Third Party Beneficiary. Except as may be expressly provided for in this Agreement, nothing contained in this Agreement is intended to confer, nor shall this Agreement be construed as conferring, any rights, including, without limitation, any rights as a third-party beneficiary or otherwise, upon any entity or person not a party to this Agreement. 8 Revised:1/31/18 720599.1 11.7 Recitals. The above-referenced Recitals are hereby incorporated into the Agreement as though fully set forth in this Agreement and each Party acknowledges and agrees that such Party is bound, for purposes of this Agreement,by the same. 11.8 Authority. The persons executing this Agreement on behalf of the Parties warrant that they are duly authorized to execute this Agreement on behalf of Parties and that by so executing this Agreement the Parties are formally bound to the provisions of this Agreement. IN WITNESS WHEREOF, the Parties have executed this Agreement as of the dates stated below. "CITY" City of Palm Springs f/ Date: �` �� David H. Ready,PhD City Manager APPROVED AS TO FORM: ATTEST By: /� By: J frey . Balling , thony *ia City Attorney City Clerk "CONSULTANT" 1"4 The Adams Companies,LLC Date: A )20 1 By: qeC3--�AA._ Ga Ad s (president) Date: (name) Not To Exceed$Without The Expres_s . Written (secretary) Authorization Of The City Manager. 9 Revised:1/31118 720599.•4 Acknowledgment by Individual State of County of I A r i 1,3iZGt On this jT�day of ►q-Pr-' ( 20 _.before me, Name of Notary Public the undersigned Notary Public,personally appeared � G4�y A-�4..,•�-L s Name of Signer(s) O Proved to me on the oath of O Personally known to me Oowe 0--rrbs— e, Q�Iz�(2br7 O�Proved to me on the basis of satisfactory evidence (�-r: ovl4. r-:U�— C'i c V-VASE (Description of ID) to be the person(s)whose name(s) is/are subscribed to the within instrument,and acknowledged that he/she/they executed it. WITNESS my hand and official seal. 04�Nt ST, , ,leffrey Ciepiel Votary Public gnature of Notary Public) ,.]aricopa County,Arizona '•, ��Niy Comm.Expires 01.03-2021 My commission expires ti Notary Seal Optional:A thumbprint is only needed if state statutes require a thumbprint. RightThumbprin of Signer For Bank Purposes Only Top of thumb-here Description of Attached Document Type or Title of document Gto'1 1�1,n S rdl,000 Document Date Number of Pages 0-I-to -1'0(C� I '?r/r Signer(s)Other Than Named Above DSG5350(Rev 02-05t17) FO01-OOOOODSG5350-01 EXHIBIT "A" CONSULTANT'S SCOPE OF SERVICES/WORK Including, Schedule of Fees And Schedule of Performance 11 Revised:1/31/18 720599.1 The Adams Companies 2602 S Jacob Street Gilbert,Arizona 85295 Phone:602-708-1177 E-mail:caryntheadamscompanies.biz Or:theadamscompaniesna,smail.com April 4,2019 Mr.Mark Jucht Airport Administration Manager Palm Springs International Airport 3400 East Tahquitz Canyon Way Palm Springs, California 92262 Re: Qualifications for an Independent Fee Estimate(IFE)for Palm Springs International Airport Construction Management Services for a Ticket Lobby Modernization project Dear Mr. Jucht: In response to your request for a proposal for the Palm Springs International Airport, The Adams Companies (TAC) is pleased to submit the following statement, proposal and work scope for an Independent Fee Estimate. TAC is a small firm established in 2005 that provides aviation consultation services to airports primarily in the Southwest U.S. TAC prides itself on providing high-quality professional services that result in a high percentage of repeat clients. The Adams Companies has the following outstanding capabilities to bring to this assignment: • Availability: TAC is completing projects in UC-Davis,CA and Lake Havasu City,AZ Airports and can begin work immediately on this analysis and complete the assignment within 7 calendar days. • Relevant Experience: TAC has completed projects similar to those described in your request. We have significant experience in all aspects of airport development projects and independent fee analysis for Federal Aviation Administration (FAA) Airport Improvement Program(AIP)grant programs. �ransportation Relationship with FAA: Mr. Adams retired as the Arizona Department of (ADOT) Aeronautics Division Director after 25 years, and has excellent working relationships with numerous FAA personnel. These relationships allow TAC to effectively and efficiently perform all agency coordination. • Page 2 April 4, 2019 This proposal and attached work scope"Exhibit A"are designed to address the overall needs of the Palm Springs International Airport for completing an Independent Fee Estimate in a well-coordinated and timely manner. Our fee for the proposed scope of services is a lump sum fee of$5,000.00. All work shall be completed within 7 calendar days from the Notice to Proceed.In order to meet the completion date,TAC will require: 1)a written notice to proceed and 2)the receipt of all necessary review materials including the following: a) The Engineer's Estimated Cost of Construction; b) Consultant's proposed scope of work; c)Consultant's redacted budget spreadsheet. We understand the importance of this effort to the City of Palm Springs and the Palm Springs International Airport. We know that during these tight economic times, the Airport needs additional funding options and creative problem solving to help complete much needed improvements.TAC is committed to providing the resources and expertise required to provide you with the most cost-effective,timely consulting services available. Thank you for considering The Adams Companies for this assignment. For more background information on The Adams Companies, please visit our website at: http://www.theadamscompanies.biz/index.html.We look forward to your favorable review of our submission for this project. Please do not hesitate to contact me at 602-708-1177, or via email at ggU(yDtheadamscompanies.biz, if you have any questions or desire further information. Sincerely, The Adams Companies . A4-ar� Gary Adams President April 4, 2019 EXHIBIT A PALM SPRINGS INTERNATIONAL AIRPORT INDEPENDENT FEE ESTIMATE ENGINEERING DESIGN, BID AND CONSTRUCTION ADMINISTRATION SERVICES FOR RENTAL CAR FACILITY EXPANSION PROJECT SCOPE OF WORK AND FEE ESTIMATE Introduction: The City of Palm Springs is undertaking a construction project to update and modernize the ticketing lobby at Palm Springs International Airport. The project includes rehabilitation of the public areas, redevelopment of the airline operations area, installation of an in-line outbound baggage handling and inspection system, and various supporting building and infrastructure upgrades.The City determined the need for Construction Management services to ensure that this project conforms to the Construction Documents(plans and specifications) and project schedule. Adherence to the construction schedule is paramount to the City. The CM must ensure that construction occurs outside the Airport's November 15 to May 1 busy season in 2020. This scope of professional services provides Construction Manager Agent/Owner's Representation (CM) for the City of Palm Springs (the City). The CM provides guidance throughout the project's lifecycle and protects the City's interests.The CM is the City's"eyes and ears" to assist with scheduling and coordination, constructability design review, nonbinding estimating, value engineering, contract conformance work observation, project documentation,and contractual adherence.Above all,the CM is the City's advocate. In order to complete the construction project,the City of Palm Springs, as owner of the Palm Springs International Airport, is about to enter into contract fee negotiations with the airport engineering consultant fun of RS&H (Consultant), after selecting them based on qualifications. In accordance with FAA consultant selection guidelines, the City of Palm Springs is requesting The Adams Companies, LLC (TAC) to submit a proposal and work scope for an Independent Fee Estimate (IFE) on the scope of services to be provided by the selected consultant. The scope of services that TAC proposes for the IFE is as follows: • Page 2 April 4,2019 Task 1: Develop Independent Fee Estimate a)TAC will review the scope of services developed by the Consultant(s)and the Palm Springs International Airport. The scope will be reviewed task-by-task to ensure that all required services for the Project,based on TAC's professional judgment, are thoroughly addressed in accordance with FAA guidelines for projects of this type, including the most recent FAA Advisory Circulars. b)TAC will provide to the Palm Springs International Airport a cost breakdown structure and cost estimate by task. The cost breakdown structure will consider the level of staff skills necessary to effectively complete each task, staff man-hours, and any other cost considerations, i.e. direct costs which may be needed for the acquisition of data or travel- related expenses. This cost breakdown will be similar in format to Appendix E of AC 150/5100-14E Change 1. c) TAC will provide a detailed cover letter with an explanation of costs and a separate comprehensive spreadsheet of the independent fee estimate to the Palm Springs International Airport,in electronic format(and hard copy if requested). Fee: Our fee for the proposed scope of services is a lump sum fee of$5,000.00.All work shall be completed within 7 calendar days from the Notice to Proceed.In order to meet the completion date,TAC will require: 1)a written notice to proceed and 2)the receipt of all necessary review materials including the following: a) The consultant's list of proposed subcontractors and subcontractors proposed work scope; and b) Consultant's proposed scope of work, as approved by the FAA. Exhibit "B" INSURANCE 1. Procurement and Maintenance of Insurance. Contractor shall procure and maintain public liability and property damage insurance against all claims for injuries against persons or damages to property resulting from Contractor's performance under this Agreement. Contractor shall procure and maintain all insurance at its sole cost and expense, in a form and content satisfactory to the City, and submit concurrently with its execution of this Agreement. Contractor shall also carry workers' compensation insurance in accordance with California workers' compensation laws. Such insurance shall be kept in full force and effect during the term of this Agreement, including any extensions. Such insurance shall not be cancelable without thirty(30) days advance written notice to City of any proposed cancellation. Certificates of insurance evidencing the foregoing and designating the City, its elected officials, officers, employees, agents, and volunteers as additional named insureds by original endorsement shall be delivered to and approved by City prior to commencement of services. The procuring of such insurance and the delivery of policies, certificates, and endorsements evidencing the same shall not be construed as a limitation of Contractor's obligation to indemnify City, its elected officials, officers, agents, employees, and volunteers. 2. Minimum Scone of Insurance. The minimum amount of insurance required under this Agreement shall be as follows: 1. Comprehensive general liability and personal injury with limits of at least one million dollars ($1,000,000.00) combined single limit coverage per occurrence and two million dollars ($2,000,000) general aggregate; 2. Automobile liability insurance with limits of at least one million dollars ($1,000,000.00)per occurrence; 3. Professional liability (errors and omissions) insurance with limits of at least one million dollars ($1,000,000.00) per occurrence and two million dollars ($2,000,000) annual aggregate is: X required is not required; 4. Workers' Compensation insurance in the statutory amount as required by the State of California and Employer's Liability Insurance with limits of at least one million dollars $1 million per occurrence. If Contractor has no employees, Contractor shall complete the City's Request for Waiver of Workers' Compensation Insurance Requirement form. 12 Revised:1/31/18 720599.1 3. Primary Insurance. For any claims related to this Agreement, Contractor's insurance coverage shall be primary with respect to the City and its respective elected officials, officers, employees, agents, and volunteers. Any insurance or self-insurance maintained by City and its respective elected officials, officers, employees, agents, and volunteers shall be in excess of Contractor's insurance and shall not contribute with it. For Workers' Compensation and Employer's Liability Insurance only, the insurer shall waive all rights of subrogation and contribution it may have against City, its elected officials, officers, employees, agents, and volunteers. 4. Errors and Omissions Coveraue. If Errors & Omissions Insurance is required, and if Contractor provides claims made professional liability insurance, Contractor shall also agree in writing either(1)to purchase tail insurance in the amount required by this Agreement to cover claims made within three years of the completion of Contractor's services under this Agreement, or (2) to maintain professional liability insurance coverage with the same carrier in the amount required by this Agreement for at least three years after completion of Contractor's services under this Agreement. Contractor shall also be required to provide evidence to City of the purchase of the required tail insurance or continuation of the professional liability policy. 5. Sufficiency of Insurers. Insurance required in this Agreement shall be provided by authorized insurers in good standing with the State of California. Coverage shall be provided by insurers admitted in the State of California with an A.M. Best's Key Rating of B++, Class VII, or better, unless otherwise acceptable to the City. 6. Verification of Coveraee. Contractor shall furnish City with both certificates of insurance and endorsements, including additional insured endorsements, effecting all of the coverages required by this Agreement. The certificates and endorsements are to be signed by a person authorized by that insurer to bind coverage on its behalf. All proof of insurance is to be received and approved by the City before work commences. City reserves the right to require Contractor's insurers to provide complete, certified copies of all required insurance policies at any time. Additional insured endorsements are not required for Errors and Omissions and Workers' Compensation policies. Verification of Insurance coverage may be provided by: (1) an approved General and/or Auto Liability Endorsement Form for the City of Palm Springs or(2) an acceptable Certificate of Liability Insurance Coverage with an approved Additional Insured Endorsement with the following endorsements stated on the certificate: 1. "The City of Palm Springs, its officials, employees, and agents are named as an additional insured..." C as respects City of Palm Springs Contract No._" or 'for any and all work performed with the City"may be included in this statement). 2. "This insurance is primary and non-contributory over any insurance or self- insurance the City may have..." ("as respects City of Palm Springs Contract No. or 'for any and all work performed with the City" may be included in this statement). 3. "Should any of the above described policies be canceled before the expiration date thereof, the issuing company will mail 30 days written notice to the Certificate Holder 13 Revised:1/31/18 720599.1 named." Language such as, "endeavor to" mail and "but failure to mail such notice shall impose no obligation or liability of any kind upon the company, its agents or representative" is not acceptable and must be crossed out. 4. Both the Workers' Compensation and Employers' Liability policies shall contain the insurer's waiver of subrogation in favor of City, its elected officials, officers, employees, agents, and volunteers. In addition to the endorsements listed above, the City of Palm Springs shall be named the certificate holder on the policies. All certificates of insurance and endorsements are to be received and approved by the City before work commences. All certificates of insurance must be authorized by a person with authority to bind coverage, whether that is the authorized agent/broker or insurance underwriter. Failure to obtain the required documents prior to the commencement of work shall not waive the Contractor's obligation to provide them. 7. Deductibles and Self-Insured Retentions. Any deductibles or self-insured retentions must be declared to and approved by the City prior to commencing any work or services under this Agreement. At the option of the City, either (1) the insurer shall reduce or eliminate such deductibles or self-insured retentions with respect to the City, its elected officials, officers, employees, agents, and volunteers; or (2) Contractor shall procure a bond guaranteeing payment of losses and related investigations, claim administration, and defense expenses. Certificates of Insurance must include evidence of the amount of any deductible or self-insured retention under the policy. Contractor guarantees payment of all deductibles and self-insured retentions. 8. Severability of Interests (Separation of Insureds). This insurance applies separately to each insured against whom claim is made or suit is brought except with respect to the limits of the insurer's liability. 14 Revised:1/31118 720599.1 EXHIBIT "C" I certify that in the performance of work for which this agreement is issued, I SHALL NOT EMPLOY ANY PERSON, in any manner so as to become subject to the worker's compensation laws of California, and agree that if I should become subject to worker's compensation provision of Section 3700 of the Labor Code, I shall for with comply with those provisions. All work shall be performed from contractor office in Gilbert Arizona and I certify that I will not perform any work, nor will there be any motor vehicles used in Palm Springs, California. These insurance policies will not be provided for this consulting services agreement. Date: i2oll? By: Gary Adams, President 15 Revised:1/31/18 720599.1 ADAMS-2 ACOR®' CERTIFICATE OF LIABILITY INSURANCE DATE(Iv1MIDDNYYY) 04/10/2019 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER,AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the poiicy(les) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder In lieu of such endorsement(s). PRODUCER 480-948-7838 CONTACT Cheri Preas NAME: NFP Property &Casualty PHONE 480-948-7838 FAX 480-948-1707 FKA Low&Johnson, Inc. (AfC,No,Ext): (Pic,No): 8201 N. Hayden Road FA ,A&ss:cher).preas@nfp.com Scottsdale, AZ 85258 Jamie S.Low,CPCU,CIC INSURERS AFFORDING COVERAGE NAIC# INSURERA:Auto-Owners Insurance 18988 INSURED INSURER B: The Adams Companies, LLC Gary Adams INSURER C: 2602 S. Jacob Street Gilbert,AZ 85295 INSURER D: INSURER E: INSURER F: COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT'TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. INSR TYPE OF INSURANCE ADDL SUB POLICY NUMBER POLICY EFF POLICY EXP LIMITS L SD MMIDD MIDD A X COMMERCIAL GENERAL LIABILITY EACH OCCURRENCE $ 1,000,000 CLAIMS-MADE [�]OCCUR X 45114602 03/2212019 03/22/2020 DAMAGE TO RENTED $ 300,000 MED EXP(Any oneperson) S 10,000 PERSONAL&ADV INJURY S excluded GEN'L AGGREGATE LIMIT APPLIES PER: GENERAL AGGREGATE S 2,000,000 pqPOLICY Ejg& LOC PRODUCTS-COMP/OP AGG $ 2,000,000 OTHER. S A AUTOMOBILE LIABILITY C OtviBINED SINGLE LIMIT $ 1,000,000 ANY AUTO 45114602 03/22/2019 03/22/2020 BODILY INJURY Perperson) $ OWNED SCHEDULED AUTOS ONLY AUTOS p BODILY INJURY Per accident) $ X AUTOS ONLY X AUTOS ONL Peer ecccidenQAMAGE $ $ UMBRELLA LIAB OCCUR EACH OCCURRENCE S EXCESS LIAB CLAIMS-MADE AGGREGATE DED I I RETENTION $ $ WORKERS COMPENSATION PER OTH- AND EMPLOYERS'LIABILITY Y f N STATUTE ER ANY PROPRIETORrPARTNERIEXECUTIVE ❑ NIA E.L.EACH ACCIDENT FFICERlM M R EXCLUDED? andatory n ) E.L.DISEASE-EA EMPLOYEE S If yes,describe under DESCRIPTION OF OPERATIONS below E.L.DISEASE-POLICY LIMIT B Professional Liab PHSD1430556 04/29/2019 04/29/2020 ea claim 1,000,000 retrodate:4129109 2500 RETENTION aggregate 2,000,000 DESCRIPTION OF OPERATIONS I LOCATIONS I VEHICLES (ACORD 101,Additional Remarks Schedule,may be attached If more space Is required) . The City of Palm Springs, its officials,employees, and agents are named as an additional insured for any and all work performed with the City" as respects to general liability coverage. CERTIFICATE HOLDER CANCELLATION SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. Palm Springs International Airport Mark Jucht Airport Admin. Mngr AUTHORIZED REPRESENTATIVE 3400 E.Tahquitz Canyon Way Palm Springs.CA 92262 ACORD 25(2016/03) O 1988-2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD PUBLIC INTEGRITY APPLICANT DISCLOSURE Name(Print last, first,middle initian E-mail Address �ka_OA Position/Title Address i Work Phone: orting Status Cell Phone: / ew isclosure: Update: Every applicant that is not an individual natural person, or comprised exclusively of natural persons with no outside investors, must disclose to the City the identity of each natural person who holds or occupies a significant position with respect to that applicant entity or any entity that owns.an interest or derives profits with respect to the applicant entity, i.e., a sub-entity: In addition, every applicant must disclose to the City the identity of.each owner or investor who has both of the following: (i) an ownership interest in the applicant entity with.a value of two thousand dollars ($2,000.00) or more, -and (ii) a material financial relationship with any official who has the opportunity to vote upon; or advocate for a particular result or outcome with respect to the application in question. A"significant position"shall be defined as follows: i. Officers,and Directors (in the,instance of a corporation); ii. Members and Managers (in the instance of limited liability company); or iii. Trustees and other Fiduciaries (in the.instance of a trust or another organization). A "material financial relationship" shall be defined as a relationship .between an owner or investor on one hand, and a voting. or potentially advocating official on the other hand, whereby the official has an interest,in the outcome of the City's action upon the application in question arising from or related to any of the following: 1. Any business that the owner oe investor in the applicant and the official do together during the year prior to.the filing of the application.; 2. Any income that the official has earned from the owner or investor in the applicant entity during the year prior to the filing of application; 3. One or more gifts, that the owner or investor in the applicant has given to the official during a year prior to the filing of the application with a total of more than fifty dollars.; 4. Any money or value that the official will or might reasonably be anticipated to gain or lose, based upon the ownership.interest of the owner or investor in the applicant entity, in relation to the outcome of the City's action upon the application. Organization/Type of organization:- Ownership Interest: Position: No (include the address, city and state where the longer the organization is located) 'held: hNaMg 2(v02 S.ic.cob S+ IGtii}aRA n2- g�aHSJ UC[sU�q eSlG��k�J 3 4 5. I DECLARE UNDER PENALTY OF PERJURY UNDER THE.LAWS OF THE STATE OF CALIFORNIA THAT THE FOREGOING IS TRUE AND.CORRECT: Signature of Disclosing Pa ate On the basis of information contained in this,report, I conclude that the filer is in compliance with Palm Springs Municipal Code Section 2.60, except as noted in the "comments" box below. Comments: Signature and Title of Agency's Final Reviewing Official CONTRACT SERVICES AGREEMENT The Adams Company THIS AGREEMENT FOR CONTRACT SERVICES ("Agreement") is made and entered into on September 22, 2017, by and between the City of Palm Springs, a California charter city and municipal corporation ("City"), and The Adams Company, a Limited Liability Company, ("Contractor"). City and Contractor are individually referred to as "Party" and are collectively referred to as the"Parties". RECITALS A. City requires the services of an Independent Fee Consultant, for Design Service fees for Airport Improvement Projects, ("Project"). B. Contractor has submitted to City a proposal to provide independent fee consulting,to City under the terms of this Agreement. C. Based on its experience, education, training, and reputation, Contractor is qualified and desires to provide the necessary services to City for the Project. D. City desires to retain the services of Contractor for the Project. In consideration of these promises and mutual agreements, City agrees as follows: AGREEMENT 1. CONTRACTOR SERVICES 1.1 Scone of Services. In compliance with all terms and conditions of this Agreement, Contractor shall provide Independent Fee Consulting, services to City as described in the Scope of Services/Work attached to this Agreement as Exhibit "A" and incorporated by reference (the "services" or "work"). Exhibit "A" includes the agreed upon schedule of performance and the schedule of fees. Contractor warrants that all services and work shall be performed in a competent, professional, and satisfactory manner consistent with prevailing industry standards. In the event of any inconsistency between the terms contained in the Scope of Services/Work and the terms set forth in this Agreement, the terms set forth in this Agreement shall govern. 1.2 Compliance with Law. Contractor services rendered under this Agreement shall comply with all applicable federal, state, and local laws, statutes and ordinances and all lawful orders, rules, and regulations. 1.3 Licenses and Permits. Contractor shall obtain at its sole cost and expense such licenses, permits, and approvals as may be required by law for the performance of the services required by this Agreement. t 7205941 ORIGINAL BID Revised 12/9115 IND/ORAGREEMENT 1.4 Familiarity with Work. By executing this Agreement, Contractor warrants that it has carefully considered how the work should be performed and fully understands the facilities, difficulties, and restrictions attending performance of the work under this Agreement. 2. TIME FOR COMPLETION The time for completion of the services to be performed by Contractor is an essential condition of this Agreement. Contractor shall prosecute regularly and diligently the work of this Agreement according to the agreed upon schedule of performance set forth in Exhibit "A." Contractor shall not be accountable for delays in the progress of its work caused by any condition beyond its control and without the fault or negligence of Contractor. Delays shall not entitle Contractor to any additional compensation regardless of the party responsible for the delay. 3. COMPENSATION OF CONTRACTOR 3.1 Compensation of Contractor. Contractor shall be compensated and reimbursed for the services rendered under this Agreement in accordance with the schedule of fees set forth in Exhibit"A". The total amount of Compensation shall not exceed $4,800.00. 3.2 Method of Payment. In any month in which Contractor wishes to receive payment, Contractor shall submit to City an invoice for services rendered prior to the date of the invoice, no later than the first working day of such month, in the form approved by City's finance director. Payments shall be based on the hourly rates set forth in Exhibit "A" for authorized services performed. City shall pay Contractor for all expenses stated in the invoice that are approved by City and consistent with this Agreement, within thirty (30) days of receipt of Contractor's invoice. 3.3 Chances. In the event any change or changes in the Scope of Services/Work is requested by City, Parties shall execute a written amendment to this Agreement, specifying all proposed amendments, including, but not limited to, any additional fees. An amendment may be entered into: A. To provide for revisions or modifications to documents, work product, or work, when required by the enactment or revision of any subsequent law; or B. To provide for additional services not included in this Agreement or not customarily furnished in accordance with generally accepted practice in Contractor's profession. 3.4 Appropriations. This Agreement is subject to, and contingent upon, funds being appropriated by the City Council of City for each fiscal year. If such appropriations are not made, this Agreement shall automatically terminate without penalty to City. 4. PERFORMANCE SCHEDULE 4.1 Time of Essence. Time is of the essence in the performance of this Agreement. 2 Revised:1219115 i20599.1 4.2 Schedule of Performance. All services rendered under this Agreement shall be performed under the agreed upon schedule of performance set forth in Exhibit "A." Any time period extension must be approved in writing by the Contract Officer. 4.3 Force Maieure. The time for performance of services to be rendered under this Agreement may be extended because of any delays due to unforeseeable causes beyond the control and without the fault or negligence of Contractor, if Contractor notifies the Contract Officer within ten (10) days of the commencement of such condition. Unforeseeable causes include, but are not limited to, acts of God or of a public enemy, acts of the government, fires, earthquakes, floods, epidemic, quarantine restrictions, riots, strikes, freight embargoes, and unusually severe weather. After Contractor notification, the Contract Officer shall investigate the facts and the extent of any necessary delay, and extend the time for performing the services for the period of the enforced delay when and if, in the Contract Officer's judgment, such delay is justified. The Contract Officer's determination shall be final and conclusive upon the parties to this Agreement. 4.4 Term. Unless earlier terminated in accordance with Section 4.5 of this Agreement, this Agreement shall continue in full force and effect for a period of ninety (90) days, commencing on September 29, 2016, and ending on December 31, 2016, unless extended by mutual written agreement of the parties. 4.5 Termination Prior to Expiration of Term. City may terminate this Agreement at any time, with or without cause, upon thirty (30) days written notice to Contractor. Where termination is due to the fault of Contractor and constitutes an immediate danger to health, safety, and general welfare, the period of notice shall be such shorter time as may be determined by the City. Upon receipt of the notice of termination, Contractor shall immediately cease all services except such as may be specifically approved by the Contract Officer. Contractor shall be entitled to compensation for all services rendered prior to receipt of the notice of termination and for any services authorized by the Contract Officer after such notice. Contractor may terminate this Agreement, with or without cause, upon thirty (30) days written notice to City. 5. COORDINATION OF WORK 5.1 Representative of Contractor. The following principal of Contractor is designated as being the principal and representative of Contractor authorized to act and make all decisions in its behalf with respect to the specified services and work: Gary Adams, President. It is expressly understood that the experience, knowledge, education, capability, and reputation of the foregoing principal is a substantial inducement for City to enter into this Agreement. Therefore, the foregoing principal shall be responsible during the term of this Agreement for directing all activities of Contractor and devoting sufficient time to personally supervise the services under this Agreement. The foregoing principal may not be changed by Contractor without prior written approval of the Contract Officer. 5.2 Contract Officer. The Contract Officer shall be the City Manager or his/her designee ("Contract Officer"), Contractor shall be responsible for keeping the Contract Officer fully informed of the progress of the performance of the services. Contractor shall refer any 3 Reviwd:1219/15 720599 1 decisions that must be made by City to the Contract Officer. Unless otherwise specified, any approval of City shall mean the approval of the Contract Officer. 5.3 Prohibition Against Subcontracting or Assignment. The experience, knowledge, education, capability, and reputation of Contractor, its principals and employees, were a substantial inducement for City to enter into this Agreement. Therefore, Contractor shall not contract with any other individual or entity to perform any services required under this Agreement without the City's express written approval. In addition, neither this Agreement nor any interest may be assigned or transferred, voluntarily or by operation of law, without the prior written approval of City. 5.4 Independent Contractor. Neither City nor any of its employees shall have any control over the manner, mode, or means by which Contractor, its agents or employees, perform the services required, except as otherwise specified. Contractor shall perform all required services as an independent contractor of City and shall not be an employee of City and shall remain at all times as to City a wholly independent contractor with only such obligations as are consistent with that role; however, City shall have the right to review Contractor's work product, result, and advice. Contractor shall not at any time or in any manner represent that it or any of its agents or employees are agents or employees of City. 5.5 Personnel. Contractor agrees to assign the following individuals to perform the services in this Agreement. Contractor shall not alter the assignment of the following personnel without the prior written approval of the Contract Officer. Acting through the City Manager, the City shall have the unrestricted right to order the removal of any personnel assigned by Contractor by providing written notice to Contractor. Name: Title: Gary Adams President 6. INSURANCE Contractor shall procure and maintain, at its sole cost and expense, policies of insurance as set forth in the attached Exhibit "C", incorporated herein by reference. 7. INDEMNIFICATION. 7.1 Indemnification. To the fullest extent permitted by law, Contractor shall defend (at Contractor's sole cost and expense), indemnify, protect, and hold harmless City, its elected officials, officers, employees, agents, and volunteers (collectively the "Indemnified Parties"), from and against any and all liabilities, actions, suits, claims, demands, losses, costs, judgments, arbitration awards, settlements, damages, demands, orders, penalties, and expenses including legal costs and attorney fees (collectively "Claims"), including but not limited to Claims arising from injuries to or death of persons (Contractor's employees included), for damage to property, including property owned by City, from any violation of any federal, state, 4 Revised:1219/15 720599.1 or local law or ordinance, and from errors and omissions committed by Contractor, its officers, employees, representatives, and agents, that arise out of or relate to Contractor's performance under this Agreement. This indemnification clause excludes Claims arising from the sole negligence or willful misconduct of the City, its elected officials, officers, employees, agents, and volunteers. Under no circumstances shall the insurance requirements and limits set forth in this Agreement be construed to limit Contractor's indemnification obligation or other liability under this Agreement. Contractor's indemnification obligation shall survive the expiration or earlier termination of this Agreement until all actions against the Indemnified Parties for such matters indemnified are fully and finally barred by the applicable statute of limitations or, if an action is timely filed, until such action is final. This provision is intended for the benefit of third party Indemnified Parties not otherwise a party to this Agreement. 7.2 Design Professional Services Indemnification and Reimbursement. If the Agreement is determined to be a "design professional services agreement" and Contractor is a "design professional" under California Civil Code Section 2782.8, then: A. To the fullest extent permitted by law, Contractor shall indemnify, defend (at Contractor's sole cost and expense), protect and hold harmless City and its elected officials, officers, employees, agents and volunteers and all other public agencies whose approval of the project is required, (individually "Indemnified Party"; collectively "Indemnified Parties") against any and all liabilities, claims,judgments, arbitration awards, settlements, costs, demands, orders and penalties (collectively "Claims"), including but not limited to Claims arising from injuries or death of persons (Contractor's employees included) and damage to property, which Claims arise out of, pertain to, or are related to the negligence, recklessness or willful misconduct of Contractor, its agents, employees, or subcontractors, or arise from Contractor's negligent, reckless or willful performance of or failure to perform any term, provision, covenant or condition of this Agreement ("Indemnified Claims"), but Contractor's liability for Indemnified Claims shall be reduced to the extent such Claims arise from the negligence, recklessness or willful misconduct of the City and its elected officials, officers, employees, agents and volunteers. B. The Contractor shall require all non-design-professional sub-contractors, used or sub-contracted by Contractor to perform the Services or Work required under this Agreement, to execute an Indemnification Agreement adopting the indemnity provisions in sub- section 7.1 in favor of the Indemnified Parties. In addition, Contractor shall require all non- design-professional sub-contractors, used or sub-contracted by Contractor to perform the Services or Work required under this Agreement, to obtain insurance that is consistent with the Insurance provisions as set forth in this Agreement, as well as any other insurance that may be required by Contract Officer. 8. RECORDS AND REPORTS 8.1 Reports. Contractor shall periodically prepare and submit to the Contract Officer reports concerning the performance of the services required by this Agreement, or as the Contract Officer shall require. 5 Revised: 12/9115 7205'N 8.2 Records. Contractor shall keep complete, accurate, and detailed accounts of all time, costs, expenses, and expenditures pertaining in any way to this Agreement. Contractor shall keep such books and records as shall be necessary to properly perform the services required by this Agreement and enable the Contract Officer to evaluate the performance of such services. The Contract Officer shall have full and free access to such books and records at all reasonable times, including the right to inspect, copy, audit, and make records and transcripts from such records. 8.3 Ownership of Documents. All drawings, specifications, reports, records, documents, and other materials prepared by Contractor in the performance of this Agreement shall be the property of City. Contractor shall deliver all above-referenced documents to City upon request of the Contract Officer or upon the termination of this Agreement. Contractor shall have no claim for further employment or additional compensation as a result of the exercise by City of its full rights or ownership of the documents and materials. Contractor may retain copies of such documents for Contractor's own use. Contractor shall have an unrestricted right to use the concepts embodied in such documents. 8.4 Release of Documents. All drawings, specifications, reports, records, documents, and other materials prepared by Contractor in the performance of services under this Agreement shall not be released publicly without the prior written approval of the Contract Officer. 8.5 Cost Records. Contractor shall maintain all books, documents, papers, employee time sheets, accounting records, and other evidence pertaining to costs incurred while performing under this Agreement. Contractor shall make such materials available at its offices at all reasonable times during the term of this Agreement and for three (3) years from the date of final payment for inspection by City and copies shall be promptly furnished to City upon request. 9. ENFORCEMENT OF AGREEMENT 9.1 California Law. This Agreement shall be construed and interpreted both as to validity and to performance of the parties in accordance with the laws of the State of California. Legal actions concerning any dispute, claim, or matter arising out of or in relation to this Agreement shall be instituted in the Superior Court of the County of Riverside, State of California, or any other appropriate court in such county, and Contractor covenants and agrees to submit to the personal jurisdiction of such court in the event of such action. 9.2 Interpretation. This Agreement shall be construed as a whole according to its fair language and common meaning to achieve the objectives and purposes of the Parties. The terms of this Agreement are contractual and the result of negotiation between the Parties. Accordingly, any rule of construction of contracts (including, without limitation, California Civil Code Section 1654) that ambiguities are to be construed against the drafting party, shall not be employed in the interpretation of this Agreement. The caption headings of the various sections and paragraphs of this Agreement are for convenience and identification purposes only and shall not be deemed to limit, expand, or define the contents of the respective sections or paragraphs. 6 Revised: 1219115 720 99.1 9.3 Waiver. No delay or omission in the exercise of any right or remedy of a non- defaulting party on any default shall impair such right or remedy or be construed as a waiver. No consent or approval of City shall be deemed to waive or render unnecessary City's consent to or approval of any subsequent act of Contractor. Any waiver by either party of any default must be in writing. No such waiver shall be a waiver of any other default concerning the same or any other provision of this Agreement. 9.4 Rights and Remedies are Cumulative. Except with respect to rights and remedies expressly declared to be exclusive in this Agreement, the rights and remedies of the parties are cumulative. The exercise by either party of one or more of such rights or remedies shall not preclude the exercise by it, at the same or different times, of any other rights or remedies for the same default or any other default by the other party. 9.5 Legal Action. In addition to any other rights or remedies, either party may take legal action, in law or in equity, to cure, correct, or remedy any default, to recover damages for any default, to compel specific performance of this Agreement, to obtain injunctive relief, a declaratory judgment, or any other remedy consistent with the purposes of this Agreement. 10. CITY OFFICERS AND EMPLOYEES: NON-DISCRIMINATION 10.1 Non-Liability of City Officers and Employees. No officer or employee of City shall be personally liable to the Contractor, or any successor-in-interest, in the event of any default or breach by City or for any amount which may become due to the Contractor or its successor, or for breach of any obligation of the terms of this Agreement. 10.2 Conflict of Interest. Contractor acknowledges that no officer or employee of the City has or shall have any direct or indirect financial interest in this Agreement nor shall Contractor enter into any agreement of any kind with any such officer or employee during the term of this Agreement and for one year thereafter. Contractor warrants that Contractor has not paid or given, and will not pay or give, any third party any money or other consideration in exchange for obtaining this Agreement. 10.3 Covenant Against Discrimination. Consultant covenants that, by and for itself, its heirs, executors, assigns, and all persons claiming under or through them, that there shall be no discrimination or segregation in the performance of or in connection with this Agreement regarding any person or group of persons on account of race, color, creed, religion, sex, marital status, disability, sexual orientation, gender identity, national origin, physical or mental disability, medical condition, or ancestry. It. MISCELLANEOUS PROVISIONS 11.1 Notice. Any notice, demand, request, consent, approval, or communication that either party desires, or is required to give to the other party or any other person shall be in writing and either served personally or sent by pre-paid, first-class mail to the address set forth below. Notice shall be deemed communicated seventy-two (72) hours from the time of mailing if mailed as provided in this Section. Either party may change its address by notifying the other party of the change of address in writing. 7 Revised 1219116 '20599 1 To City: City of Palm Springs Attention: City Manager/City Clerk 3200 E. Tahquitz Canyon Way Palm Springs, California 92262 Palm Springs International Airport 3400 E. Tahquitz Canyon Way Palm Springs, California 92262 To Contractor: The Adams Company 1508 W. Tara Drive Gilbert, AZ 85233 11.2 Integrated Agreement. This Agreement contains all of the agreements of the parties and supersedes all other written agreements. 11.3 Amendment. No amendments or other modifications of this Agreement shall be binding unless through written agreement by all Parties. 11.4 Severability. Whenever possible, each provision of this Agreement shall be interpreted in such a manner as to be effective and valid under applicable law. In the event that any one or more of the phrases, sentences, clauses, paragraphs, or sections contained in this Agreement shall be declared invalid or unenforceable by valid judgment or decree of a court of competent jurisdiction, such invalidity or unenforceability shall not affect any of the remaining phrases, sentences, clauses, paragraphs, or sections of this Agreement, which shall be interpreted to carry out the intent of the parties. 11.5 Successors in Interest. This Agreement shall be binding upon and inure to the benefit of the Parties' successors and assignees. 11.6 Third Party Beneficiary. Except as may be expressly provided for in this Agreement, nothing contained in this Agreement is intended to confer, nor shall this Agreement be construed as conferring, any rights, including, without limitation, any rights as a third-party beneficiary or otherwise, upon any entity or person not a party to this Agreement. 11.7 Recitals. The above-referenced Recitals are hereby incorporated into the Agreement as though fully set forth in this Agreement and each Party acknowledges and agrees that such Party is bound, for purposes of this Agreement, by the same. 11.8 Authority. The persons executing this Agreement on behalf of the Parties warrant that they are duly authorized to execute this Agreement on behalf of Parties and that by so executing this Agreement the Parties are formally bound to the provisions of this Agreement. 8 Revwd:12/9/15 7120599,1 IN WITNESS WHEREOF, the Parties have executed this Agreement as of the dates stated below. "CITY" City of Palm Springs Date: 1a 1•lb By: David H. Ready City Manager APPROVELt BY CITY MMIAGER APPROVED AS TO FORM: ATTEST By: &a By: \L"AD Dougl4s C. Holland, lhetngsen- City Attorney k1WQty Clerk "CONTRACTOR" The Adams Company Date: �( 2 By : . G A44mis President Date: ame) (secretary) 9 Revised: 12/9115 720599.1 CALAPOWM AL.L44NO MACKNONLEDGIMM CnnLCODE.§tlao A mtay pblc or odw mica ampYeilg alb an0irab mmmmifi cr*the idrilily of the ndiidd ahe aiped the docunwt1Dmdwdn Vws astiicds ialechsd rdro*mvuftki amrwlLavmkWoftaducum iL stale d C.ibn:a P P 1 Z ON ) Cwdy of A.V 1 LQ Cl✓ On D1b None and Tdo of thd Ofioer PrN appeared who Proved to me an the base of adeafaclay awfancs to be the personN noes no meo Were srbecrbed b do within iahunnert and atloaabdped to me that hrrMMhey Traded the same in h'Nha/tlnei audxw ad cspw4(Pr1.and Od by hieRwAlri aipWrreM on tlr istrumetihs person(a), or the enmity upon behsi of rttch the perso nN acted.executed Mix iehurevmL I osnity under PBMLTY OF PE WJRY under the here of the ffide of CaManva Dud the foregang paragraph is true,rid corrset. L WYRYBKOVM VWWM and ofnal aeaL StMe U .Hc:OPACOUNTY a,_L Ili My M=10jon rfas M MUM 10,70g0 sigahuaW Nobry pubic Pbca Notary Sod Above OrnOME Thar Uss section a optiond Mr ffdbrrrshcrr can filer alteration of On document or krddrt reeCachmrt of H&form to an uidrded doaaiad. DesaWbo n at Attached Doamrnt Tills or Type of Doaenarrt Document Ddc Number of Paget sign.r(s) OIMr Than Named Above: Cspackyoso Claimed by Sgnr(a) signer's Nina: 9gnara Pimrrr ❑Corporale Officer—Ttle{ai: ❑CorpasY Officer—Tine; ❑Partner— O L mwlsd ❑General ❑Partner— O limited ❑General ❑Irdrvidai ❑Attorney in Fad ❑hsSvidsd ❑Atkwrwy in Fact ❑Trusbe ❑Guardian or Corervalor ❑Trustee ❑Guardian or Coreemvdor ❑OMar-. ❑Ober. Sign Is RepsaribW 9ga IS Rspaerh ng: BZ014 Nefimaf Nobry Arocstirr•rrr.N�aneriodyag•tAgals NtITAHy(1-am-aTB-eBZ)) i.n rim 10 Revised 12f9/15 720599.1 September21, 2016 EXHIBIT A PALM SPRINGS INTERNATIONAL AIRPORT INDEPENDENT FEE ESTIMATE ENGINEERING DESIGN, BID AND CONSTRUCTION ADMINISTRATION SERVICES FOR RENTAL CAR FACILITY EXPANSION PROJECT SCOPE OF WORK AND FEE ESTIMATE Introduction: The City of Palm Springs will soon begin a project to design and construct an expansion to the current rental car facility at the Palm Springs International Airport. The location for the rental car facility is on the north end of the terminal building currently used for open lot rental car operations, and by the Customs and Border Protection building adjacent further west. Based on the recent PSP Airport Master Plan Update, on-airport rental car operations are constrained based on the limited size of the open lot. The Master Plan identifies that the increase in passenger volume and rental car activity will overburden existing facilities and adjacent roadways and impact rental car operating efficiencies. Based on projected passenger volumes, the Master Plan recommends the expansion of the on-airport rental car facilities in the area adjacent to the main terminals north end. Conceptual design options earlier prepared by WSP/PB, determined that the available site area has the capacity for a new customer service building (CSB) and ready/return stalls with vehicle servicing and storage in a multi-level garage providing storage and fueling and maintenance. Including these maintenance activities in this footprint will considerably reduce the amount of vehicle shuttling activity that impacts abutting neighborhoods and constrains public roadways. In order to complete the design project, the City of Palm Springs, as owner of the Palm Springs International Airport, is about to enter into contract fee negotiations with the airport engineering consultant firm of Parsons Brinkerhoff(Consultant), after selecting them based on qualifications. In accordance with FAA consultant selection guidelines, the City of Palm Springs is requesting TAC to submit a proposal and work scope for an Independent Fee Estimate (IFE) on the scope of services to be provided by the selected consultant. The scope of services that TAC proposes for the IFE is as follows: ]� Revised:12/9115 7N599.1 ® Page 2 September 21, 2016 Task 1: Develop Independent Fee Estimate a) TAC will review the scope of services developed by the Consultant(s) and the Palm Springs International Airport. The scope will be reviewed task-by-task to ensure that all required services for the Project, based on TAC's professional judgment, are thoroughly addressed in accordance with FAA guidelines for projects of this type, including the most recent FAA Advisory Circulars. b)TAC will provide to the Palm Springs International Airport a cost breakdown structure and cost estimate by task. The cost breakdown structure will consider the level of staff skills necessary to effectively complete each task, staff man-hours, and any other cost considerations, i.e. direct costs which may be needed for the acquisition of data or travel-related expenses. This cost breakdown will be similar in format to Appendix E of AC 150/5100-14E Change 1. c) TAC will provide a detailed cover letter with an explanation of costs and a separate comprehensive spreadsheet of the independent fee estimate to the Palm Springs International Airport, in electronic format(and hard copy if requested). Fee: Our fee for the proposed scope of services is a lump sum fee of$4,800.00. All work shall be completed within 7 calendar days from the Notice to Proceed. In order to meet the completion date, TAC will require: 1) a written notice to proceed and 2)the receipt of all necessary review materials including the following: a) The consultant's list of proposed subcontractors and subcontractors proposed work scope; and b) Consultant's proposed scope of work, as approved by the FAA. Billing/Contact Information: The Adams Companies LLC Palm Springs Business License#20016856. TAC's billing address is: The Adams Companies, LLC 1508 W. Tara Dr. Gilbert,AZ 85233 602- 708-1177 12 Rwwd:1219/15 720599A Exhibit `B" INSURANCE 1. Procurement and Maintenance of Insurance. Contractor shall procure and maintain public liability and property damage insurance against all claims for injuries against persons or damages to property resulting from Contractor's performance under this Agreement. Contractor shall procure and maintain all insurance at its sole cost and expense, in a form and content satisfactory to the City, and submit concurrently with its execution of this Agreement. Contractor shall also carry workers' compensation insurance in accordance with California workers' compensation laws. Such insurance shall be kept in full force and effect during the term of this Agreement, including any extensions. Such insurance shall not be cancelable without thirty (30) days advance written notice to City of any proposed cancellation. Certificates of insurance evidencing the foregoing and designating the City, its elected officials, officers, employees, agents, and volunteers as additional named insureds by original endorsement shall be delivered to and approved by City prior to commencement of services. The procuring of such insurance and the delivery of policies, certificates, and endorsements evidencing the same shall not be construed as a limitation of Contractor's obligation to indemnify City, its elected officials, officers, agents, employees, and volunteers. 2. Minimum Scone of Insurance. The minimum amount of insurance required under this Agreement shall be as follows: 1. Comprehensive general liability and personal injury with limits of at least one million dollars ($1,000,000.00) combined single limit coverage per occurrence and two million dollars ($2,000,000) general aggregate; 2. Automobile liability insurance with limits of at least one million dollars ($1,000,000.00)per occurrence; 3. Professional liability (errors and omissions) insurance with limits of at least one million dollars ($1,000,000.00) per occurrence and two million dollars ($2,000,000) annual aggregate is: X required is not required; 4. Workers' Compensation insurance in the statutory amount as required by the State of California and Employer's Liability Insurance with limits of at least one million dollars $1 million per occurrence. If Contractor has no employees, Contractor shall complete the City's Request for Waiver of Workers' Compensation Insurance Requirement form. 3. Primary Insurance. For any claims related to this Agreement, Contractor's insurance coverage shall be primary with respect to the City and its respective elected officials, 13 Revised:12015 720599.1 officers, employees, agents, and volunteers. Any insurance or self-insurance maintained by City and its respective elected officials, officers, employees, agents, and volunteers shall be in excess of Contractor's insurance and shall not contribute with it. For Workers' Compensation and Employer's Liability Insurance only, the insurer shall waive all rights of subrogation and contribution it may have against City, its elected officials, officers, employees, agents, and volunteers. 4. Errors and Omissions Coverage. If Errors & Omissions Insurance is required, and if Contractor provides claims made professional liability insurance, Contractor shall also agree in writing either (1) to purchase tail insurance in the amount required by this Agreement to cover claims made within three years of the completion of Contractor's services under this Agreement, or (2) to maintain professional liability insurance coverage with the same carrier in the amount required by this Agreement for at least three years after completion of Contractor's services under this Agreement. Contractor shall also be required to provide evidence to City of the purchase of the required tail insurance or continuation of the professional liability policy. 5. Sufficiency of Insurers. Insurance required in this Agreement shall be provided by authorized insurers in good standing with the State of California. Coverage shall be provided by insurers admitted in the State of California with an A.M. Best's Key Rating of B++, Class VII, or better, unless otherwise acceptable to the City. 6. Verification of Coverage. Contractor shall furnish City with both certificates of insurance and endorsements, including additional insured endorsements, effecting all of the coverages required by this Agreement. The certificates and endorsements are to be signed by a person authorized by that insurer to bind coverage on its behalf. All proof of insurance is to be received and approved by the City before work commences. City reserves the right to require Contractor's insurers to provide complete, certified copies of all required insurance policies at any time. Additional insured endorsements are not required for Errors and Omissions and Workers' Compensation policies. Verification of Insurance coverage may be provided by: (1) an approved General and/or Auto Liability Endorsement Form for the City of Palm Springs or(2) an acceptable Certificate of Liability Insurance Coverage with an approved Additional Insured Endorsement with the following endorsements stated on the certificate: 1. "The City of Palm Springs, its officials, employees, and agents are named as an additional insured... " ("as respects City of Palm Springs Contract Na" or 'for any and all work performed with the City"may be included in this statement). 2. "This insurance is primary and non-contributory over any insurance or self- insurance the City may have..." ("as respects City of Palm Springs Contract No. " or 'for any and all workperformed with the City" may be included in this statement). 3. "Should any of the above described policies be canceled before the expiration date thereof, the issuing company will mail 30 days written notice to the Certificate Holder named." Language such as, "endeavor to" mail and "but failure to mail such notice shall impose 14 Revised:12/9115 720599.1 no obligation or liability of any kind upon the company, its agents or representative" is not acceptable and must be crossed out. 4. Both the Workers' Compensation and Employers' Liability policies shall contain the insurer's waiver of subrogation in favor of City, its elected officials, officers, employees, agents, and volunteers. In addition to the endorsements listed above, the City of Palm Springs shall be named the certificate holder on the policies. All certificates of insurance and endorsements are to be received and approved by the City before work commences. All certificates of insurance must be authorized by a person with authority to bind coverage, whether that is the authorized agent/broker or insurance underwriter. Failure to obtain the required documents prior to the commencement of work shall not waive the Contractor's obligation to provide them. 7. Deductibles and Self-Insured Retentions. Any deductibles or self-insured retentions must be declared to and approved by the City prior to commencing any work or services under this Agreement. At the option of the City, either (1) the insurer shall reduce or eliminate such deductibles or self-insured retentions with respect to the City, its elected officials, officers, employees, agents, and volunteers; or (2) Contractor shall procure a bond guaranteeing payment of losses and related investigations, claim administration, and defense expenses. Certificates of Insurance must include evidence of the amount of any deductible or self-insured retention under the policy. Contractor guarantees payment of all deductibles and self-insured retentions. 8. Severability of Interests (Separation of Insureds). This insurance applies separately to each insured against whom claim is made or suit is brought except with respect to the limits of the insurer's liability. 15 Revised:12/9115 720i99A EXHIBIT "C" I certify that in the performance of work for which this agreement is issued, I SHALL NOT EMPLOY ANY PERSON, in any manner so as to become subject to the worker's compensation laws of California, and agree that if I should become subject to worker's compensation provision of Section 3700 of the Labor Code, I shall for with comply with those provisions. All work shall be performed from mu office in Gilbert Arizona and 1 certify that I will not perform any work, nor will there be any motor vehicles used in Palm Springs, California. These insurance policies will not be provided for this consulting services agreement. Date: B y: _ `— Gary��, President 16 Revised:1219/15 720599 1 CONSULTING SERVICES AGREEMENT The Adams Company THIS AGREEMENT FOR CONSULTING SERVICES ("Agreement") is made and entered into on September 30, 2014, by and between the City of Palm Springs, a California charter city and municipal corporation ("City"), and The Adams Company, a Limited Liability Company, ("Consultant"). City and Consultant are individually referred to as "Party" and are collectively referred to as the "Parties". RECITALS A. City requires the services of an Independent Fee Consultant, for Design and Construction Management Services for Airport Improvement Projects, ("Project"). B. Consultant has submitted to City a proposal to provide independent fee consulting,to City under the terms of this Agreement. C. Based on its experience, education, training, and reputation, Consultant is qualified and desires to provide the necessary services to City for the Project. D. City desires to retain the services of Consultant for the Project. In consideration of these promises and mutual agreements, City agrees as follows: AGREEMENT 1. CONSULTANT SERVICES 1.1 Scone of Services. In compliance with all terms and conditions of this Agreement, Consultant shall provide Independent Fee Consulting services to City as described in the Scope of Services/Work attached to this Agreement as Exhibit "A" and incorporated by reference (the "services" or "work"). Exhibit "A" includes the agreed upon schedule of performance and the schedule of fees. Consultant warrants that all services and work shall be performed in a competent, professional, and satisfactory manner consistent with prevailing industry standards. In the event of any inconsistency between the terms contained in the Scope of Services/Work and the terms set forth in this Agreement, the terms set forth in this Agreement shall govern. 1.2 Compliance with Law. Consultant services rendered under this Agreement shall comply with all applicable federal, state, and local laws, statutes and ordinances and all lawful orders, rules, and regulations. 1.3 Licenses and Permits. Consultant shall obtain at its sole cost and expense such licenses, permits, and approvals as may be required by law for the performance of the services required by this Agreement. j Revised:6/16/10 720599.1 1.4 Familiarity with Work. By executing this Agreement, Consultant warrants that it has carefully considered how the work should be performed and fully understands the facilities, difficulties, and restrictions attending performance of the work under this Agreement. 2. TIME FOR COMPLETION The time for completion of the services to be performed by Consultant is an essential condition of this Agreement. Consultant shall prosecute regularly and diligently the work of this Agreement according to the agreed upon schedule of performance set forth in Exhibit "A." Consultant shall not be accountable for delays in the progress of its work caused by any condition beyond its control and without the fault or negligence of Consultant. Delays shall not entitle Consultant to any additional compensation regardless of the party responsible for the delay. 3. COMPENSATION OF CONSULTANT 3.1 Compensation of Consultant. Consultant shall be compensated and reimbursed for the services rendered under this Agreement in accordance with the schedule of fees set forth in Exhibit"A". The total amount of Compensation shall not exceed $7,000.00. 3.2 Method of Payment. In any month in which Consultant wishes to receive payment, Consultant shall submit to City an invoice for services rendered prior to the date of the invoice, no later than the first working day of such month, in the form approved by City's finance director. Payments shall be based on the hourly rates set forth in Exhibit "A" for authorized services performed. City shall pay Consultant for all expenses stated in the invoice that are approved by City and consistent with this Agreement, within thirty (30) days of receipt of Consultant's invoice. 3.3 Changes. In the event any change or changes in the Scope of Services/Work is requested by City, Parties shall execute a written amendment to this Agreement, specifying all proposed amendments, including, but not limited to, any additional fees. An amendment may be entered into: A. To provide for revisions or modifications to documents, work product, or work, when required by the enactment or revision of any subsequent law; or B. To provide for additional services not included in this Agreement or not customarily furnished in accordance with generally accepted practice in Consultant's profession. 3.4 Appropriations. This Agreement is subject to, and contingent upon, funds being appropriated by the City Council of City for each fiscal year. If such appropriations are not made, this Agreement shall automatically terminate without penalty to City. 4. PERFORMANCE SCHEDULE 4.1 Time of Essence. Time is of the essence in the performance of this Agreement. 2 Revised:6/16110 ?20599.1 4.2 Schedule of Performance. All services rendered under this Agreement shall be performed under the agreed upon schedule of performance set forth in Exhibit "A." Any time period extension must be approved in writing by the Contract Officer. 4.3 Force Maieure. The time for performance of services to be rendered under this Agreement may be extended because of any delays due to unforeseeable causes beyond the control and without the fault or negligence of Consultant, if Consultant notifies the Contract Officer within ten (10) days of the commencement of such condition. Unforeseeable causes include, but are not limited to, acts of God or of a public enemy, acts of the government, fires, earthquakes, floods, epidemic, quarantine restrictions, riots, strikes, freight embargoes, and unusually severe weather. After Consultant notification, the Contract Officer shall investigate the facts and the extent of any necessary delay, and extend the time for performing the services for the period of the enforced delay when and if, in the Contract Officer's judgment, such delay is justified. The Contract Officer's determination shall be final and conclusive upon the parties to this Agreement. 4.4 Term. Unless earlier terminated in accordance with Section 4.5 of this Agreement, this Agreement shall continue in full force and effect for a period of thirty days, commencing on September 30, 2014, and ending on October 30, 2014, unless extended by mutual written agreement of the parties. 4.5 Termination Prior to Exniration of Term. City may terminate this Agreement at any time, with or without cause, upon thirty (30) days written notice to Consultant. Where termination is due to the fault of Consultant and constitutes an immediate danger to health, safety, and general welfare, the period of notice shall be such shorter time as may be determined by the City. Upon receipt of the notice of termination, Consultant shall immediately cease all services except such as may be specifically approved by the Contract Officer. Consultant shall be entitled to compensation for all services rendered prior to receipt of the notice of termination and for any services authorized by the Contract Officer after such notice. Consultant may terminate this Agreement, with or without cause, upon thirty(30) days written notice to City. 5. COORDINATION OF WORK 5.1 Representative of Consultant. The following principal of Consultant is designated as being the principal and representative of Consultant authorized to act and make all decisions in its behalf with respect to the specified services and work: Gary Adams, President. It is expressly understood that the experience, knowledge, education, capability, and reputation of the foregoing principal is a substantial inducement for City to enter into this Agreement. Therefore, the foregoing principal shall be responsible during the term of this Agreement for directing all activities of Consultant and devoting sufficient time to personally supervise the services under this Agreement. The foregoing principal may not be changed by Consultant without prior written approval of the Contract Officer. 5.2 Contract Officer. The Contract Officer shall be the City Manager or his/her designee ("Contract Officer"). Consultant shall be responsible for keeping the Contract Officer fully informed of the progress of the performance of the services. Consultant shall refer any 3 Revised:6116/10 720599.1 decisions that must be made by City to the Contract Officer. Unless otherwise specified, any approval of City shall mean the approval of the Contract Officer. 5.3 Prohibition Against Subcontracting or Assignment. The experience, knowledge, education, capability, and reputation of Consultant, its principals and employees, were a substantial inducement for City to enter into this Agreement. Therefore, Consultant shall not contract with any other individual or entity to perform any services required under this Agreement without the City's express written approval. In addition, neither this Agreement nor any interest may be assigned or transferred, voluntarily or by operation of law, without the prior written approval of City. 5.4 Independent Contractor. Neither City nor any of its employees shall have any control over the manner, mode, or means by which Consultant, its agents or employees, perform the services required, except as otherwise specified. Consultant shall perform all required services as an independent contractor of City and shall not be an employee of City and shall remain at all times as to City a wholly independent contractor with only such obligations as are consistent with that role; however, City shall have the right to review Consultant's work product, result, and advice. Consultant shall not at any time or in any manner represent that it or any of its agents or employees are agents or employees of City. 5.5 Personnel. Consultant agrees to assign the following individuals to perform the services in this Agreement. Consultant shall not alter the assignment of the following personnel without the prior written approval of the Contract Officer. Acting through the City Manager, the City shall have the unrestricted right to order the removal of any personnel assigned by Consultant by providing written notice to Consultant. Name: Title: Gary Adams President 6. INSURANCE Consultant shall procure and maintain, at its sole cost and expense, policies of insurance as set forth in the attached Exhibit "B", incorporated herein by reference. 7. INDEMNIFICATION. 7.1 Indemnification. To the fullest extent permitted by law, Consultant shall defend (at Consultant's sole cost and expense), indemnify, protect, and hold harmless City, its elected officials, officers, employees, agents, and volunteers (collectively the "Indemnified Parties"), from and against any and all liabilities, actions, suits, claims, demands, losses, costs, judgments, arbitration awards, settlements, damages, demands, orders, penalties, and expenses including legal costs and attorney fees (collectively "Claims"), including but not limited to Claims arising from injuries to or death of persons (Consultant's employees included), for damage to property, including property owned by City, from any violation of any federal, state, 4 Revised:6/16110 720599.1 or local law or ordinance, and from errors and omissions committed by Consultant, its officers, employees, representatives, and agents, that arise out of or relate to Consultant's performance under this Agreement. This indemnification clause excludes Claims arising from the sole negligence or willful misconduct of the City, its elected officials, officers, employees, agents, and volunteers. Under no circumstances shall the insurance requirements and limits set forth in this Agreement be construed to limit Consultant's indemnification obligation or other liability under this Agreement. Consultant's indemnification obligation shall survive the expiration or earlier termination of this Agreement until all actions against the Indemnified Parties for such matters indemnified are fully and finally barred by the applicable statute of limitations or, if an action is timely filed, until such action is final. This provision is intended for the benefit of third party Indemnified Parties not otherwise a party to this Agreement. 7.2 Design Professional Services Indemnification and Reimbursement. If the Agreement is determined to be a "design professional services agreement" and Consultant is a "design professional" under California Civil Code Section 2782.8, then: A. To the fullest extent permitted by law, Consultant shall indemnify, defend (at Consultant's sole cost and expense), protect and hold harmless City and its elected officials, officers, employees, agents and volunteers and all other public agencies whose approval of the project is required, (individually "Indemnified Party'; collectively "Indemnified Parties") against any and all liabilities, claims,judgments, arbitration awards, settlements, costs, demands, orders and penalties (collectively "Claims"), including but not limited to Claims arising from injuries or death of persons (Consultant's employees included) and damage to property, which Claims arise out of, pertain to, or are related to the negligence, recklessness or willful misconduct of Consultant, its agents, employees, or subcontractors, or arise from Consultant's negligent, reckless or willful performance of or failure to perform any term, provision, covenant or condition of this Agreement ("Indemnified Claims"), but Consultant's liability for Indemnified Claims shall be reduced to the extent such Claims arise from the negligence, recklessness or willful misconduct of the City and its elected officials, officers, employees, agents and volunteers. B. The Consultant shall require all non-design-professional sub-contractors, used or sub-contracted by Consultant to perform the Services or Work required under this Agreement, to execute an Indemnification Agreement adopting the indemnity provisions in sub- section 7.1 in favor of the Indemnified Parties. In addition, Consultant shall require all non- design-professional sub-contractors, used or sub-contracted by Consultant to perform the Services or Work required under this Agreement, to obtain insurance that is consistent with the Insurance provisions as set forth in this Agreement, as well as any other insurance that may be required by Contract Officer. 8. RECORDS AND REPORTS 8.1 Reports. Consultant shall periodically prepare and submit to the Contract Officer reports concerning the performance of the services required by this Agreement, or as the Contract Officer shall require. 5 Revised:6/16110 720599.1 8.2 Records. Consultant shall keep complete, accurate, and detailed accounts of all time, costs, expenses, and expenditures pertaining in any way to this Agreement. Consultant shall keep such books and records as shall be necessary to properly perform the services required by this Agreement and enable the Contract Officer to evaluate the performance of such services. The Contract Officer shall have full and free access to such books and records at all reasonable times, including the right to inspect, copy, audit, and make records and transcripts from such records. 8.3 Ownership of Documents. All drawings, specifications, reports, records, documents, and other materials prepared by Consultant in the performance of this Agreement shall be the property of City. Consultant shall deliver all above-referenced documents to City upon request of the Contract Officer or upon the termination of this Agreement. Consultant shall have no claim for further employment or additional compensation as a result of the exercise by City of its full rights or ownership of the documents and materials. Consultant may retain copies of such documents for Consultant's own use. Consultant shall have an unrestricted right to use the concepts embodied in such documents. 8.4 Release of Documents. All drawings, specifications, reports, records, documents, and other materials prepared by Consultant in the performance of services under this Agreement shall not be released publicly without the prior written approval of the Contract Officer. 8.5 Cost Records. Consultant shall maintain all books, documents, papers, employee time sheets, accounting records, and other evidence pertaining to costs incurred while performing under this Agreement. Consultant shall make such materials available at its offices at all reasonable times during the term of this Agreement and for three (3) years from the date of final payment for inspection by City and copies shall be promptly furnished to City upon request. 9. ENFORCEMENT OF AGREEMENT 9.1 California Law. This Agreement shall be construed and interpreted both as to validity and to performance of the parties in accordance with the laws of the State of California. Legal actions concerning any dispute, claim, or matter arising out of or in relation to this Agreement shall be instituted in the Superior Court of the County of Riverside, State of California, or any other appropriate court in such county, and Consultant covenants and agrees to submit to the personal jurisdiction of such court in the event of such action. 9.2 Interpretation. This Agreement shall be construed as a whole according to its fair language and common meaning to achieve the objectives and purposes of the Parties. The terms of this Agreement are contractual and the result of negotiation between the Parties. Accordingly, any rule of construction of contracts (including, without limitation, California Civil Code Section 1654) that ambiguities are to be construed against the drafting party, shall not be employed in the interpretation of this Agreement. The caption headings of the various sections and paragraphs of this Agreement are for convenience and identification purposes only and shall not be deemed to limit, expand, or define the contents of the respective sections or paragraphs. 6 Revised:6/16110 720599.1 9.3 Waiver. No delay or omission in the exercise of any right or remedy of a non- defaulting party on any default shall impair such right or remedy or be construed as a waiver. No consent or approval of City shall be deemed to waive or render unnecessary City's consent to or approval of any subsequent act of Consultant. Any waiver by either party of any default must be in writing. No such waiver shall be a waiver of any other default concerning the same or any other provision of this Agreement. 9.4 Rights and Remedies are Cumulative. Except with respect to rights and remedies expressly declared to be exclusive in this Agreement, the rights and remedies of the parties are cumulative. The exercise by either party of one or more of such rights or remedies shall not preclude the exercise by it, at the same or different times, of any other rights or remedies for the same default or any other default by the other party. 9.5 Legal Action. In addition to any other rights or remedies, either party may take legal action, in law or in equity, to cure, correct, or remedy any default, to recover damages for any default, to compel specific performance of this Agreement, to obtain injunctive relief, a declaratory judgment, or any other remedy consistent with the purposes of this Agreement. 10. CITY OFFICERS AND EMPLOYEES: NON-DISCRIMINATION 10.1 Non-Liability of City Officers and Employees. No officer or employee of City shall be personally liable to the Consultant, or any successor-in-interest, in the event of any default or breach by City or for any amount which may become due to the Consultant or its successor, or for breach of any obligation of the terms of this Agreement. 10.2 Conflict of Interest. No officer or employee of the City shall have any direct or indirect financial interest in this Agreement nor shall any such officer or employee participate in any decision relating to the Agreement which effects their financial interest or the financial interest of any corporation, partnership, or association in which he/she is, directly or indirectly, interested in violation of any state statute or regulation. Consultant warrants that Consultant has not paid or given, and will not pay or give, any third party any money or other consideration in exchange for obtaining this Agreement. 10.3 Covenant Against Discrimination. Consultant covenants that, by and for itself, its heirs, executors, assigns, and all persons claiming under or through them, that there shall be no discrimination or segregation in the performance of or in connection with this Agreement regarding any person or group of persons on account of race, color, creed, religion, sex, marital status, disability, sexual orientation, national origin, or ancestry. 11. MISCELLANEOUS PROVISIONS 11.1 Notice. Any notice, demand, request, consent, approval, or communication that either party desires, or is required to give to the other party or any other person shall be in writing and either served personally or sent by pre-paid, first-class mail to the address set forth below. Notice shall be deemed communicated seventy-two (72) hours from the time of mailing if mailed as provided in this Section. Either party may change its address by notifying the other party of the change of address in writing. 7 Revised:6/16/10 720599 1 To City: City of Palm Springs Attention: City Manager/ City Clerk 3200 E. Tahquitz Canyon Way Palm Springs, California 92262 To Consultant: The Adams Companies 1508 W. Tara Drive 1508 Gilbert, AZ 85233 11.2 Integrated Agreement. This Agreement contains all of the agreements of the parties and supersedes all other written agreements. 11.3 Amendment. No amendments or other modifications of this Agreement shall he binding unless through written agreement by all Parties. 11.4 Severability. Whenever possible, each provision of this Agreement shall be interpreted in such a manner as to be effective and valid under applicable law. In the event that any one or more of the phrases, sentences, clauses, paragraphs, or sections contained in this Agreement shall be declared invalid or unenforceable by valid judgment or decree of a court of competent jurisdiction, such invalidity or unenforceability shall not affect any of the remaining phrases, sentences, clauses, paragraphs, or sections of this Agreement, which shall be interpreted to carry out the intent of the parties. 11.5 Successors in Interest. This Agreement shall be binding upon and inure to the benefit of the Parties' successors and assignees. 11.6 Third Party Beneficiary. Except as may be expressly provided for in this Agreement, nothing contained in this Agreement is intended to confer, nor shall this Agreement be construed as conferring, any rights, including, without limitation, any rights as a third-party beneficiary or otherwise, upon any entity or person not a party to this Agreement. 11.7 Recitals. The above-referenced Recitals are hereby incorporated into the Agreement as though fully set forth in this Agreement and each Parry acknowledges and agrees that such Party is bound, for purposes of this Agreement, by the same. 11.8 Authority. The persons executing this Agreement on behalf of the Parties warrant that they are duly authorized to execute this Agreement on behalf of Parties and that by so executing this Agreement the Parties are formally bound to the provisions of this Agreement. 8 Revis d 6116/10 720599.1 IN WITNESS WHEREOF, the Parties have executed this Agreement as of the dates stated below. "CITY" City of Palm Springs Date: By: David H. Ready City Manager APPROVED AS TO FORM: ATTEST By: By: Douglas C. Holland, James Thompson, City Attorney City Clerk "CONSULTANT" The Adams Companies Date: `r/2 2 /J cJ By Ga(Z)AdCnj, President Date: e-7 z z N WUh '- (name) Pa., et 5. Y—e- d-e I AAav S (secretary) 9 Revised:6116/10 720599.1 CN WITNESS WHEREOI', the Parties have executed this Agreement as of tl;e dates stated below. "CITY" City of Palm Springs Date: � 1 --- By David H Rea dv City Manager APPROVED BY C11Y MANAGER APPROVED AS TO FORM: ATTEST DAL �1000°- By: tl Dougl C. Holland. ies Thompson, City At orney City Cterk "CONSULTANT" The Adams Companies Date: t E2 7 By -- C ��r ' Gary, d . President c lhb Date: (name) (secretary) 9 Revised 6116/10 The Adams Companies 1508 W Tara Drive Gilbert,Arizona 85233 _,�OD Phone:602-708-1177 E-mail:gary@theadamseompanies.biz September 4, 2014 Mr. Mark Jucht Airport Administration Manager Palm Springs International Airport 3400 East Tahquitz Canyon Way Palm Springs, California 92262 Re: Qualifications for an Independent Fee Estimate (IFE) for Engineering Construction Services at the Palm Springs International Airport. Dear Mr. Jucht: In response to your request for a proposal for the Palm Springs International Airport, The Adams Companies (TAC) is pleased to submit the following statement, proposal and work scope for an Independent Fee Estimate. TAC is a small fine established in 2005 that provides aviation consultation services to airports primarily in the Southwest U.S.TAC prides itself on providing high-quality professional services that result in a high percentage of repeat clients. The Adams Companies has the following outstanding capabilities to bring to this assignment: • Availability: TAC is completing projects at Scottsdale and Sedona Airports and can begin work immediately on this analysis and complete the assignment within 7 work days. • Relevant Experience: TAC has completed projects similar to those described in your request. We have significant experience in all aspects of airport development projects and independent fee analysis for Federal Aviation Administration (FAA) Airport Improvement Program (AIP) grant programs. • Relationship with FAA: Mr. Adams retired as the Arizona Department of Transportation (ADOT) Aeronautics Division Director after 25 years, and has excellent working relationships with numerous FAA personnel. These relationships allow TAC to effectively and efficiently perform all agency coordination. • Page 2 September 4, 2014 This proposal and attached work scope"Exhibit A"are designed to address the overall needs of the Palm Springs International Airport for completing an Independent Fee Estimate in a well-coordinated and timely manner. Our fee for the proposed scope of services is a lump sum fee of$7,000.00. All work shall be completed within 7 working days from the Notice to Proceed. In order to meet the completion date,TAC will require: 1)a written notice to proceed and 2)the receipt of all necessary review materials including the following: a) The consultant's list of proposed subcontractors and subcontractors proposed work scope;b)Consultant's proposed scope of work,as approved by the FAA; c)Consultant's redacted budget spreadsheet. We understand the importance of this effort to the City of Palm Springs and the Palm Springs International Airport. We know that during these tight economic times, the Airport needs additional funding options and creative problem solving to help complete much needed improvements.TAC is committed to providing the resources and expertise required to provide you with the most cost-effective,timely consulting services available. Thank you for considering The Adams Companies for this assignment. For more background information on The Adams Companies, please visit our website at: http•//www.theadamscompanies.biz/index.html. We look forward to your favorable review of our submission for this project. Please do not hesitate to contact me at 602-708-1177, or via email at earv(cbtheadamscompanies.biz, if you have any questions or desire further information. Sincerely, The Adams Companies Gary Adams President September4, 2014 EXHIBIT A PALM SPRINGS INTERNATIONAL AIRPORT INDEPENDENT FEE ESTIMATE ENGINEERING CONSTRUCTION SERVICES FOR RUNWAY 13R- 31L REHABILITATION, LIGHTING AND MARKING SCOPE OF WORK AND FEE ESTIMATE Introduction: The City of Palm Springs will soon begin a construction project to rehabilitate the airport asphalt runway pavement at the Palm Springs International Airport.The construction includes approximately 2.3 million square feet of asphalt pavement to be removed or rehabilitated. This project will also be retrofitted with LED lights and signs were possible and appropriate for the runway.Parsons Brinkerhoff, Inc. is the construction team managers and will subcontract the construction observation and management portion of the project. The goal of this project is to provide the airport and the traveling public with a safer and more secure transportation system at the Palm Springs International Airport. In order to complete the runway pavement rehabilitation project, the City of Palm Springs,as owner of the Palm Springs International Airport, is about to enter into contract fee negotiations with the airport engineering consultant firm of Parsons Brinkerhoff (Consultant), after selecting them based on qualifications. In accordance with FAA consultant selection guidelines,the City of Palm Springs is requesting TAC to submit a proposal and work scope for an Independent Fee Estimate(IFE)on the scope of services to he provided by the selected consultant. The scope of services that TAC proposes for the IFE is as follows: Task 1: Develop Independent Fee Estimate a)TAC will review the scope of services developed by the Consultant(s)and the Palm Springs Intemational Airport. The scope will be reviewed task-by-task to ensure that all required services for the Project, based on TAC's professional judgment, are thoroughly addressed in accordance with FAA guidelines for projects of this type, including the most recent FAA Advisory Circulars. b)TAC will provide to the Palm Springs International Airport a cost breakdown structure and cost estimate by task. The cost breakdown structure will consider the level of staff skills necessary to effectively complete each task, staff man-hours, and any other cost considerations, i.e. direct costs which may be needed for the acquisition of data or travel- • Page 2 September 4,2014 related expenses. This cost breakdown will be similar in format to Appendix F of AC 150/5100-14D. c) TAC will provide a detailed cover letter with an explanation of costs and a separate comprehensive spreadsheet of the independent fee estimate to the Palm Springs International Airport,both in hard copy(if requested)and electronic format. Fee: Our fee for the proposed scope of services is a lump sum fee of$7,000.00. All work shall be completed within 7 working days from the Notice to Proceed.In order to meet the completion date,TAC will require: 1)a written notice to proceed and 2)the receipt of all necessary review materials including the following: a) The consultant's list of proposed subcontractors and subcontractors proposed work scope;b)Consultant's proposed scope of work,as approved by the FAA; and c)Consultant's redacted budget spreadsheet. Billing/Contact Information: The Adams Companies LLC -Federal ID number is 76-0823239. Palm Springs Business License#20016856 TAC's billing address is: The Adams Companies, LLC 1508 W.Tara Dr. Gilbert,AZ 85233 602-708-1177 Exhibit B I certify that in the performance of work for which this agreement is issued, I SHALL NOT EMPLOY ANY PERSON, in any manner so as to become subject to the worker's compensation laws of California, and agree that if I should become subject to the worker's compensation provisions of Section 3700 of the Labor Code, I shall for with comply with those provisions. All work shall be performed from my office in Gilbert Arizona and I certify that I will not perform any work, nor will there be any motor vehicles used in Palm Springs, California. Insurance polies will not be provided for this consulting services agreement. } Date: IC= 3 Z ! By : ' � ary din , President CONSULTING SERVICES AGREEMENT The Adams Company THIS AGREEMENT FOR CONSULTING SERVICES ("Agreement") is made and entered into on November 26, 2013, by and between the City of Palm Springs, a California charter city and municipal corporation ("City"), and The Adams Company, a Limited Liability Company, ("Consultant'). City and Consultant are individually referred to as "Party" and are collectively referred to as the "Parties". RECITALS A. City requires the services of an Independent Fee Consultant, for Design and Construction Management Services for Airport Improvement Projects, ("Project'). B. Consultant has submitted to City a proposal to provide independent fee consulting, to City under the terms of this Agreement. C. Based on its experience, education, training, and reputation, Consultant is qualified and desires to provide the necessary services to City for the Project. D. City desires to retain the services of Consultant for the Project. In consideration of these promises and mutual agreements, City agrees as follows: AGREEMENT 1. CONSULTANT SERVICES 1.1 Scope of Services. In compliance with all terms and conditions of this Agreement, Consultant shall provide Independent Fee Consulting services to City as described in the Scope of Services/Work attached to this Agreement as Exhibit "A" and incorporated by reference (the "services" or "work"). Exhibit "A" includes the agreed upon schedule of performance and the schedule of fees. Consultant agrees that all services and work shall be performed in a competent, professional, and satisfactory manner consistent with prevailing industry standards. In the event of any inconsistency between the terms contained in the Scope of Services/Work and the terms set forth in this Agreement,the terms set forth in this Agreement shall govern. 1.2 Compliance with Law. Consultant services rendered under this Agreement shall comply with all applicable federal, state, and local laws, statutes and ordinances and all lawful orders, rules, and regulations. 1.3 Licenses and Permits. Consultant shall obtain at its sole cost and expense such licenses, permits, and approvals as may be required by law for the performance of the services required by this Agreement. ] Revised:11/28H3 7205�0,1 ORIGINAL BIL) Au'tD/OR AGREEAdEW 1.4 Familiarity with Work. By executing this Agreement, Consultant agrees that it has carefully considered how the work should be performed and fully understands the facilities, difficulties, and restrictions attending performance of the work under this Agreement. 2. TIME FOR COMPLETION The time for completion of the services to be performed by Consultant is an essential condition of this Agreement. Consultant shall prosecute regularly and diligently the work of this Agreement according to the agreed upon schedule of performance set forth in Exhibit "A." Consultant shall not be accountable for delays in the progress of its work caused by any condition beyond its control and without the fault or negligence of Consultant. Delays shall not entitle Consultant to any additional compensation regardless of the parry responsible for the delay. 3. COMPENSATION OF CONSULTANT 3.1 Compensation of Consultant. Consultant shall be compensated and reimbursed for the services rendered under this Agreement in accordance with the schedule of fees set forth in Exhibit"A". The total amount of Compensation shall not exceed$5,000.00. 3.2 Method of Payment. In any month in which Consultant wishes to receive payment, Consultant shall submit to City an invoice for services rendered prior to the date of the invoice, no later than the first working day of such month, in the form approved by City's finance director. Payments shall be based on the hourly rates set forth in Exhibit "A" for authorized services performed. City shall pay Consultant for all expenses stated in the invoice that are approved by City and consistent with this Agreement, within thirty (30) days of receipt of Consultant's invoice. 33 Chances. In the event any change or changes in the Scope of Services/Work is requested by City, Parties shall execute a written amendment to this Agreement, specifying all proposed amendments, including, but not limited to, any additional fees. An amendment may be entered into: A. To provide for revisions or modifications to documents, work product, or work, when required by the enactment or revision of any subsequent law; or B. To provide for additional services not included in this Agreement or not customarily furnished in accordance with generally accepted practice in Consultant's profession. 3.4 Appropriations. This Agreement is subject to, and contingent upon, funds being appropriated by the City Council of City for each fiscal year. If such appropriations are not made, this Agreement shall automatically terminate without penalty to City. 4. PERFORMANCE SCHEDULE 4.1 Time of Essence. Time is of the essence in the performance of this Agreement. 2 Revised:11/26113 "20599A 4.2 Schedule of Performance. All services rendered under this Agreement shall be performed under the agreed upon schedule of performance set forth in Exhibit "A." Any time period extension must be approved in writing by the Contract Officer. 4.3 Force Maieure. The time for performance of services to be rendered under this Agreement may be extended because of any delays due to unforeseeable causes beyond the control and without the fault or negligence of Consultant, if Consultant notifies the Contract Officer within ten (10) days of the commencement of such condition. Unforeseeable causes include, but are not limited to, acts of God or of a public enemy, acts of the government, fires, earthquakes, floods, epidemic, quarantine restrictions, riots, strikes, freight embargoes, and unusually severe weather. After Consultant notification, the Contract Officer shall investigate the facts and the extent of any necessary delay, and extend the time for performing the services for the period of the enforced delay when and if, in the Contract Officer's judgment, such delay is justified. The Contract Officer's determination shall be final and conclusive upon the parties to this Agreement. 4.4 Term. Unless earlier terminated in accordance with Section 4.5 of this Agreement, this Agreement shall continue in full force and effect for a period of thirty days, commencing on December 2, 2013, and ending on December 31, 2013, unless extended by mutual written agreement of the parties. 4.5 Termination Prior to Expiration of Term. City may terminate this Agreement at any time, with or without cause, upon thirty (30) days written notice to Consultant. Where termination is due to the fault of Consultant and constitutes an immediate danger to health, safety, and general welfare, the period of notice shall be such shorter time as may be determined by the City. Upon receipt of the notice of termination, Consultant shall immediately cease all services except such as may be specifically approved by the Contract Officer. Consultant shall be entitled to compensation for all services rendered prior to receipt of the notice of termination and for any services authorized by the Contract Officer after such notice. Consultant may terminate this Agreement, with or without cause,upon thirty (30) days written notice to City. 5. COORDINATION OF WORK 5.1 Representative of Consultant. The following principal of Consultant is designated as being the principal and representative of Consultant authorized to act and make all decisions in its behalf with respect to the specified services and work: Gary Adams, President. It is expressly understood that the experience, knowledge, education, capability, and reputation of the foregoing principal is a substantial inducement for City to enter into this Agreement. Therefore, the foregoing principal shall be responsible during the term of this Agreement for directing all activities of Consultant and devoting sufficient time to personally supervise the services under this Agreement. The foregoing principal may not be changed by Consultant without prior written approval of the Contract Officer. 5.2 Contract Officer. The Contract Officer shall be the City Manager or his/her designee ("Contract Officer"). Consultant shall be responsible for keeping the Contract Officer fully informed of the progress of the performance of the services. Consultant shall refer any 3 Revised:11/26/13 720599_I decisions that must be made by City to the Contract Officer. Unless otherwise specified, any approval of City shall mean the approval of the Contract Officer. 53 Prohibition Against Subcontracting or Assignment. The experience, knowledge, education, capability, and reputation of Consultant, its principals and employees, were a substantial inducement for City to enter into this Agreement. Therefore, Consultant shall not contract with any other individual or entity to perform any services required under this Agreement without the City's express written approval. In addition, neither this Agreement nor any interest may be assigned or transferred, voluntarily or by operation of law, without the prior written approval of City. 5.4 Indenendcnt Contractor. Neither City nor any of its employees shall have any control over the manner, mode, or means by which Consultant, its agents or employees, perform the services required, except as otherwise specified. Consultant shall perform all required services as an independent contractor of City and shall not be an employee of City and shall remain at all times as to City a wholly independent contractor with only such obligations as are consistent with that role; however, City shall have the right to review Consultant's work product, result, and advice. Consultant shall not at any time or in any manner represent that it or any of its agents or employees are agents or employees of City. 5.5 Personnel. Consultant agrees to assign the following individuals to perform the services in this Agreement. Consultant shall not alter the assignment of the following personnel without the prior written approval of the Contract Officer. Acting through the City Manager, the City shall have the unrestricted right to order the removal of any personnel assigned by Consultant by providing written notice to Consultant. Name: Title: Gary Adams President 6. INSURANCE Consultant shall procure and maintain, at its sole cost and expense, policies of insurance as set forth in the attached Exhibit "B", incorporated herein by reference. 7. INDEMNIFICATION. 7.1 Indemnification. To the fullest extent permitted by law, Consultant shall defend (at Consultant's sole cost and expense), indemnify, protect, and hold harmless City, its elected officials, officers, employees, agents, and volunteers (collectively the "Indemnified Parties"), from and against any and all liabilities, actions, suits, claims, demands, losses, costs, judgments, arbitration awards, settlements, damages, demands, orders, penalties, and expenses including legal costs and attorney fees (collectively "Claims"), including but not limited to Claims arising from injuries to or death of persons (Consultant's employees included), for damage to property, including property owned by City, from any violation of any federal, state, 4 Reviwd: 11/26/13 7205921 or local law or ordinance, and from errors and omissions committed by Consultant, its officers, employees, representatives, and agents, that arise out of or relate to Consultant's performance under this Agreement. This indemnification clause excludes Claims arising from the sole negligence or willful misconduct of the City, its elected officials, officers, employees, agents, and volunteers. Under no circumstances shall the insurance requirements and limits set forth in this Agreement be construed to limit Consultant's indemnification obligation or other liability under this Agreement. Consultant's indemnification obligation shall survive the expiration or earlier termination of this Agreement until all actions against the Indemnified Parties for such matters indemnified are fully and finally barred by the applicable statute of limitations or, if an action is timely filed, until such action is final. This provision is intended for the benefit of third party Indemnified Parties not otherwise a parry to this Agreement. 7.2 Desism Professional Services Indemnification and Reimbursement. If the Agreement is determined to be a "design professional services agreement" and Consultant is a "design professional" under California Civil Code Section 2782.8, then: A. To the fullest extent permitted by law, Consultant shall indemnify, defend (at Consultant's sole cost and expense), protect and hold harmless City and its elected officials, officers, employees, agents and volunteers and all other public agencies whose approval of the project is required, (individually "Indemnified Party'; collectively "Indemnified Parties") against any and all liabilities, claims,judgments, arbitration awards, settlements, costs, demands, orders and penalties (collectively "Claims"), including but not limited to Claims arising from injuries or death of persons (Consultant's employees included) and damage to property, which Claims arise out of, pertain to, or are related to the negligence, recklessness or willful misconduct of Consultant, its agents, employees, or subcontractors, or arise from Consultant's negligent, reckless or willful performance of or failure to perform any term, provision, covenant or condition of this Agreement ("Indemnified Claims"), but Consultant's liability for Indemnified Claims shall be reduced to the extent such Claims arise from the negligence, recklessness or willful misconduct of the City and its elected officials, officers, employees, agents and volunteers. B. The Consultant shall require all non-design-professional sub-contractors, used or sub-contracted by Consultant to perform the Services or Work required under this Agreement, to execute an Indemnification Agreement adopting the indemnity provisions in sub- section 7.1 in favor of the Indemnified Parties. In addition, Consultant shall require all non- design-professional sub-contractors, used or sub-contracted by Consultant to perform the Services or Work required under this Agreement, to obtain insurance that is consistent with the Insurance provisions as set forth in this Agreement, as well as any other insurance that may be required by Contract Officer. 8. RECORDS AND REPORTS 8.1 Reports. Consultant shall periodically prepare and submit to the Contract Officer reports concerning the performance of the services required by this Agreement, or as the Contract Officer shall require. 9 Revimd 11/26/13 720599,1 8.2 Records. Consultant shall keep complete, accurate, and detailed accounts of all time, costs, expenses, and expenditures pertaining in any way to this Agreement. Consultant shall keep such books and records as shall be necessary to properly perform the services required by this Agreement and enable the Contract Officer to evaluate the performance of such services. The Contract Officer shall have full and free access to such books and records at all reasonable times, including the right to inspect, copy, audit, and make records and transcripts from such records. 8.3 Ownership of Documents. All drawings, specifications, reports, records, documents, and other materials prepared by Consultant in the performance of this Agreement shall be the property of City. Consultant shall deliver all above-referenced documents to City upon request of the Contract Officer or upon the termination of this Agreement. Consultant shall have no claim for further employment or additional compensation as a result of the exercise by Cityof its full rights or ownership of the documents and materials. Consultant may retain copies P Y p of such documents for Consultant's own use. Consultant shall have an unrestricted right to use the concepts embodied in such documents. 4 Re lease el ease of Documents. All drawings, specifications, reports, records, documents, and other materials prepared by Consultant in the performance of services under this Agreement shall not be released publicly without the prior written approval of the Contract Officer. 8.5 Cost Records. Consultant shall maintain all books, documents,papers, employee time sheets, accounting records, and other evidence pertaining to costs incurred while performing under this Agreement. Consultant shall make such materials available at its offices at all reasonable times during the term of this Agreement and for three (3) years from the date of final payment for inspection by City and copies shall be promptly furnished to City upon request. 9. ENFORCEMENT OF AGREEMENT 9.1 California Law. This Agreement shall be construed and interpreted both as to g rp validity and to performance of the parties in accordance with the laws of the State of California. Legal actions concerning any dispute, claim, or matter arising out of or in relation to this Agreement shall be instituted in the Superior Court of the County of Riverside, State of California, or any other appropriate court in such county, and Consultant covenants and agrees to submit to the personal jurisdiction of such court in the event of such action. 9.2 Interpretation. This Agreement shall be construed as a whole according to its fair language and common meaning to achieve the objectives and purposes of the Parties. The terms of this Agreement are contractual and the result of negotiation between the Parties. Accordingly, any rule of construction of contracts (including, without limitation, California Civil Code Section 1654) that ambiguities are to be construed against the drafting party, shall not be employed in the interpretation of this Agreement. The caption headings of the various sections and paragraphs of this Agreement are for convenience and identification purposes only and shall not be deemed to limit, expand, or define the contents of the respective sections or paragraphs. 6 Revised:11128113 720599A 9.3 Waiver. No delay or omission in the exercise of any right or remedy of a non- defaulting party on any default shall impair such right or remedy or be construed as a waiver. No consent or approval of City shall be deemed to waive or render unnecessary City's consent to or approval of any subsequent act of Consultant. Any waiver by either party of any default must be in writing. No such waiver shall be a waiver of any other default concerning the same or any other provision of this Agreement. 9.4 Rights and Remedies are Cumulative. Except with respect to rights and remedies expressly declared to be exclusive in this Agreement, the rights and remedies of the parties are cumulative. The exercise by either party of one or more of such rights or remedies shall not preclude the exercise by it, at the same or different times, of any other rights or remedies for the same default or any other default by the other party. 9.5 Legal Action. In addition to any other rights or remedies, either party may take legal action, in law or in equity, to cure, correct, or remedy any default, to recover damages for any default, to compel specific performance of this Agreement, to obtain injunctive relief, a declaratory judgment, or any other remedy consistent with the purposes of this Agreement. 10. CITY OFFICERS AND EMPLOYEES: NON-DISCRIMINATION 10.1 Non-Liability of City Officers and Employees. No officer or employee of City shall be personally liable to the Consultant, or any successor-in-interest, in the event of any default or breach by City or for any amount which may become due to the Consultant or its successor, or for breach of any obligation of the terms of this Agreement. 10.2 Conflict of Interest. No officer or employee of the City shall have any direct or indirect financial interest in this Agreement nor shall any such officer or employee participate in any decision relating to the Agreement which effects their financial interest or the financial interest of any corporation, partnership, or association in which he/she is, directly or indirectly, interested in violation of any state statute or regulation. Consultant warrants that Consultant has not paid or given, and will not pay or give, any third party any money or other consideration in exchange for obtaining this Agreement. 10.3 Covenant Against Discrimination. Consultant covenants that, by and for itself, its heirs, executors, assigns, and all persons claiming under or through them, that there shall be no discrimination or segregation in the performance of or in connection with this Agreement regarding any person or group of persons on account of race, color, creed, religion, sex, marital status, disability, sexual orientation, national origin, or ancestry. 11. MISCELLANEOUS PROVISIONS 11.1 Notice. Any notice, demand, request, consent, approval, or communication that either party desires, or is required to give to the other party or any other person shall be in writing and either served personally or sent by pre-paid, first-class mail to the address set forth below. Notice shall be deemed communicated seventy-two (72) hours from the time of mailing if mailed as provided in this Section. Either party may change its address by notifying the other party of the change of address in writing. 7 Reviwd:11f2&13 720599.1 To City: City of Palm Springs Attention: City Manager/ City Clerk 3200 E. Tahquitz Canyon Way Palm Springs, California 92262 To Consultant: The Adams Companies 1508 W. Tara Drive Gilbert, AZ 85233 11.2 Integrated Agreement. This Agreement contains all of the agreements of the parties and supersedes all other written agreements. 11.3 Amendment. No amendments or other modifications of this Agreement shall be binding unless through written agreement by all Parties. 11.4 Severability. Whenever possible, each provision of this Agreement shall be interpreted in such a manner as to be effective and valid under applicable law. In the event that any one or more of the phrases, sentences, clauses, paragraphs, or sections contained in this Agreement shall be declared invalid or unenforceable by valid judgment or decree of a court of competent jurisdiction, such invalidity or unenforceability shall not affect any of the remaining phrases, sentences, clauses, paragraphs, or sections of this Agreement, which shall be interpreted to carry out the intent of the parties. 11.5 Successors in Interest. This Agreement shall be binding upon and inure to the benefit of the Parties' successors and assignees. 11.6 Third Party Beneficiary. Except as may be expressly provided for in this Agreement, nothing contained in this Agreement is intended to confer, nor shall this Agreement be construed as conferring, any rights, including, without limitation, any rights as a third-party beneficiary or otherwise, upon any entity or person not a party to this Agreement. 11.7 Recitals. The above-referenced Recitals are hereby incorporated into the Agreement as though fully set forth in this Agreement and each Party acknowledges and agrees that such Party is bound, for purposes of this Agreement, by the same. 11.8 Authority. The persons executing this Agreement on behalf of the Parties warrant that they are duly authorized to execute this Agreement on behalf of Parties and that by so executing this Agreement the Parties are formally bound to the provisions of this Agreement. $ Raviwd 11/26/13 720599.1 IN WITNESS WHEREOF, the Parties have executed this Agreement as of the dates stated below. "CITY" City of Palm Springs T t; n, ec. Director Date: By: 0 4�1T r4wcela-u l x-ez—t� David H. Ready City Manager APPROVED AS TO FORM: ATTEST By: , 4&41-4( Douglas . Holland, James Thompson, City A omey City Clerk "CONSULTANT" The Adams Companies Date: 29/13 By Gar"ddths, President Date: q-2-9 113 1cu,;l,e&-- ktA d d—Axa mS (name) (secretary) APPROVED BY DEPARR 'ME,N�T HEAD 9 Revised:1112&13 7205991 CALIFORNIA ALL4WRPOSE ACKNOWLEDGMENT State of California 1 County of 1} On before me, DM Hen In a Nam "Vk of w Ww personally appeared _--- amraNl n egim(H who proved to me on the basis of satisfactory evidence to be the persort(s) whose name(s) Ware subscribed to the within instrument and acknowledged to me that hdsheRhey executed the same in histherAfteb authorized capacity(es), and that by histhedthfeir signs fa(s)on the Instrument tlhe person(s), or the entity upon behalf of which the person(s)acted,executed the instrument I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph Is true and correct. WITNESS my hand and offidal seal. Signature PMva emery Sml Moue 9 uomry OPTIONAL Though the k?W418600 below(a not requhsd by law,It may pious Vskobb to persons refyhp on hie document and mould prnrora traudukn!rerrlvval and reaeadensre of dth form to another abcument. Description of Attached Document Title or Type of Document: Document Data: Number of Pages: Signer(s)Other Than Named Above: Capac"Ies)Cialtned by Signer(s) Signer's Name: Signers Name: 1 Individual ❑individual ❑ Corporate Officer—Title(s): ❑Corporate Officer—Title(s): U Partner—U limited U General ❑Partner—rJ Limited ❑General U Attorney in Fact ❑Attorney in Fact • Trustee Top of.ty b here C Trustee I Top of thwnb mm ❑ Guardian or Conservator ❑Guardian or Conservator O Other. C Other ` Signer Is Representing: Signer Is Representing: OAOTlLlomlfLary Aeodabn.(t9so Geob km.,P.O.�csae•!]mrore,,CA atat9a�o2•wwar.MYvmFlMrLmp Nm�IVID] neptler:CYTa1Frce18oLLaBM2r 10 Revised:11M/13 720599.1 EXHIBIT A PALM SPRINGS INTERNATIONAL AIRPORT INDEPENDENT FEE ESTIMATE FOR ENGINEERING DESIGN SERVICES FOR RUNWAY REHABILITATION AND EVALUATION OF EXISTING ACCESS CONTROL, CCTV, FLIGHT DISPLAY AND STRUCTURED CABLING SYSTEM SCOPE OF WORK AND FEE ESTIMATE Introduction: The City of Palm Springs will soon begin a design project to rehabilitate the airport asphalt runway pavement at the Palm Springs International Airport. The design includes an analysis of the existing airport Access Control, CCTV, Flight Information Display and Structured Cabling System. Parsons Brinckerhoff, Inc. has been selected as the design team managers for the project. The goal of this project is to provide the airport and the traveling public with a safer and more secure transportation system at the Palm Springs International Airport. In order to complete the runway pavement rehabilitation project, the City of Palm Springs, as owner of the Palm Springs International Airport, is about to enter into contract fee negotiations with the airport engineering consultant firm of Parsons Brinkerhoff(Consultant), after selecting them based on qualifications. In accordance with FAA consultant selection guidelines, the City of Palm Springs is requesting TAC to submit a proposal and work scope for an Independent Fee Estimate (IFE)on the scope of services to be provided by the selected consultant. The scope of services that TAC proposes for the IFE is as follows: Task 1: Develop Independent Fee Estimate a) TAC will review the scope of services developed by the Consultant(s) and the Palm Springs International Airport. The scope will be reviewed task-by-task to ensure that all required services for the Project,based on TAC's professional judgment, are thoroughly addressed in accordance with FAA guidelines for projects of this type, including the most recent FAA Advisory Circulars. 11 Revised:11/26/13 720599_I b) TAC will provide to the Palm Springs International Airport a cost breakdown structure and cost estimate by task. The cost breakdown structure will consider the level of staff skills necessary to effectively complete each task, staff man-hours,and any other cost considerations, i.e. direct costs which may be needed for the acquisition of data or travel-related expenses. This cost breakdown will be similar in format to Appendix F of AC 150/5100-14D. c) TAC will provide a detailed cover letter with an explanation of costs and a separate comprehensive spreadsheet of the independent fee estimate to the Palm Springs International Airport, both in hard copy (if requested)and electronic format. Fee and Schedule: Our fee for the proposed scope of services is a lump sum fee of$5,000.00. All work shall be completed within 7 working days from the Notice to Proceed. In order to meet the completion date, TAC will require, in conjunction with the Notice to Proceed: 1) a written notice to proceed and 2)the receipt of all necessary review materials including the following: a) The consultant's list of proposed subcontractors and subcontractors proposed work scope; b) Consultant's proposed scope of work, as approved by the FAA; and c) Consultant's redacted budget spreadsheet. Billing/Contact Information: The Adams Companies LLC - Federal ID number is 76-0823239. Palm Springs Business License# 20016856 TAC's billing address is: The Adams Companies, LLC 1508 W. Tara Dr. Gilbert, AZ 85233 602-708-1177 12 Revised:11/26/13 720599.1 EXHIBIT "B" INSURANCE PROVISIONS Including Verification of Coverage, Sufficiency of Insurers, Errors and Omissions Coverage, g , Minimum Scope of Insurance, Deductibles and Self-Insured Retentions, and Severability of Interests (Separation of Insureds) 13 Revised:11/26/13 720599.1 INSURANCE 1. Procurement and Maintenance of Insurance. Consultant shall procure and maintain public liability and property damage insurance against all claims for injuries against persons or damages to property resulting from Consultant's performance under this Agreement. Consultant shall procure and maintain all insurance at its sole cost and expense, in a form and content satisfactory to the City, and submit concurrently with its execution of this Agreement. Consultant shall also carry workers' compensation insurance in accordance with California workers' compensation laws. Such insurance shall be kept in full force and effect during the term of this Agreement, including any extensions. Such insurance shall not be cancelable without thirty(30) days advance written notice to City of any proposed cancellation. Certificates of insurance evidencing the foregoing and designating the City, its elected officials, officers, employees, agents, and volunteers as additional named insureds by original endorsement shall be delivered to and approved by City prior to commencement of services. The procuring of such insurance and the delivery of policies, certificates, and endorsements evidencing the same shall not be construed as a limitation of Consultant's obligation to indemnify City, its elected officials, officers, agents,employees, and volunteers. 2. Minimum Scope of Insurance. The minimum amount of insurance required under this Agreement shall be as follows: 1. Comprehensive general liability and personal injury with limits of at least one million dollars ($1,000,000.00) combined single limit coverage per occurrence and two million dollars ($2,000,000) general aggregate; 2. Professional liability (errors and omissions) insurance with limits of at least one million dollars ($1,000,000.00) per occurrence and two million dollars ($2,000,000) annual aggregate is: required is not required; 3. Workers' Compensation insurance in the statutory amount as required by the State of California and Employer's Liability Insurance with limits of at least one million dollars $1 million per occurrence. If Consultant has no employees, Consultant shall complete the City's Request for Waiver of Workers' Compensation Insurance Requirement form. 3. Primary Insurance. For any claims related to this Agreement, Consultant's insurance coverage shall be primary with respect to the City and its respective elected officials, officers, employees, agents, and volunteers. Any insurance or self-insurance maintained by City and its respective elected officials, officers, employees, agents, and volunteers shall be in excess of Consultant's insurance and shall not contribute with it. For Workers' Compensation and Employer's Liability Insurance only, the insurer shall waive all rights of subrogation and contribution it may have against City, its elected officials, officers, employees, agents, and volunteers. 14 Revised: 11126/13 720599.1 4. Errors and Omissions Coverage. If Errors & Omissions Insurance is required, and if Consultant provides claims made professional liability insurance, Consultant shall also agree in writing either(1) to purchase tail insurance in the amount required by this Agreement to cover claims made within three years of the completion of Consultant's services under this Agreement, or (2) to maintain professional liability insurance coverage with the same carrier in the amount required by this Agreement for at least three years after completion of Consultant's services under this Agreement. Consultant shall also be required to provide evidence to City of the purchase of the required tail insurance or continuation of the professional liability policy. 5. Sufficiency of Insurers. Insurance required in this Agreement shall be provided by authorized insurers in good standing with the State of California. Coverage shall be provided by insurers admitted in the State of California with an A.M. Best's Key Rating of B++, Class VII, or better,unless otherwise acceptable to the City. 6. Verification of Coverage. Consultant shall fiimish City with both certificates of insurance and endorsements, including additional insured endorsements, effecting all of the coverages required by this Agreement. The certificates and endorsements are to be signed by a person authorized by that insurer to bind coverage on its behalf. All proof of insurance is to be received and approved by the City before work commences. City reserves the right to require Consultant's insurers to provide complete, certified copies of all required insurance policies at any time. Additional insured endorsements are not required for Errors and Omissions and Workers' Compensation policies. Verification of Insurance coverage may be provided by: (1) an approved General and/or Auto Liability Endorsement Form for the City of Palm Springs or(2) an acceptable Certificate of Liability Insurance Coverage with an approved Additional Insured Endorsement with the following endorsements stated on the certificate: 1. "The City of Palm Springs, its officials, employees, and agents are named as an additional insured... " ("as respects City of Palm Springs Contract Na" or 'for any and all work performed with the City"may be included in this statement). 2. "This insurance is primary and non-contributory over any insurance or self- insurance the City may have..." ("as respects City of Palm Springs Contract Na" or 'for any and all work performed with the City" may be included in this statement). 3. "Should any of the above described policies be canceled before the expiration date thereof, the issuing company will mail 30 days written notice to the Certificate Holder named." Language such as, "endeavor to" mail and "but failure to mail such notice shall impose no obligation or liability of any kind upon the company, its agents or representative" is not acceptable and must be crossed out. 4. Both the Workers' Compensation and Employers' Liability policies shall contain the insurer's waiver of subrogation in favor of City, its elected officials, officers, employees, agents, and volunteers. 15 Revised: 11/26/13 7205 W I In addition to the endorsements listed above, the City of Palm Springs shall be named the certificate holder on the policies. All certificates of insurance and endorsements are to be received and approved by the City before work commences. All certificates of insurance must be authorized by a person with authority to bind coverage, whether that is the authorized agentibroker or insurance underwriter. Failure to obtain the required documents prior to the commencement of work shall not waive the Consultant's obligation to provide them. 7. Deductibles and Self-Insured Retentions. Any deductibles or self-insured retentions must be declared to and approved by the City prior to commencing any work or services under this Agreement. At the option of the City, either (1) the insurer shall reduce or eliminate such deductibles or self-insured retentions with respect to the City, its elected officials, officers, employees, agents, and volunteers; or (2) Consultant shall procure a bond guaranteeing payment of losses and related investigations, claim administration, and defense expenses. Certificates of Insurance must include evidence of the amount of any deductible or self-insured retention under the policy. Consultant guarantees payment of all deductibles and self-insured retentions. 8. Severability of Interests (Separation of Insureds). This insurance applies separately to each insured against whom claim is made or suit is brought except with respect to the limits of the insurer's liability. 16 Revi d 11/26/13 .120?99.1 CONSULTING SERVICES AGREEMENT The Adams Company THIS AGREEMENT FOR CONSULTING SERVICES ("Agreement") is made and entered into on July 24, 2012,by and between the City of Palm Springs, a California charter city and municipal corporation ("City"), and The Adams Company, a Limited Liability Company, ("Consultant"). City and Consultant are individually referred to as "Party" and are collectively referred to as the "Parties". RECITALS A. City requires the services of an Independent Fee Consultant, for Design and Construction Management Services for Airport Improvement Projects, ("Project"). B. Consultant has submitted to City a proposal to provide independent fee consulting,to City under the terms of this Agreement. C. Based on its experience, education, training, and reputation, Consultant is qualified and desires to provide the necessary services to City for the Project. D. City desires to retain the services of Consultant for the Project. In consideration of these promises and mutual agreements,City agrees as follows: AGREEMENT 1. CONSULTANT SERVICES 1.1 Scope of Services. In compliance with all terms and conditions of this Agreement, Consultant shall provide Independent Fee Consulting services to City as described in the Scope of Services/Work attached to this Agreement as Exhibit "A" and incorporated by reference (the "services" or "work"). Exhibit "A" includes the agreed upon schedule of performance and the schedule of fees. Consultant warrants that all services and work shall be performed in a competent, professional, and satisfactory manner consistent with prevailing industry standards. In the event of any inconsistency between the terms contained in the Scope of Services/Work and the terms set forth in this Agreement,the terms set forth in this Agreement shall govern. 1.2 Compliance with Law. Consultant services rendered under this Agreement shall comply with all applicable federal, state, and local laws, statutes and ordinances and all lawful orders,rules, and regulations. 1.3 Licenses and Permits. Consultant shall obtain at its sole cost and expense such licenses, permits, and approvals as may be required by law for the performance of the services required by this Agreement. Revised:6116110 710599.1 ORIGINAL DID AND/OR AGREEMENT 1.4 Familiarity with Work. By executing this Agreement, Consultant warrants that it has carefully considered how the work should be performed and fully understands the facilities, difficulties, and restrictions attending performance of the work under this Agreement. 2. TIME FOR COMPLETION The time for completion of the services to be performed by Consultant is an essential condition of this Agreement. Consultant shall prosecute regularly and diligently the work of this Agreement according to the agreed upon schedule of performance set forth in Exhibit "A." Consultant shall not be accountable for delays in the progress of its work caused by any condition beyond its control and without the fault or negligence of Consultant. Delays shall not entitle Consultant to any additional compensation regardless of the parry responsible for the delay. 3. COMPENSATION OF CONSULTANT 3.1 Compensation of Consultant. Consultant shall be compensated and reimbursed for the services rendered under this Agreement in accordance with the schedule of fees set forth in Exhibit"A". The total amount of Compensation shall not exceed$5,000.00. 3.2 Method of Payment. In any month in which Consultant wishes to receive payment, Consultant shall submit to City an invoice for services rendered prior to the date of the invoice, no later than the first working day of such month, in the form approved by City's finance director. Payments shall be based on the hourly rates set forth in Exhibit "A" for authorized services performed. City shall pay Consultant for all expenses stated in the invoice that are approved by City and consistent with this Agreement, within thirty (30) days of receipt of Consultant's invoice. 3.3 Changes. In the event any change or changes in the Scope of Services/Work is requested by City, Parties shall execute a written amendment to this Agreement, specifying all proposed amendments, including, but not limited to, any additional fees. An amendment may be entered into: A. To provide for revisions or modifications to documents, work product, or work, when required by the enactment or revision of any subsequent law; or B. To provide for additional services not included in this Agreement or not customarily furnished in accordance with generally accepted practice in Consultant's profession. 3.4 Appropriations. This Agreement is subject to, and contingent upon, funds being appropriated by the City Council of City for each fiscal year. If such appropriations are not made, this Agreement shall automatically terminate without penalty to City. 4. PERFORMANCE SCHEDULE 4.1 Time of Essence. Time is of the essence in the performance of this Agreement. 2 Revised:6116/10 72OJ99.I 4.2 Schedule of Performance. All services rendered under this Agreement shall be performed under the agreed upon schedule of performance set forth in Exhibit "A." Any time period extension must be approved in writing by the Contract Officer. 4.3 Force Maieure. The time for performance of services to be rendered under this Agreement may be extended because of any delays due to unforeseeable causes beyond the control and without the fault or negligence of Consultant, if Consultant notifies the Contract Officer within ten (10) days of the commencement of such condition. Unforeseeable causes include, but are not limited to, acts of God or of a public enemy, acts of the government, fires, earthquakes, floods, epidemic, quarantine restrictions, riots, strikes, freight embargoes, and unusually severe weather. After Consultant notification, the Contract Officer shall investigate the facts and the extent of any necessary delay, and extend the time for performing the services for the period of the enforced delay when and if, in the Contract Officer's judgment, such delay is justified. The Contract Officer's determination shall be final and conclusive upon the parties to this Agreement. 4.4 Term. Unless earlier terminated in accordance with Section 4.5 of this Agreement, this Agreement shall continue in full force and effect for a period of fifteen days, commencing on July 24, 2012, and ending on August 8, 2012, unless extended by mutual written agreement of the parties. 4.5 Termination Prior to Expiration of Term. City may terminate this Agreement at any time, with or without cause, upon thirty (30) days written notice to Consultant. Where termination is due to the fault of Consultant and constitutes an immediate danger to health, safety, and general welfare, the period of notice shall be such shorter time as may be determined by the City. Upon receipt of the notice of termination, Consultant shall immediately cease all services except such as may be specifically approved by the Contract Officer. Consultant shall be entitled to compensation for all services rendered prior to receipt of the notice of termination and for any services authorized by the Contract Officer after such notice. Consultant may terminate this Agreement, with or without cause,upon thirty(30)days written notice to City. 5. COORDINATION OF WORK 5.1 Representative of Consultant. The following principal of Consultant is designated as being the principal and representative of Consultant authorized to act and make all decisions in its behalf with respect to the specified services and work: Gary Adams, President. It is expressly understood that the experience, knowledge, education, capability, and reputation of the foregoing principal is a substantial inducement for City to enter into this Agreement. Therefore, the foregoing principal shall be responsible during the term of this Agreement for directing all activities of Consultant and devoting sufficient time to personally supervise the services under this Agreement. The foregoing principal may not be changed by Consultant without prior written approval of the Contract Officer. 5.2 Contract Officer. The Contract Officer shall be the City Manager or his/her designee ("Contract Officer"). Consultant shall be responsible for keeping the Contract Officer fully informed of the progress of the performance of the services. Consultant shall refer any 3 Revised:6/16/10 720549.1 decisions that must be made by City to the Contract Officer. Unless otherwise specified, any approval of City shall mean the approval of the Contract Officer. 5.3 Prohibition Against Subcontracting or Assignment. The experience, knowledge, education, capability, and reputation of Consultant, its principals and employees, were a substantial inducement for City to enter into this Agreement. Therefore, Consultant shall not contract with any other individual or entity to perform any services required under this Agreement without the City's express written approval. hi addition, neither this Agreement nor any interest may be assigned or transferred, voluntarily or by operation of law, without the prior written approval of City. 5.4 Independent Contractor. Neither City nor any of its employees shall have any control over the manner, mode, or means by which Consultant, its agents or employees,perform the services required, except as otherwise specified. Consultant shall perform all required services as an independent contractor of City and shall not be an employee of City and shall remain at all times as to City a wholly independent contractor with only such obligations as are consistent with that role; however, City shall have the right to review Consultant's work product, result, and advice. Consultant shall not at any time or in any manner represent that it or any of its agents or employees are agents or employees of City. 5.5 Personnel. Consultant agrees to assign the following individuals to perform the services in this Agreement. Consultant shall not alter the assignment of the following personnel without the prior written approval of the Contract Officer. Acting through the City Manager, the City shall have the unrestricted right to order the removal of any personnel assigned by Consultant by providing written notice to Consultant. Name: Title: Gary Adams President 6. INSURANCE Consultant shall procure and maintain, at its sole cost and expense, policies of insurance as set forth in the attached Exhibit "B", incorporated herein by reference. 7. INDEMNIFICATION. 7.1 Indemnification. To the fullest extent permitted by law, Consultant shall defend (at Consultant's sole cost and expense), indemnify, protect, and hold harmless City, its elected officials, officers, employees, agents, and volunteers (collectively the "Indemnified Parties"), from and against any and all liabilities, actions, suits, claims, demands, losses, costs, judgments, arbitration awards, settlements, damages, demands, orders, penalties, and expenses including legal costs and attorney fees (collectively "Claims"), including but not limited to Claims arising from injuries to or death of persons (Consultant's employees included), for damage to property, including property owned by City, from any violation of any federal, state, 4 Revised:6116/10 730599.1 or local law or ordinance, and from errors and omissions committed by Consultant, its officers, employees, representatives, and agents, that arise out of or relate to Consultant's performance under this Agreement. This indemnification clause excludes Claims arising from the sole negligence or willful misconduct of the City, its elected officials, officers, employees, agents, and volunteers. Under no circumstances shall the insurance requirements and limits set forth in this Agreement be construed to limit Consultant's indemnification obligation or other liability under this Agreement. Consultant's indemnification obligation shall survive the expiration or earlier termination of this Agreement until all actions against the Indemnified Parties for such matters indemnified are fully and finally barred by the applicable statute of limitations or, if an action is timely filed,until such action is final. This provision is intended for the benefit of third party Indemnified Parties not otherwise a party to this Agreement. 7.2 Desian Professional Services Indemnification and Reimbursement. If the Agreement is determined to be a "design professional services agreement" and Consultant is a "design professional"under California Civil Code Section 2782.8, then: A. To the fullest extent permitted by law, Consultant shall indemnify, defend (at Consultant's sole cost and expense), protect and hold harmless City and its elected officials, officers, employees, agents and volunteers and all other public agencies whose approval of the project is required, (individually"Indemnified Party'; collectively"Indemnified Parties") against any and all liabilities, claims,judgments, arbitration awards, settlements, costs, demands, orders and penalties (collectively"Claims"), including but not limited to Claims arising from injuries or death of persons (Consultant's employees included) and damage to property, which Claims arise out of, pertain to, or are related to the negligence, recklessness or willful misconduct of Consultant, its agents, employees, or subcontractors, or arise from Consultant's negligent, reckless or willful performance of or failure to perform any tern, provision, covenant or condition of this Agreement ("Indemnified Claims"), but Consultant's liability for Indemnified Claims shall be reduced to the extent such Claims arise from the negligence, recklessness or willful misconduct of the City and its elected officials, officers, employees, agents and volunteers. B. The Consultant shall require all non-design-professional sub-contractors, used or sub-contracted by Consultant to perform the Services or Work required under this Agreement, to execute an Indemnification Agreement adopting the indemnity provisions in sub- section 7.1 in favor of the Indemnified Parties. In addition, Consultant shall require all non- design-professional sub-contractors, used or sub-contracted by Consultant to perform the Services or Work required under this Agreement, to obtain insurance that is consistent with the Insurance provisions as set forth in this Agreement, as well as any other insurance that may be required by Contract Officer. 8. RECORDS AND REPORTS 8.1 Resorts. Consultant shall periodically prepare and submit to the Contract Officer reports concerning the performance of the services required by this Agreement, or as the Contract Officer shall require. 5 Revised:6116/10 720599.1 8.2 Records. Consultant shall keep complete, accurate, and detailed accounts of all time, costs, expenses, and expenditures pertaining in any way to this Agreement. Consultant shall keep such books and records as shall be necessary to properly perform the services required by this Agreement and enable the Contract Officer to evaluate the performance of such services. The Contract Officer shall have full and free access to such books and records at all reasonable times, including the right to inspect, copy, audit, and make records and transcripts from such records. 8.3 Ownership of Documents. All drawings, specifications, reports, records, documents, and other materials prepared by Consultant in the performance of this Agreement shall be the property of City. Consultant shall deliver all above-referenced documents to City upon request of the Contract Officer or upon the termination of this Agreement. Consultant shall have no claim for further employment or additional compensation as a result of the exercise by City of its full rights or ownership of the documents and materials. Consultant may retain copies of such documents for Consultant's own use. Consultant shall have an unrestricted right to use the concepts embodied in such documents. 8.4 Release of Documents. All drawings, specifications, reports, records, documents, and other materials prepared by Consultant in the performance of services under this Agreement shall not be released publicly without the prior written approval of the Contract Officer. 8.5 Cost Records. Consultant shall maintain all books, documents, papers, employee time sheets, accounting records, and other evidence pertaining to costs incurred while performing under this Agreement. Consultant shall make such materials available at its offices at all reasonable times during the term of this Agreement and for three (3) years from the date of final payment for inspection by City and copies shall be promptly furnished to City upon request. 9. ENFORCEMENT OF AGREEMENT 9.1 California Law. This Agreement shall be construed and interpreted both as to validity and to performance of the parties in accordance with the laws of the State of California. Legal actions concerning any dispute, claim, or matter arising out of or in relation to this Agreement shall be instituted in the Superior Court of the County of Riverside, State of California, or any other appropriate court in such county, and Consultant covenants and agrees to submit to the personal jurisdiction of such court in the event of such action. 9.2 Interpretation. This Agreement shall be construed as a whole according to its fair language and common meaning to achieve the objectives and purposes of the Parties. The terms of this Agreement are contractual and the result of negotiation between the Parties. Accordingly, any rule of construction of contracts (including, without limitation, California Civil Code Section 1654) that ambiguities are to be construed against the drafting party, shall not be employed in the interpretation of this Agreement. The caption headings of the various sections and paragraphs of this Agreement are for convenience and identification purposes only and shall not be deemed to limit, expand, or define the contents of the respective sections or paragraphs. Revised:6/16/10 P_0599.1 9.3 Waiver. No delay or omission in the exercise of any right or remedy of a non- defaulting parry on any default shall impair such right or remedy or be construed as a waiver. No consent or approval of City shall be deemed to waive or render unnecessary City's consent to or approval of any subsequent act of Consultant. Any waiver by either party of any default must be in writing. No such waiver shall be a waiver of any other default concerning the same or any other provision of this Agreement. 9.4 Rights and Remedies are Cumulative. Except with respect to rights and remedies expressly declared to be exclusive in this Agreement, the rights and remedies of the parties are cumulative. The exercise by either parry of one or more of such rights or remedies shall not preclude the exercise by it, at the same or different times, of any other rights or remedies for the same default or any other default by the other party. 9.5 Leeal Action. In addition to any other rights or remedies, either party may take legal action, in law or in equity, to cure, correct, or remedy any default, to recover damages for any default, to compel specific performance of this Agreement, to obtain injunctive relief, a declaratory judgment, or any other remedy consistent with the purposes of this Agreement. 10. CITY OFFICERS AND EMPLOYEES: NON-DISCRIMINATION 10.1 Non-Liability of City Officers and Employees. No officer or employee of City shall be personally liable to the Consultant, or any successor-in-interest, in the event of any default or breach by City or for any amount which may become due to the Consultant or its successor, or for breach of any obligation of the terms of this Agreement. 10.2 Conflict of Interest. No officer or employee of the City shall have any direct or indirect financial interest in this Agreement nor shall any such officer or employee participate in any decision relating to the Agreement which effects their financial interest or the financial interest of any corporation, partnership, or association in which he/she is, directly or indirectly, interested in violation of any state statute or regulation. Consultant warrants that Consultant has not paid or given, and will not pay or give, any third party any money or other consideration in exchange for obtaining this Agreement. 10.3 Covenant Asainst Discrimination. Consultant covenants that, by and for itself, its heirs, executors, assigns, and all persons claiming under or through them, that there shall be no discrimination or segregation in the performance of or in connection with this Agreement regarding any person or group of persons on account of race, color, creed, religion, sex, marital status, disability, sexual orientation,national origin, or ancestry. 11. MISCELLANEOUS PROVISIONS 11.1 Notice. Any notice, demand, request, consent, approval, or communication that either party desires, or is required to give to the other party or any other person shall be in writing and either served personally or sent by pre-paid, first-class mail to the address set forth below. Notice shall be deemed communicated seventy-two (72) hours from the time of mailing if mailed as provided in this Section. Either party may change its address by notifying the other party of the change of address in writing. 7 Revised:6/16/10 7'_0599.1 To City: City of Palm Springs Attention: City Manager/City Clerk 3200 E. Tahquitz Canyon Way Palm Springs, California 92262 To Consultant: The Adams Companies 1508 W. Tara Drive 1508 Gilbert, AZ 85233 11.2 Integrated Agreement. This Agreement contains all of the agreements of the parties and supersedes all other written agreements. 11.3 Amendment. No amendments or other modifications of this Agreement shall be binding unless through written agreement by all Parties. 11.4 Severability. Whenever possible, each provision of this Agreement shall be interpreted in such a manner as to be effective and valid under applicable law. In the event that any one or more of the phrases, sentences, clauses, paragraphs, or sections contained in this Agreement shall be declared invalid or unenforceable by valid judgment or decree of a court of competent jurisdiction, such invalidity or unenforceability shall not affect any of the remaining phrases, sentences, clauses,paragraphs, or sections of this Agreement, which shall be interpreted to carry out the intent of the parties. 11.5 Successors in Interest. This Agreement shall be binding upon and inure to the benefit of the Parties' successors and assignees. 11.6 Third Party Beneficiary. Except as may be expressly provided for in this Agreement, nothing contained in this Agreement is intended to confer, nor shall this Agreement be construed as conferring, any rights, including, without limitation, any rights as a third-party beneficiary or otherwise, upon any entity or person not a party to this Agreement. 11.7 Recitals. The above-referenced Recitals are hereby incorporated into the Agreement as though fully set forth in this Agreement and each Party acknowledges and agrees that such Party is bound, for purposes of this Agreement,by the same. 11.8 Authority. The persons executing this Agreement on behalf of the Parties warrant that they are duly authorized to execute this Agreement on behalf of Parties and that by so executing this Agreement the Parties are formally bound to the provisions of this Agreement. 8 Revised:6/16/10 720599.1 IN WITNESS WHEREOF, the Parties have executed this Agreement as of the dates stated below. "CITY" By: �— City of Palm Springs Thomas Irolan, A.A.E. Executive Director Date: $�QI'Ja By: ,mom- i vo David H. Ready �} f J%r6 City Manager Q APPROVED AS TO FORM: ATTEST By: By: ouglas . Hollan , ;;� ames Thompson, City Attome City Clerk "CO SULTANT" T Adams Companies Date: y Gary Adams,President IQ/ Date: 000 APPROVED BY DEPARMENT HEAD 9 Revised:6/16/10 720599.1 IN WITNESS WHEREOF, the Parties have executed this Agreement as of the dates stated below. "CITY" BY City of Palm Sprin Thomas Nolan, A.A.E. Executive Director Date: g�0�' ia By: d H. Ready ity Manager APPROVED AS TO FORM:: ATTEST By: By: Douglas C. Holland, James Thompson, City Attorney City Clerk "CONSULTANT" The Adams Companies Date: So 17 'k0 I Z By : Garkjkd4us,President Date: : 01 2 71 2,01 Z QV-V � ;L"td � (name) f��melq S. I�Q1del-/lda�ts (secretory) - 9 Revise0:&16110 720599.1 EXHIBIT "A" CONSULTANT'S SCOPE OF SERVICES/WORK Including, Schedule of Fees and Schedule and Performance Scope Summary of Fees: IFE for Airport Apron and Taxiway Design, Not to exceed $5000.00 Schedule: Work for this project to be completed no later than August 8, 2012 Scope: The performance of this project by the Adams Company will be conducted solely from the firm's Arizona office. The firm will review the scope of services developed by Parson Brinckerhoff Inc. for the Palm Springs International Airport Improvement Grant Project. The scope will be reviewed task-by-task with analysis for total project hours necessary to perform the design and engineering services for this AIP eligible project, also the total project cost will be projected in an independent manor acceptable with FAA standards. Reviewing project details to ensure that all required services for the project,based on the consultant's expertise are thoroughly addressed in accordance with Federal guidelines for work of this type. The Adams Company will provide to the Palm Springs International Airport a cost breakdown structure and cost estimate by task. The cost breakdown structure will consider the level of staff skills necessary to effectively complete each task, staff hours,and any other cost considerations, such as direct costs which may be needed for the acquisition of data or travel related expenses. This cost breakdown will be similar in format to Appendix F of the Advisory Circular 150/5100-14D. The Adams Company will provide a detailed cover letter with an explanation of costs and a separate comprehensive spreadsheet of the independent fee estimate to the Palm Springs International Airport,both in hard copy and electronically. Report details will follow all FAA Requirements and standards. EXHIBIT "B" INSURANCE PROVISIONS Including Verification of Coverage, Sufficiency of Insurers, Errors and Omissions Coverage, Minimum Scope of Insurance, Deductibles and Self-Insured Retentions, and Severability of Interests (Separation of Insureds) 12 Revised:6/16110 INSURANCE 1. Procurement and Maintenance of Insurance. Consultant shall procure and maintain public liability and property damage insurance against all claims for injuries against persons or damages to property resulting from Consultant's performance under this Agreement. Consultant shall procure and maintain all insurance at its sole cost and expense, in a form and content satisfactory to the City, and submit concurrently with its execution of this Agreement. Consultant shall also carry workers' compensation insurance in accordance with California workers' compensation laws. Such insurance shall be kept in full force and effect during the term of this Agreement, including any extensions. Such insurance shall not be cancelable without thirty(30)days advance written notice to City of any proposed cancellation. Certificates of insurance evidencing the foregoing and designating the City, its elected officials, officers, employees, agents, and volunteers as additional named insureds by original endorsement shall be delivered to and approved by City prior to commencement of services. The procuring of such insurance and the delivery of policies, certificates, and endorsements evidencing the same shall not be construed as a limitation of Consultant's obligation to indemnify City, its elected officials, officers, agents, employees, and volunteers. 2. Minimum Scope of Insurance. The minimum amount of insurance required under this Agreement shall be as follows: 1. Comprehensive general liability and personal injury with limits of at least one million dollars ($1,000,000.00) combined single limit coverage per occurrence and two million dollars ($2,000,000) general aggregate; 2. Automobile liability insurance with limits of at least one million dollars ($1,000,000.00)per occurrence; 3. Professional liability (errors and omissions) insurance with limits of at least one million dollars ($1,000,000.00) per occurrence and two million dollars ($2,000,000) annual aggregate is: #3 required #1,#2,#4 is not required; 4. Workers' Compensation insurance in the statutory amount as required by the State of California and Employer's Liability Insurance with limits of at least one million dollars $1 million per occurrence. If Consultant has no employees, Consultant shall complete the City's Request for Waiver of Workers' Compensation Insurance Requirement form. 3. Primary Insurance. For any claims related to this Agreement, Consultant's insurance coverage shall be primary with respect to the City and its respective elected officials, officers, employees, agents, and volunteers. Any insurance or self-insurance maintained by City and its respective elected officials, officers, employees, agents, and volunteers shall be in excess of Consultant's insurance and shall not contribute with it. For Workers' Compensation and Employer's Liability Insurance only, the insurer shall waive all rights of subrogation and 13 Revised:6/16/10 720599.1 contribution it may have against City, its elected officials, officers, employees, agents, and volunteers. 4. Errors and Omissions Coverage. If Errors & Omissions Insurance is required, and if Consultant provides claims made professional liability insurance, Consultant shall also agree in writing either(1) to purchase tail insurance in the amount required by this Agreement to cover claims made within three years of the completion of Consultant's services under this Agreement, or (2) to maintain professional liability insurance coverage with the same carrier in the amount required by this Agreement for at least three years after completion of Consultant's services under this Agreement. Consultant shall also be required to provide evidence to City of the purchase of the required tail insurance or continuation of the professional liability policy. 5. Sufficiency of Insurers. Insurance required in this Agreement shall be provided by authorized insurers in good standing with the State of California. Coverage shall be provided by insurers admitted in the State of California with an A.M. Best's Key Rating of B++, Class VII, or better,unless otherwise acceptable to the City. 6. Verification of Coverage. Consultant shall furnish City with both certificates of insurance and endorsements, including additional insured endorsements, effecting all of the coverages required by this Agreement. The certificates and endorsements are to be signed by a person authorized by that insurer to bind coverage on its behalf. All proof of insurance is to be received and approved by the City before work commences. City reserves the right to require Consultant's insurers to provide complete, certified copies of all required insurance policies at any time. Additional insured endorsements are not required for Errors and Omissions and Workers' Compensation policies. Verification of Insurance coverage may be provided by: (1) an approved General and/or Auto Liability Endorsement Form for the City of Palm Springs or(2) an acceptable Certificate of Liability Insurance Coverage with an approved Additional Insured Endorsement with the following endorsements stated on the certificate: 1. "The City of Palm Springs, its officials, employees, and agents are named as an additional insured... " ("as respects City of Palm Springs Contract Na" or 'for any and all workperformed with the City"may be included in this statement). 2. "This insurance is primary and non-contributory over any insurance or self- insurance the City may have..." ("as respects City of Palm Springs Contract No._" or 'for any and all work performed with the City" may be included in this statement). 3. "Should any of the above described policies be canceled before the expiration date thereof, the issuing company will mail 30 days written notice to the Certificate Holder named." Language such as, "endeavor to"mail and "but failure to mail such notice shall impose no obligation or liability of any kind upon the company, its agents or representative" is not acceptable and must be crossed out. 14 Revised:6/16/10 20599.1 4. Both the Workers' Compensation and Employers' Liability policies shall contain the insurer's waiver of subrogation in favor of City, its elected officials, officers, employees, agents,and volunteers. In addition to the endorsements listed above, the City of Palm Springs shall be named the certificate holder on the policies. All certificates of insurance and endorsements are to be received and approved by the City before work commences. All certificates of insurance must be authorized by a person with authority to bind coverage, whether that is the authorized agent/broker or insurance underwriter. Failure to obtain the required documents prior to the commencement of work shall not waive the Consultant's obligation to provide them. 7. Deductibles and Self-Insured Retentions. Any deductibles or self-insured retentions must be declared to and approved by the City prior to commencing any work or services under this Agreement. At the option of the City, either (1) the insurer shall reduce or eliminate such deductibles or self-insured retentions with respect to the City, its elected officials, officers, employees, agents, and volunteers; or(2) Consultant shall procure a bond guaranteeing payment of losses and related investigations, claim administration, and defense expenses. Certificates of Insurance must include evidence of the amount of any deductible or self-insured retention under the policy. Consultant guarantees payment of all deductibles and self-insured retentions. S. Severability of Interests (Separation of Insureds). This insurance applies separately to each insured against whom claim is made or suit is brought except with respect to the limits of the insurer's liability. 15 Revised:6/16110 72009.1