Loading...
HomeMy WebLinkAbout24I397 - Willams Scotsman, Inc.CONTRACT ABSTRACT Contract/Amendment Name of Contract: Company Name: Company Contact: Email: Summary of Services: Contract Price: Contract Term: Public Integrity/ Business Disclosure Forms: Contract Administration Lead Department: Contract Administrator/ Ext: Contract Approvals Council/City Manager Approval Date: Agreement Number: Amendment Number: Contract Compliance Exhibits: Insurance: Routed By: Bonds: Business License: Sole Source Co-Op CoOp Agmt #: Sole Source Documents: CoOp Name: CoOp Pricing: By: Submitted on: Contract Abstract Form Rev 8.16.23 Authorized Signers: Name, Email (Corporations require 2 signatures) Williams Scotsman, Inc FY2025-2026 Willams Scotsman, Inc. Robert Henlon, Jr. Robert.Henlon@willscot.com Rental of storage units for the Parks & Recreation department supplies. $10,669.44 December 1, 2024 - November 30, 2026 Waleed Almanasrah, waleed.almanasrah@willscot.com Joseph Leppert, joseph.leppert@willscot.com Parks & Recreation Nicholas Gonzalez, Director/ Ext. 8277 N/A 241397 1 Yes Yes Yes Department N/A No 01/30/25 Janet Burns Docusign Envelope ID: EC4EFB2F-9404-4DCB-9F7E-187BBA4CDD61 Page 1 of 3 Revised: 10.31.23 AMENDMENT NO. 1 TO THE CONTRACT SERVICES AGREEMENT 241397 BETWEEN THE CITY PALM SPRINGS AND WILLIAMS SCOTSMAN, INC. 1. Parties and Date. This Amendment No. 1 to the Contract Services Agreement is made and entered into as of this 30th day of January, 2025, by and between the City of Palm Springs (“City”) and Williams Scotsman, Inc., a Maryland Corporation (“Contractor”). City and Contractor are sometimes individually referred to as “Party” and collectively as “Parties.” 2. Recitals. 2.1 Agreement. The City and Contractor have entered into an agreement entitled “Contract Services Agreement 241397” dated December 1, 2024, (“Agreement”) for the purpose of retaining the services of Contractor to provide rental of portable storage units for an amount not to exceed $212.22 per month for a two year period or not to exceed $10,669.44 for the two year term and a term of December 1, 2024 to November 30, 2026. 2.2 Amendment. The City and Contractor desire to amend the Agreement to revise the compensation verbiage to clarify the “not to exceed amount.” 2.4 Amendment Authority. This Amendment No. 1 is authorized pursuant to Section 3.3 of the Agreement. 3. Terms. 3.1 Compensation of Contractor. Section 3.1 of the Agreement is hereby amended in its entirety to read as follows: “Contractor shall be compensated and reimbursed for the services rendered under this Agreement in accordance with the schedule of fees set forth in Exhibit “A”. The total amount of Compensation shall not exceed $10,669.44.” 3.2 Continuing Effect of Agreement. Except as amended by this Amendment No. 1, all other provisions of the Agreement remain in full force and effect and shall govern the actions of the parties under this Amendment No. 1. From and after the date of this Amendment No. 1, whenever the term “Agreement” or “Contract” appears in the Agreement, it shall mean the Agreement as amended by this Amendment No. 1. 3.3 Adequate Consideration. The Parties hereto irrevocably stipulate and agree that they have each received adequate and independent consideration for the performance of the obligations they have undertaken pursuant to this Amendment No. 1. Docusign Envelope ID: EC4EFB2F-9404-4DCB-9F7E-187BBA4CDD61 Page 2 of 3 Revised: 10.31.23 3.4 Severability. If any portion of this Amendment No. 1 is declared invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions shall continue in full force and effect. 3.5 Counterparts. This Amendment No. 1 may be executed in duplicate originals, each of which is deemed to be an original, but when taken together shall constitute but one and the same instrument. [SIGNATURES ON FOLLOWING PAGE] Docusign Envelope ID: EC4EFB2F-9404-4DCB-9F7E-187BBA4CDD61 Page 3 of 3 Revised: 10.31.23 SIGNATURE PAGE TO AGREEMENT BY AND BETWEEN THE CITY OF PALM SPRINGS AND WILLIAMS SCOTSMAN, INC. IN WITNESS WHEREOF, the Parties have executed this Agreement as of the dates stated below. CONTRACTOR: By: _______________________________________ By: _________________________________________ Signature Signature (2nd signature required for Corporations) Date: Date: CITY OF PALM SPRINGS: APPROVED BY CITY COUNCIL: Date: N/A Item No. N/A APPROVED AS TO FORM: ATTEST: By: ___________________________ By: _______________________________ City Attorney City Clerk APPROVED: By: _______________________________ Date: City Manager – over $50,000 Deputy/Assistant City Manager – up to $50,000 Director – up to $25,000 Manager – up to $5,000 Docusign Envelope ID: EC4EFB2F-9404-4DCB-9F7E-187BBA4CDD61 2/3/2025 2/3/2025 2/4/2025 2/5/2025 2/5/2025 CONTRACT ABSTRACT Contract/Amendment Name of Contract: Company Name: Company Contact: Email: Summary of Services: Contract Price: Contract Term: Public Integrity/ Business Disclosure Forms: Contract Administration Lead Department: Contract Administrator/ Ext: Contract Approvals Council/City Manager Approval Date: Agreement Number: Amendment Number: Contract Compliance Exhibits: Insurance: Routed By: Bonds: Business License: Sole Source Co-Op CoOp Agmt #: Sole Source Documents: CoOp Name: CoOp Pricing: By: Submitted on: Contract Abstract Form Rev 8.16.23 Authorized Signers: Name, Email (Corporations require 2 signatures) Williams Scotsman, Inc FY2025-2026 Willams Scotsman, Inc. Robert Henlon, Jr. Robert.Henlon@willscot.com Rental of storage units for the Parks & Recreation department supplies. $10,669.44 December 1, 2024 - November 30, 2026 Waleed Almanasrah, waleed.almanasrah@willscot.com Joseph Leppert, joseph.leppert@willscot.com Parks & Recreation Nicholas Gonzalez, Director/ Ext. 8277 N/A 241397 N/A Yes Yes Yes Department N/A No 01/17/25 Janet Burns Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 Revised 4.13.23 Page 1 of 18 CONTRACT SERVICES AGREEMENT 241397 WILLIAMS SCOTSMAN, INC FY2025-2026 THIS AGREEMENT FOR CONTRACT SERVICES (“Agreement”) is made and entered into on December 1, 2024, by and between the City of Palm Springs, a California charter city and municipal corporation (“City”), and Williams Scotsman, Inc., a Maryland Corporation, (“Contractor”). City and Contractor are individually referred to as “Party” and are collectively referred to as the “Parties”. RECITALS A. City requires the services of a licensed and qualified vendor to provide rental of storage units for the Parks & Recreation department supplies, (“Project”). B. Contractor has submitted to City a quote to provide rental of portable storage units, to City under the terms of this Agreement. C. Based on its experience, education, training, and reputation, Contractor is qualified and desires to provide the necessary services to City for the Project. D. City desires to retain the services of Contractor for the Project. NOW, THEREFORE, in consideration of the promises and mutual obligations, covenants, and conditions contained herein, and other valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties agree as follows: AGREEMENT 1. CONTRACTOR SERVICES 1.1 Scope of Services. In compliance with all terms and conditions of this Agreement, Contractor shall provide services to City as described in the Scope of Services/Work attached to this Agreement as Exhibit “A” and incorporated herein by reference (the “Services” or “Work”). Exhibit "A" includes the agreed upon schedule of performance and the schedule of fees. Contractor warrants that the Services shall be performed in a competent, professional, and satisfactory manner consistent with the level of care and skill ordinarily exercised by high quality, experienced, and well qualified members of the profession currently practicing under similar conditions. In the event of any inconsistency between the terms contained in the Scope of Services/Work and the terms set forth in this Agreement, the terms set forth in this Agreement shall govern. 1.2 Compliance with Law. Contractor shall comply with all applicable federal, state, and local laws, statutes and ordinances and all lawful orders, rules, and regulations when performing the Services. Contractor shall be liable for all violations of such laws and regulations in connection with the Services and this Agreement. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 Revised 4.13.23 Page 2 of 18 1.3 Licenses and Permits. Contractor shall obtain at its sole cost and expense such licenses, permits, and approvals as may be required by law for the performance of the Services required by this Agreement. 1.4 Familiarity with Work. By executing this Agreement, Contractor warrants that it has carefully considered how the Work should be performed and fully understands the facilities, difficulties, and restrictions attending performance of the Work under this Agreement. 2. TIME FOR COMPLETION The time for completion of the Services to be performed by Contractor is an essential condition of this Agreement. Contractor shall prosecute regularly and diligently the work of this Agreement according to the agreed upon schedule of performance set forth in Exhibit “A.” Neither Party shall be accountable for delays in performance caused by any condition beyond the reasonable control and without the fault or negligence of the non-performing Party. Delays shall not entitle Contractor to any additional compensation regardless of the Party responsible for the delay. 3. COMPENSATION OF CONTRACTOR 3.1 Compensation of Contractor. Contractor shall be compensated and reimbursed for the services rendered under this Agreement in accordance with the schedule of fees set forth in Exhibit “A”. The total amount of Compensation shall not exceed $212.22 per month for a two year period or not to exceed $10,669.44 for the two year term. 3.2 Method of Payment. In any month in which Contractor wishes to receive payment, Contractor shall submit to City an invoice for Services rendered prior to the date of the invoice, no later than the first working day of such month, in the form approved by City’s finance director. Payments shall be based on the hourly rates set forth in Exhibit “A” for authorized services performed. City shall pay Contractor for all expenses stated in the invoice that are approved by City and consistent with this Agreement, within thirty (30) days of receipt of Contractor’s invoice. 3.3 Changes. In the event any change or changes in the Services is requested by City, Parties shall execute a written amendment to this Agreement, specifying all proposed amendments, including, but not limited to, any additional fees. An amendment may be entered into: A. To provide for revisions or modifications to documents, work product, or Work, when required by the enactment or revision of any subsequent law; or B. To provide for additional services not included in this Agreement or not customarily furnished in accordance with generally accepted practice in Contractor’s profession. 3.4 Appropriations. This Agreement is subject to, and contingent upon, funds being appropriated by the City Council of City for each fiscal year. If such appropriations are not made, this Agreement shall automatically terminate without penalty to City. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 Revised 4.13.23 Page 3 of 18 4. PERFORMANCE SCHEDULE 4.1 Time of Essence. Time is of the essence in the performance of this Agreement. 4.2 Schedule of Performance. All Services rendered under this Agreement shall be performed under the agreed upon schedule of performance set forth in Exhibit “A.” Any time period extension must be approved in writing by the Contract Officer. 4.3 Force Majeure. The time for performance of Services to be rendered under this Agreement may be extended because of any delays due to a Force Majeure Event, if Contractor notifies the Contract Officer within ten (10) days of the commencement of the Force Majeure Event. A Force Majeure Event shall mean an event that materially affects the Contractor’s performance and is one or more of the following: (1) Acts of God or other natural disasters occurring at the project site; (2) terrorism or other acts of a public enemy; (3) orders of governmental authorities (including, without limitation, unreasonable and unforeseeable delay in the issuance of permits or approvals by governmental authorities that are required for the Work); and (4) pandemics, epidemics or quarantine restrictions. For purposes of this section, “orders of governmental authorities,” includes ordinances, emergency proclamations and orders, rules to protect the public health, welfare and safety, and other actions of the City in its capacity as a municipal authority. After Contractor notification, the Contract Officer shall investigate the facts and the extent of any necessary delay and extend the time for performing the Services for the period of the enforced delay when and if, in the Contract Officer’s judgment, such delay is justified. The Contract Officer’s determination shall be final and conclusive upon the Parties to this Agreement. The Contractor will not receive an adjustment to the contract price or any other compensation. Notwithstanding the foregoing, the City may still terminate this Agreement in accordance with the termination provisions of this Agreement. 4.4 Term. Unless earlier terminated in accordance with Section 4.5 of this Agreement, this Agreement shall continue in full force and effect for a period of two years, commencing on December 1, 2024, and ending on November 30, 2026, unless extended by mutual written agreement of the Parties. 4.5 Termination Prior to Expiration of Term. City may terminate this Agreement at any time, with or without cause, upon thirty (30) days written notice to Contractor. Where termination is due to the fault of Contractor and constitutes an immediate danger to health, safety, and general welfare, the period of notice shall be such shorter time as may be determined by the City. Upon receipt of the notice of termination, Contractor shall immediately cease all Services except such as may be specifically approved by the Contract Officer. Contractor shall be entitled to compensation for all Services rendered prior to receipt of the notice of termination and for any Services authorized by the Contract Officer after such notice. City shall not be liable for any costs other than the charges or portions thereof which are specified herein. Contractor shall not be entitled to payment for unperformed Services and shall not be entitled to damages or compensation for termination of Work. If the termination is for cause, the City shall have the right to take whatever steps it deems necessary to correct Contractor's deficiencies and charge the cost thereof to Contractor, who shall be liable for the full cost of the City's corrective action. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 Revised 4.13.23 Page 4 of 18 Contractor may not terminate this Agreement except for cause, upon thirty (30) days written notice to City. 5. COORDINATION OF WORK 5.1 Representative of Contractor. The following principal of Contractor is designated as being the principal and representative of Contractor authorized to act and make all decisions in its behalf with respect to the specified Services: Robert Henlon, Jr., Sales Representative II. It is expressly understood that the experience, knowledge, education, capability, and reputation of the foregoing principal is a substantial inducement for City to enter into this Agreement. Therefore, the foregoing principal shall be responsible during the term of this Agreement for directing all activities of Contractor and devoting sufficient time to personally supervise the Services under this Agreement. The foregoing principal may not be changed by Contractor without prior written approval of the Contract Officer. 5.2 Contract Officer. The Contract Officer shall be the City Manager or his/her designee ("Contract Officer"). Contractor shall be responsible for keeping the Contract Officer fully informed of the progress of the performance of the Services. Contractor shall refer any decisions that must be made by City to the Contract Officer. Unless otherwise specified, any approval of City shall mean the approval of the Contract Officer. 5.3 Prohibition Against Subcontracting or Assignment. The experience, knowledge, education, capability, and reputation of Contractor, its principals and employees, were a substantial inducement for City to enter into this Agreement. Contractor shall not contract with any other individual or entity to perform any Services required under this Agreement without the City's express written approval. In addition, neither this Agreement nor any interest may be assigned or transferred, voluntarily or by operation of law, without the prior written approval of City. Subcontracts, if any, shall contain a provision making them subject to all provisions stipulated in this Agreement including without limitation the insurance and indemnification requirements. If Contractor is permitted to subcontract any part of this Agreement by City, Contractor shall be responsible to City for the acts and omissions of its subcontractor(s) in the same manner as it is for persons directly employed. Nothing contained in this Agreement shall create any contractual relationships between any subcontractor and City. 5.4 Independent Contractor. Neither City nor any of its employees shall have any control over the manner, mode, or means by which Contractor, its agents or employees, perform the Services required, except as otherwise specified. Contractor shall perform all required Services as an independent contractor of City and shall not be an employee of City and shall remain at all times as to City a wholly independent contractor with only such obligations as are consistent with that role; however, City shall have the right to review Contractor’s work product, result, and advice. Contractor shall not at any time or in any manner represent that it or any of its agents or employees are agents or employees of City. Contractor shall pay all wages, salaries, and other amounts due personnel in connection with their performance under this Agreement and as required by law. Contractor shall be responsible for all reports and obligations respecting such personnel, including, but not limited to: social security taxes, income tax withholding, unemployment insurance, and workers’ compensation insurance. Contractor shall not have any authority to bind City in any manner. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 Revised 4.13.23 Page 5 of 18 5.5 Personnel. Contractor agrees to assign the following individuals to perform the services in this Agreement. Contractor shall not alter the assignment of the following personnel without the prior written approval of the Contract Officer. Acting through the City Manager, the City shall have the unrestricted right to order the removal of any personnel assigned by Contractor by providing written notice to Contractor. Name: Title: Robert Henlon, Jr. Sales Representative II 5.6 California Labor Code Requirements. A. Contractor is aware of the requirements of California Labor Code Sections 1720 et seq. and 1770 et seq., which require the payment of prevailing wage rates and the performance of other requirements on certain “public works” and “maintenance” projects (“Prevailing Wage Laws”). If the Services are being performed as part of an applicable “public works” or “maintenance” project, as defined by the Prevailing Wage Laws, and if the total compensation is $15,000 or more for maintenance or $25,000 or more for construction, alteration, demolition, installation, or repair, Contractor agrees to fully comply with such Prevailing Wage Laws. Contractor shall defend, indemnify and hold the City, its officials, officers, employees and agents free and harmless from any claims, liabilities, costs, penalties or interest arising out of any failure or alleged failure to comply with the Prevailing Wage Laws. It shall be mandatory upon the Contractor and all subcontractors to comply with all California Labor Code provisions, which include but are not limited to prevailing wages (Labor Code Sections 1771, 1774 and 1775), employment of apprentices (Labor Code Section 1777.5), certified payroll records (Labor Code Sections 1771.4 and 1776), hours of labor (Labor Code Sections 1813 and 1815) and debarment of contractors and subcontractors (Labor Code Section 1777.1). B. If the Services are being performed as part of an applicable “public works” or “maintenance” project and if the total compensation is $15,000 or more for maintenance or $25,000 or more for construction, alteration, demolition, installation, or repair, then pursuant to Labor Code Sections 1725.5 and 1771.1, the Contractor and all subcontractors performing such Services must be registered with the Department of Industrial Relations. Contractor shall maintain registration for the duration of the Project and require the same of any subcontractors, as applicable. This Agreement may also be subject to compliance monitoring and enforcement by the Department of Industrial Relations. It shall be Contractor’s sole responsibility to comply with all applicable registration and labor compliance requirements. 6. INSURANCE Contractor shall procure and maintain, at its sole cost and expense, policies of insurance as set forth in the attached Exhibit "B", incorporated herein by reference. 7. INDEMNIFICATION. 7.1 Indemnification. To the fullest extent permitted by law, Contractor shall defend (at Contractor’s sole cost and expense), indemnify, protect, and hold harmless City, its elected officials, officers, employees, agents, and volunteers (collectively the “Indemnified Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 Revised 4.13.23 Page 6 of 18 Parties”), from and against any and all liabilities, actions, suits, claims, demands, losses, costs, judgments, arbitration awards, settlements, damages, demands, orders, penalties, and expenses including legal costs and attorney fees (collectively “Claims”), including but not limited to Claims arising from injuries to or death of persons (Contractor’s employees included), for damage to property, including property owned by City, for any violation of any federal, state, or local law or ordinance or in any manner arising out of, pertaining to, or incident to any acts, errors or omissions, or willful misconduct committed by Contractor, its officers, employees, representatives, and agents, that arise out of or relate to Contractor’s performance of Services or this Agreement. This indemnification clause excludes Claims arising from the sole negligence or willful misconduct of the Indemnified Parties. Under no circumstances shall the insurance requirements and limits set forth in this Agreement be construed to limit Contractor’s indemnification obligation or other liability under this Agreement. Contractor’s indemnification obligation shall survive the expiration or earlier termination of this Agreement until all actions against the Indemnified Parties for such matters indemnified are fully and finally barred by the applicable statute of limitations or, if an action is timely filed, until such action is final. 7.2 Design Professional Services Indemnification and Reimbursement. If Contractor’s obligation to defend, indemnify, and/or hold harmless arises out of Contractor’s performance as a “design professional” (as that term is defined under Civil Code section 2782.8), then, and only to the extent required by Civil Code section 2782.8, which is fully incorporated herein, Contractor’s indemnification obligation shall be limited to the extent which the Claims arise out of, pertain to, or relate to the negligence, recklessness, or willful misconduct of the Contractor in the performance of the Services or this Agreement, and, upon Contractor obtaining a final adjudication by a court of competent jurisdiction, Contractor’s liability for such claim, including the cost to defend, shall not exceed the Contractor’s proportionate percentage of fault. 8. RECORDS AND REPORTS 8.1 Reports. Contractor shall periodically prepare and submit to the Contract Officer reports concerning the performance of the Services required by this Agreement, or as the Contract Officer shall require. 8.2 Records. Contractor shall keep complete, accurate, and detailed accounts of all time, costs, expenses, and expenditures pertaining in any way to this Agreement. Contractor shall keep such books and records as shall be necessary to properly perform the Services required by this Agreement and enable the Contract Officer to evaluate the performance of such Services. The Contract Officer shall have full and free access to such books and records at all reasonable times, including the right to inspect, copy, audit, and make records and transcripts from such records. 8.3 Ownership of Documents. All drawings, specifications, reports, records, documents, and other materials prepared by Contractor in the performance of this Agreement shall be the property of City. Contractor shall deliver all above-referenced documents to City upon request of the Contract Officer or upon the termination of this Agreement. Contractor shall have no claim for further employment or additional compensation as a result of the exercise by City of its full rights or ownership of the documents and materials. Contractor may retain copies Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 Revised 4.13.23 Page 7 of 18 of such documents for Contractor's own use. Contractor shall have an unrestricted right to use the concepts embodied in such documents. 8.4 Release of Documents. All drawings, specifications, reports, records, documents, and other materials prepared by Contractor in the performance of Services under this Agreement shall not be released publicly without the prior written approval of the Contract Officer. 8.5 Audit and Inspection of Records. After receipt of reasonable notice and during the regular business hours of City, Contractor shall provide City, or other agents of City, such access to Contractor’s books, records, payroll documents, and facilities as City deems necessary to examine, copy, audit, and inspect all accounting books, records, work data, documents, and activities directly related to Contractor’s performance under this Agreement. Contractor shall maintain such books, records, data, and documents in accordance with generally accepted accounting principles and shall clearly identify and make such items readily accessible to such parties during the term of this Agreement and for a period of three (3) years from the date of final payment by City hereunder. 9. ENFORCEMENT OF AGREEMENT 9.1 California Law. This Agreement shall be construed and interpreted both as to validity and to performance of the parties in accordance with the laws of the State of California. Legal actions concerning any dispute, claim, or matter arising out of or in relation to this Agreement shall be instituted in the Superior Court of the County of Riverside, State of California, or any other appropriate court in such county, and Contractor covenants and agrees to submit to the personal jurisdiction of such court in the event of such action. 9.2 Interpretation. This Agreement shall be construed as a whole according to its fair language and common meaning to achieve the objectives and purposes of the Parties. The terms of this Agreement are contractual and the result of negotiation between the Parties. Accordingly, any rule of construction of contracts (including, without limitation, California Civil Code Section 1654) that ambiguities are to be construed against the drafting party, shall not be employed in the interpretation of this Agreement. The caption headings of the various sections and paragraphs of this Agreement are for convenience and identification purposes only and shall not be deemed to limit, expand, or define the contents of the respective sections or paragraphs. 9.3 Waiver. No delay or omission in the exercise of any right or remedy of a non- defaulting Party on any default shall impair such right or remedy or be construed as a waiver. No consent or approval of City shall be deemed to waive or render unnecessary City’s consent to or approval of any subsequent act of Contractor. Any waiver by either Party of any default must be in writing. No such waiver shall be a waiver of any other default concerning the same or any other provision of this Agreement. 9.4 Rights and Remedies are Cumulative. Except with respect to rights and remedies expressly declared to be exclusive in this Agreement, the rights and remedies of the parties are cumulative. The exercise by either Party of one or more of such rights or remedies Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 Revised 4.13.23 Page 8 of 18 shall not preclude the exercise by it, at the same or different times, of any other rights or remedies for the same default or any other default by the other Party. 9.5 Legal Action. In addition to any other rights or remedies, either Party may take legal action, in law or in equity, to cure, correct, or remedy any default, to recover damages for any default, to compel specific performance of this Agreement, to obtain injunctive relief, a declaratory judgment, or any other remedy consistent with the purposes of this Agreement. 9.6 Attorney Fees. In the event any dispute between the Parties with respect to this Agreement results in litigation or any non-judicial proceeding, the prevailing Party shall be entitled, in addition to such other relief as may be granted, to recover from the non-prevailing Party all reasonable costs and expenses. These include but are not limited to reasonable attorney fees, expert contractor fees, court costs and all fees, costs, and expenses incurred in any appeal or in collection of any judgment entered in such proceeding. 10. CITY OFFICERS AND EMPLOYEES: NON-DISCRIMINATION 10.1 Non-Liability of City Officers and Employees. No officer or employee of City shall be personally liable to the Contractor, or any successor-in-interest, in the event of any default or breach by City or for any amount which may become due to the Contractor or its successor, or for breach of any obligation of the terms of this Agreement. 10.2 Conflict of Interest. Contractor acknowledges that no officer or employee of the City has or shall have any direct or indirect financial interest in this Agreement, nor shall Contractor enter into any agreement of any kind with any such officer or employee during the term of this Agreement and for one (1) year thereafter. Contractor warrants that Contractor has not paid or given, and will not pay or give, any third party any money or other consideration in exchange for obtaining this Agreement. 10.3 Covenant Against Discrimination. In connection with its performance under this Agreement, Contractor shall not discriminate against any employee or applicant for employment because of actual or perceived race, religion, color, sex, age, marital status, ancestry, national origin (i.e., place of origin, immigration status, cultural or linguistic characteristics, or ethnicity), sexual orientation, gender identity, gender expression, physical or mental disability, or medical condition (each a “prohibited basis”). Contractor shall ensure that applicants are employed, and that employees are treated during their employment, without regard to any prohibited basis. As a condition precedent to City’s lawful capacity to enter this Agreement, and in executing this Agreement, Contractor certifies that its actions and omissions hereunder shall not incorporate any discrimination arising from or related to any prohibited basis in any Contractor activity, including but not limited to the following: employment, upgrading, demotion or transfer; recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship; and further, that Contractor is in full compliance with the provisions of Palm Springs Municipal Code Section 7.09.040, including without limitation the provision of benefits, relating to non- discrimination in city contracting. 11. MISCELLANEOUS PROVISIONS Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 Revised 4.13.23 Page 9 of 18 11.1 Notice. Any notice, demand, request, consent, approval, or communication that either Party desires, or is required to give to the other Party or any other person shall be in writing and either served personally or sent by pre-paid, first-class mail to the address set forth below. Notice shall be deemed communicated seventy-two (72) hours from the time of mailing if mailed as provided in this Section. Either Party may change its address by notifying the other Party of the change of address in writing. To City: City of Palm Springs Attention: City Manager/ City Clerk 3200 E. Tahquitz Canyon Way Palm Springs, California 92262 To Contractor: Williams Scotsman, Inc. 4646 East Van Buren St Suite 400 Phoenix, AZ 85005 11.2 Integrated Agreement. This Agreement constitutes the entire understanding between the Parties and supersedes and cancels all prior negotiations, arrangements, agreements, representations, and understandings, if any, made by or among the Parties with respect to the subject matter in this Agreement. 11.3 Amendment. No amendments or other modifications of this Agreement shall be binding unless through written agreement signed by all Parties. 11.4 Severability. Whenever possible, each provision of this Agreement shall be interpreted in such a manner as to be effective and valid under applicable law. In the event that any one or more of the phrases, sentences, clauses, paragraphs, or sections contained in this Agreement shall be declared invalid or unenforceable by valid judgment or decree of a court of competent jurisdiction, such invalidity or unenforceability shall not affect any of the remaining phrases, sentences, clauses, paragraphs, or sections of this Agreement, which shall be interpreted to carry out the intent of the Parties. 11.5 Successors in Interest. This Agreement shall be binding upon and inure to the benefit of the Parties’ successors and assignees. 11.6 Third Party Beneficiary. Except as may be expressly provided for in this Agreement, nothing contained in this Agreement is intended to confer, nor shall this Agreement be construed as conferring, any rights, including, without limitation, any rights as a third-party beneficiary or otherwise, upon any entity or person not a party to this Agreement. 11.7 Recitals. The above-referenced Recitals are hereby incorporated into the Agreement as though fully set forth in this Agreement and each Party acknowledges and agrees that such Party is bound, for purposes of this Agreement, by the same. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 Revised 4.13.23 Page 10 of 18 11.8 Authority. The persons executing this Agreement on behalf of the Parties warrant that they are duly authorized to execute this Agreement on behalf of Parties and that by so executing this Agreement the Parties are formally bound to the provisions of this Agreement. 11.9 Counterparts. This Agreement may be signed in counterparts, each of which shall constitute an original. 11.10 Compliance with Economic Sanctions in Response to Russia's Actions in Ukraine. When funding for the services is provided, in whole or in part, by an agency controlled of the State of California, Consultant shall fully and adequately comply with California Executive Order N-6-22 (“Russian Sanctions Program”). As part of this compliance process, Consultant shall also certify compliance with the Russian Sanctions Program by completing the form located in Exhibit “C” (Russian Sanctions Certification), attached hereto and incorporated herein by reference. Consultant shall also require any subconsultants to comply with the Russian Sanctions Program and certify compliance pursuant to this Section. [SIGNATURES ON NEXT PAGE] Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 Revised 4.13.23 Page 11 of 18 SIGNATURE PAGE TO AGREEMENT BY AND BETWEEN THE CITY OF PALM SPRINGS AND WILLIAMS SCOTSMAN, INC. IN WITNESS WHEREOF, the Parties have executed this Agreement as of the dates stated below. CONTRACTOR: By: _______________________________________ By: _________________________________________ Signature Signature (2nd signature required for Corporations) Date: Date: CITY OF PALM SPRINGS: APPROVED BY CITY COUNCIL: Date: N/A Item No. N/A APPROVED AS TO FORM: ATTEST: By: ___________________________ By: _______________________________ City Attorney City Clerk APPROVED: By: _______________________________ Date: City Manager – over $50,000 Deputy/Assistant City Manager – up to $50,000 Director – up to $25,000 Manager – up to $5,000 Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 1/21/2025 1/21/2025 1/21/2025 1/21/2025 1/21/2025 Revised 4.13.23 Page 12 of 18 EXHIBIT “A” SCOPE OF SERVICES/WORK Including, Schedule of Fees And Schedule of Performance Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 Revised 4.13.23 Page 13 of 18 EXHIBIT “A” Contractor will provide rental of portable storage units for the Parks & Recreation Department as described below. I. DETAILS OF RENTAL The following are details for two (2) long-term storage unit rentals. Location: City of Palm Springs 401 S Pavilion Way Palm Springs, CA 92262 ESTIMATED DELIVERY AND INSTALLATION Delivery - 8’ wide flatbed $221.00 Return - 8’ wide flatbed $221.00 Total Delivery and Installation Charges Including Estimated Taxes $482.88 RENTAL PRICING TYPE DURATION RENTAL FEES PER UNIT: 20’ Standard Tri Cam Container 12 months minimum $185.00 Personal Property Expense 12 months minimum $9.25 Total Recurring Charges Per Billing Cycle Including Estimated Taxes $212.22 Total for (1) Unit for 12 Months $2,546.64 TOTAL RENTAL PRICING (2) Units for 24 Months $10,186.56 Total Charges for Delivery of (1) New Unit and 24 Months Rental of (2) Units $10,669.44 II. SPECIAL ARRANGEMENTS Parks & Recreation Department will need to utilize two (2) units for long-term usage to store VillageFest and Special Events supplies. Storage units to remain on location in parking lot near the Pavilion and Leisure Center. Parks & Recreation has been using an existing unit on a monthly payment plan and needs an additional unit. This agreement is in compliance with Finance directive for best procurement practices. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 Revised 4.13.23 Page 14 of 18 EXHIBIT “B” INSURANCE PROVISIONS Including Verification of Coverage, Sufficiency of Insurers, Errors and Omissions Coverage, Minimum Scope of Insurance, Deductibles and Self-Insured Retentions, and Severability of Interests (Separation of Insureds) Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 Revised 4.13.23 Page 15 of 18 INSURANCE 1. Procurement and Maintenance of Insurance. Contractor shall procure and maintain public liability and property damage insurance against all claims for injuries against persons or damages to property resulting from Contractor’s performance under this Agreement. Contractor shall procure and maintain all insurance at its sole cost and expense, in a form and content satisfactory to the City, and submit concurrently with its execution of this Agreement. Contractor shall also carry workers’ compensation insurance in accordance with California workers’ compensation laws. Such insurance shall be kept in full force and effect during the term of this Agreement, including any extensions. Such insurance shall not be cancelable without thirty (30) days advance written notice to City of any proposed cancellation. Certificates of insurance evidencing the foregoing and designating the City, its elected officials, officers, employees, agents, and volunteers as additional named insureds by original endorsement shall be delivered to and approved by City prior to commencement of services. The procuring of such insurance and the delivery of policies, certificates, and endorsements evidencing the same shall not be construed as a limitation of Contractor’s obligation to indemnify City, its elected officials, officers, agents, employees, and volunteers. 2. Minimum Scope of Insurance. The minimum amount of insurance required under this Agreement shall be as follows: 1. Comprehensive general liability and personal injury with limits of at least one million dollars ($1,000,000.00) combined single limit coverage per occurrence and two million dollars ($2,000,000) general aggregate; 2. Automobile liability insurance with limits of at least one million dollars ($1,000,000.00) per occurrence; 3. Professional liability (errors and omissions) insurance with limits of at least one million dollars ($1,000,000.00) per occurrence and two million dollars ($2,000,000) annual aggregate is: _________ required _____X____ is not required; 4. Workers’ Compensation insurance in the statutory amount as required by the State of California and Employer’s Liability Insurance with limits of at least one million dollars $1 million per occurrence. If Contractor has no employees, Contractor shall complete the City’s Request for Waiver of Workers’ Compensation Insurance Requirement form. 3. Primary Insurance. For any claims related to this Agreement, Contractor’s insurance coverage shall be primary with respect to the City and its respective elected officials, officers, employees, agents, and volunteers. Any insurance or self-insurance maintained by City and its respective elected officials, officers, employees, agents, and volunteers shall be in excess of Contractor’s insurance and shall not contribute with it. For Workers’ Compensation and Employer’s Liability Insurance only, the insurer shall waive all rights of subrogation and Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 Revised 4.13.23 Page 16 of 18 contribution it may have against City, its elected officials, officers, employees, agents, and volunteers. 4. Errors and Omissions Coverage. If Errors & Omissions Insurance is required, and if Contractor provides claims made professional liability insurance, Contractor shall also agree in writing either (1) to purchase tail insurance in the amount required by this Agreement to cover claims made within three years of the completion of Contractor’s services under this Agreement, or (2) to maintain professional liability insurance coverage with the same carrier in the amount required by this Agreement for at least three years after completion of Contractor’s services under this Agreement. Contractor shall also be required to provide evidence to City of the purchase of the required tail insurance or continuation of the professional liability policy. 5. Sufficiency of Insurers. Insurance required in this Agreement shall be provided by authorized insurers in good standing with the State of California. Coverage shall be provided by insurers admitted in the State of California with an A.M. Best’s Key Rating of B++, Class VII, or better, unless otherwise acceptable to the City. 6. Verification of Coverage. Contractor shall furnish City with both certificates of insurance and endorsements, including additional insured endorsements, affecting all of the coverages required by this Agreement. The certificates and endorsements are to be signed by a person authorized by that insurer to bind coverage on its behalf. All proof of insurance is to be received and approved by the City before work commences. City reserves the right to require Contractor’s insurers to provide complete, certified copies of all required insurance policies at any time. Additional insured endorsements are not required for Errors and Omissions and Workers’ Compensation policies. Verification of Insurance coverage may be provided by: (1) an approved General and/or Auto Liability Endorsement Form for the City of Palm Springs or (2) an acceptable Certificate of Liability Insurance Coverage with an approved Additional Insured Endorsement with the following endorsements stated on the certificate: A. "The City of Palm Springs, its officials, employees, and agents are named as an additional insured…” ("as respects City of Palm Springs Contract No.___" or "for any and all work performed with the City" may be included in this statement). B. "This insurance is primary and non-contributory over any insurance or self- insurance the City may have..." ("as respects City of Palm Springs Contract No.___" or "for any and all work performed with the City" may be included in this statement). C. "Should any of the above-described policies be canceled before the expiration date thereof, the issuing company will mail 30 days written notice to the Certificate Holder named." Language such as, “endeavor to” mail and "but failure to mail such notice shall impose no obligation or liability of any kind upon the company, its agents or representative" is not acceptable and must be crossed out. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 Revised 4.13.23 Page 17 of 18 D. Both the Workers’ Compensation and Employers' Liability policies shall contain the insurer's waiver of subrogation in favor of City, its elected officials, officers, employees, agents, and volunteers. In addition to the endorsements listed above, the City of Palm Springs shall be named the certificate holder on the policies. All certificates of insurance and endorsements are to be received and approved by the City before work commences. All certificates of insurance must be authorized by a person with authority to bind coverage, whether that is the authorized agent/broker or insurance underwriter. Failure to obtain the required documents prior to the commencement of work shall not waive the Contractor’s obligation to provide them. 7. Deductibles and Self-Insured Retentions. Any deductibles or self-insured retentions must be declared to and approved by the City prior to commencing any work or services under this Agreement. At the option of the City, either (1) the insurer shall reduce or eliminate such deductibles or self-insured retentions with respect to the City, its elected officials, officers, employees, agents, and volunteers; or (2) Contractor shall procure a bond guaranteeing payment of losses and related investigations, claim administration, and defense expenses. Certificates of Insurance must include evidence of the amount of any deductible or self-insured retention under the policy. Contractor guarantees payment of all deductibles and self-insured retentions. 8. Severability of Interests (Separation of Insureds). This insurance applies separately to each insured against whom claim is made or suit is brought except with respect to the limits of the insurer’s liability. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 Revised 4.13.23 Page 18 of 18 EXHIBIT “C” EXECUTIVE ORDER N-6-22 CERTIFICATION Executive Order N-6-22 issued by Governor Gavin Newsom on March 4, 2022, directs all agencies and departments that are subject to the Governor’s authority to (a) terminate any contracts with any individuals or entities that are determined to be a target of economic sanctions against Russia and Russian entities and individuals; and (b) refrain from entering into any new contracts with such individuals or entities while the aforementioned sanctions are in effect. Executive Order N-6-22 also requires that any contractor that: (1) currently has a contract with the City of Palm Springs funded through grant funds provided by the State of California; and/or (2) submits a bid or proposal or otherwise proposes to or enter into or renew a contract with the City of Palm Springs with State of California grant funds, certify that the person is not the target of any economic sanctions against Russia and Russian entities and individuals. The contractor hereby certifies, SUBJECT TO PENALTY FOR PERJURY, that a) the contractor is not a target of any economic sanctions against Russian and Russian entities and individuals as discussed in Executive Order N-6-22 and b) the person signing below is duly authorized to legally bind the Contractor. This certification is made under the laws of the State of California. Signature: Printed Name: Title: Firm Name: Date: Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 Waleed Almanasrah 1/21/2025 Williams Scotsman, Inc. Legal Contracts Specialist SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. INSURER(S) AFFORDING COVERAGE INSURER F : INSURER E : INSURER D : INSURER C : INSURER B : INSURER A : NAIC # NAME:CONTACT (A/C, No):FAX E-MAILADDRESS: PRODUCER (A/C, No, Ext):PHONE INSURED REVISION NUMBER:CERTIFICATE NUMBER:COVERAGES IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. OTHER: (Per accident) (Ea accident) $ $ N / A SUBR WVD ADDL INSD THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. $ $ $ $PROPERTY DAMAGE BODILY INJURY (Per accident) BODILY INJURY (Per person) COMBINED SINGLE LIMIT AUTOS ONLY AUTOSAUTOS ONLY NON-OWNED SCHEDULEDOWNED ANY AUTO AUTOMOBILE LIABILITY Y / N WORKERS COMPENSATION AND EMPLOYERS' LIABILITY OFFICER/MEMBER EXCLUDED? (Mandatory in NH) DESCRIPTION OF OPERATIONS below If yes, describe under ANY PROPRIETOR/PARTNER/EXECUTIVE $ $ $ E.L. DISEASE - POLICY LIMIT E.L. DISEASE - EA EMPLOYEE E.L. EACH ACCIDENT EROTH-STATUTEPER LIMITS(MM/DD/YYYY)POLICY EXP(MM/DD/YYYY)POLICY EFFPOLICY NUMBERTYPE OF INSURANCELTRINSR DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) EXCESS LIAB UMBRELLA LIAB $EACH OCCURRENCE $AGGREGATE $ OCCUR CLAIMS-MADE DED RETENTION $ $PRODUCTS - COMP/OP AGG $GENERAL AGGREGATE $PERSONAL & ADV INJURY $MED EXP (Any one person) $EACH OCCURRENCE DAMAGE TO RENTED $PREMISES (Ea occurrence) COMMERCIAL GENERAL LIABILITY CLAIMS-MADE OCCUR GEN'L AGGREGATE LIMIT APPLIES PER: POLICY PRO-JECT LOC CERTIFICATE OF LIABILITY INSURANCE DATE (MM/DD/YYYY) CANCELLATION AUTHORIZED REPRESENTATIVE ACORD 25 (2016/03) © 1988-2015 ACORD CORPORATION. All rights reserved. CERTIFICATE HOLDER The ACORD name and logo are registered marks of ACORD HIRED AUTOS ONLY 12/17/2024 Lovitt &Touché A Marsh and McLennan Agency,LLC 8605 E.Raintree Drive,Suite 200 Scottsdale AZ 85260 Tami Lane 602-956-2250 602-956-2258 Tami.Lane@MarshMMA.com Federal Insurance Company 20281 WILLSMOBIL Zurich American Insurance Company 16535WilliamsScotsman,Inc.and its Subsidiaries DBA WillScot 4646 E.Van Buren Street,Suite 400 Phoenix AZ 85008 American Zurich Insurance Company 40142 Scottsdale Indemnity Company 15580 Allied World Assurance Company (US)Inc 19489 197898756 B X 2,000,000 X 500,000 10,000 2,000,000 10,000,000 X X X $4,000,000 Y Y GLO557056500 11/1/2024 11/1/2025 4,000,000 B 10,000,000 X X X Y Y BAP557056400 11/1/2024 11/1/2025 D E X X 18,000,000 X Y XLI2000152 03140527 11/1/2024 11/1/2024 Y 11/1/2025 11/1/2025 18,000,000 MULTIPLE POLICIES SEE PAGE 2 C B X N Y WC557056600 (AOS) WC557056300 (MA/NE/WI) 11/1/2024 11/1/2024 11/1/2025 11/1/2025 3,000,000 3,000,000 3,000,000 A Motor Truck Cargo Legal Liability 06592841WUC 11/1/2024 11/1/2025 Limit:$250,000 Certificate Holder is an Additional Insured on a Primary and Non-Contributory basis as respects to General Liability including Ongoing/Completed Operations if required in a written contract and as respects to Auto Liability if required in a written contract subject to all policy terms,conditions,definitions,and exclusions. 30 Day Notice of Cancellation and Waiver of Subrogation applies as respects to General Liability,Auto Liability &Workers Compensation if required in a written contract,subject to all policy terms,conditions,definitions,and exclusions. **SEE PAGE 2 FOR UMBRELLA/EXCESS POLICY INFORMATION** See Attached... City of Palm Springs 401 S.Pavillion way Palm Springs CA 92262 Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 ACORD 101 (2008/01) The ACORD name and logo are registered marks of ACORD © 2008 ACORD CORPORATION. All rights reserved. THIS ADDITIONAL REMARKS FORM IS A SCHEDULE TO ACORD FORM, FORM NUMBER:FORM TITLE: ADDITIONAL REMARKS ADDITIONAL REMARKS SCHEDULE Page of AGENCY CUSTOMER ID: LOC #: AGENCY CARRIER NAIC CODE POLICY NUMBER NAMED INSURED EFFECTIVE DATE: WILLSMOBIL 1 1 Lovitt &Touché A Marsh and McLennan Agency,LLC Williams Scotsman,Inc.and its Subsidiaries DBA WillScot 4646 E.Van Buren Street,Suite 400 Phoenix AZ 85008 25 CERTIFICATE OF LIABILITY INSURANCE Excess Liability:$5,000,000 xs of $2,000,000 (Follows Form &Excess over General Liability &Employer's Liability) Insurer:Scottsdale Indemnity Company /NAIC #15580 Policy Number:XLl2000152 Eff Date:11/1/2024 Exp Date:11/1/2025 Excess Liability:$3,000,000 xs $5,000,000 (Follows Form &Excess over General Liability &Employer's Liability) Insurer:Allied World Assurance Co (U.S.)Inc./NAIC #19489 Policy Number:03140527 Eff Date:11/1/2024 Exp Date:11/1/2025 Excess Liability:$10,000,000 xs $8,000,000 (Follows Form &Excess over General Liability,Auto Liability and Excess Policies with Scottsdale Indemnity Company &Allied World Assurance Co (U.S.)Inc.) Insurer:American Guarantee and Liability Insurance Company Policy Number:ZAU329850000 /NAIC #26247 Eff Date:11/1/2024 Exp Date:11/1/2025 Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 POLICY NUMBER: GLO 5570565 00 COMMERCIAL GENERAL LIABILITY CG 20 10 12 19 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. CG 20 10 12 19 © Insurance Services Office, Inc., 2018 Page 1 of 2 Wolters Kluwer Financial Services, Inc. | Uniform Forms ADDITIONAL INSURED – OWNERS, LESSEES OR CONTRACTORS – SCHEDULED PERSON OR ORGANIZATION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or Organization(s) Location(s) Of Covered Operations Any person or organization, other than an architect, engineer, or surveyor, whom you are required to add as an additional insured under this policy under a written contract or written agreement executed prior to loss. Any location or project, other than a wrap-up or other consolidated insurance program location or project, for which insurance is otherwise separately provided to you by a wrap-up or other consolidated insurance program. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. A. Section II – Who Is An Insured is amended to include as an additional insured the person(s) or organization(s) shown in the Schedule, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by: 1. Your acts or omissions; or 2. The acts or omissions of those acting on your behalf; in the performance of your ongoing operations for the additional insured(s) at the location(s) designated above. However: 1. The insurance afforded to such additional insured only applies to the extent permitted by law; and 2. If coverage provided to the additional insured is required by a contract or agreement, the insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. B. With respect to the insurance afforded to these additional insureds, the following additional exclusions apply: This insurance does not apply to "bodily injury" or "property damage" occurring after: 1. All work, including materials, parts or equipment furnished in connection with such work, on the project (other than service, maintenance or repairs) to be performed by or on behalf of the additional insured(s) at the location of the covered operations has been completed; or 2. That portion of "your work" out of which the injury or damage arises has been put to its intended use by any person or organization other than another contractor or subcontractor engaged in performing operations for a principal as a part of the same project. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 Page 2 of 2 © Insurance Services Office, Inc., 2018 CG 20 10 12 19 C. With respect to the insurance afforded to these additional insureds, the following is added to Section III – Limits Of Insurance: If coverage provided to the additional insured is required by a contract or agreement, the most we will pay on behalf of the additional insured is the amount of insurance: 1. Required by the contract or agreement; or 2. Available under the applicable limits of insurance; whichever is less. This endorsement shall not increase the applicable limits of insurance. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 POLICY NUMBER: GLO 5570565 00 COMMERCIAL GENERAL LIABILITY CG 20 37 12 19 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. CG 20 37 12 19 © Insurance Services Office, Inc., 2018 Page 1 of 1 Wolters Kluwer Financial Services, Inc. | Uniform Forms ADDITIONAL INSURED – OWNERS, LESSEES OR CONTRACTORS – COMPLETED OPERATIONS This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or Organization(s) Location And Description Of Completed Operations Any person or organization, other than an architect, engineer, or surveyor, whom you are required to add as an additional insured under this policy under a written contract or written agreement executed prior to loss. Any location or project, other than a wrap-up or other consolidated insurance program location or project, for which insurance is otherwise separately provided to you by a wrap-up or other consolidated insurance program. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. A. Section II – Who Is An Insured is amended to include as an additional insured the person(s) or organization(s) shown in the Schedule, but only with respect to liability for "bodily injury" or "property damage" caused, in whole or in part, by "your work" at the location designated and described in the Schedule of this endorsement performed for that additional insured and included in the "products-completed operations hazard". However: 1. The insurance afforded to such additional insured only applies to the extent permitted by law; and 2. If coverage provided to the additional insured is required by a contract or agreement, the insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. B. With respect to the insurance afforded to these additional insureds, the following is added to Section III – Limits Of Insurance: If coverage provided to the additional insured is required by a contract or agreement, the most we will pay on behalf of the additional insured is the amount of insurance: 1. Required by the contract or agreement; or 2. Available under the applicable limits of insurance; whichever is less. This endorsement shall not increase the applicable limits of insurance. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 POLICY NUMBER: GLO 5570565 00 COMMERCIAL GENERAL LIABILITY CG 20 26 12 19 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. CG 20 26 12 19 © Insurance Services Office, Inc., 2018 Page 1 of 1 Wolters Kluwer Financial Services, Inc. | Uniform Forms ADDITIONAL INSURED – DESIGNATED PERSON OR ORGANIZATION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART SCHEDULE Name Of Additional Insured Person(s) Or Organization(s): Any person or organization, other than an architect, engineer, or surveyor, whom you are required to add as an additional insured under this policy under a written contract or written agreement executed prior to loss. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. A. Section II – Who Is An Insured is amended to include as an additional insured the person(s) or organization(s) shown in the Schedule, but only with respect to liability for "bodily injury", "property damage" or "personal and advertising injury" caused, in whole or in part, by your acts or omissions or the acts or omissions of those acting on your behalf: 1. In the performance of your ongoing operations; or 2. In connection with your premises owned by or rented to you. However: 1. The insurance afforded to such additional insured only applies to the extent permitted by law; and 2. If coverage provided to the additional insured is required by a contract or agreement, the insurance afforded to such additional insured will not be broader than that which you are required by the contract or agreement to provide for such additional insured. B. With respect to the insurance afforded to these additional insureds, the following is added to Section III – Limits Of Insurance: If coverage provided to the additional insured is required by a contract or agreement, the most we will pay on behalf of the additional insured is the amount of insurance: 1. Required by the contract or agreement; or 2. Available under the applicable limits of insurance; whichever is less. This endorsement shall not increase the applicable limits of insurance. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 POLICY NUMBER: GLO 5570565 00 COMMERCIAL GENERAL LIABILITY CG 20 01 12 19 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. CG 20 01 12 19 © Insurance Services Office, Inc., 2018 Page 1 of 1 Wolters Kluwer Financial Services, Inc. | Uniform Forms PRIMARY AND NONCONTRIBUTORY – OTHER INSURANCE CONDITION This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART LIQUOR LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART The following is added to the Other Insurance Condition and supersedes any provision to the contrary: Primary And Noncontributory Insurance This insurance is primary to and will not seek contribution from any other insurance available to an additional insured under your policy provided that: (1) The additional insured is a Named Insured under such other insurance; and (2) You have agreed in writing in a contract or agreement that this insurance would be primary and would not seek contribution from any other insurance available to the additional insured. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 POLICY NUMBER: GLO 5570565 00 COMMERCIAL GENERAL LIABILITY CG 24 04 12 19 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. CG 24 04 12 19 © Insurance Services Office, Inc., 2018 Page 1 of 1 Wolters Kluwer Financial Services, Inc. | Uniform Forms WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US (WAIVER OF SUBROGATION) This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART ELECTRONIC DATA LIABILITY COVERAGE PART LIQUOR LIABILITY COVERAGE PART POLLUTION LIABILITY COVERAGE PART DESIGNATED SITES POLLUTION LIABILITY LIMITED COVERAGE PART DESIGNATED SITES PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART RAILROAD PROTECTIVE LIABILITY COVERAGE PART UNDERGROUND STORAGE TANK POLICY DESIGNATED TANKS SCHEDULE Name Of Person(s) Or Organization(s): Information required to complete this Schedule, if not shown above, will be shown in the Declarations. The following is added to Paragraph 8. Transfer Of Rights Of Recovery Against Others To Us of Section IV – Conditions: We waive any right of recovery against the person(s) or organization(s) shown in the Schedule above because of payments we make under this Coverage Part. Such waiver by us applies only to the extent that the insured has waived its right of recovery against such person(s) or organization(s) prior to loss. This endorsement applies only to the person(s) or organization(s) shown in the Schedule above. Any person or organization where required by written contract or written agreement and executed prior to loss. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 U-GL-2161-A CW (11/17) Page 1 of 3 Includes copyrighted material of Insurance Services Office, Inc., with its permission. Designated Project General Aggregate Limit (Erodes All Designated Projects Total General Aggregate Limit) THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. Policy No. GLO 5570565 00 Effective Date: 11/01/2024 This endorsement modifies insurance provided under the: Commercial General Liability Coverage Part SCHEDULE "Designated Projects": Any construction project except a construction project for which a consolidated (wrap-up) or similar insurance program has been provided. All Designated Projects Total General Aggregate Limit: $10,000,000 * (*If no amount is shown for the All Designated Projects Total General Aggregate Limit, $4,000,000 applies.) A. Solely with respect to all sums which the insured becomes legally obligated to pay as damages caused by "occurrences" under Section I – Coverage A, and for all medical expenses caused by accidents under Section I – Coverage C, which can be attributed only to operations at a single "designated project": 1. A separate Designated Project General Aggregate Limit applies to each "designated project", and that limit is equal to the amount of the General Aggregate Limit shown in the Declarations. 2. The Designated Project General Aggregate Limit is the most we will pay for the sum of all damages under Coverage A, except damages because of "bodily injury" or "property damage" included in the "products - completed operations hazard", and for medical expenses under Coverage C regardless of the number of: a. Insureds; b. Claims made or "suits" brought; or c. Persons or organizations making claims or bringing "suits". 3. The following is added to Section III – Limits Of Insurance: The All Designated Projects Total General Aggregate Limit shown in the Schedule of this endorsement is the most we will pay for the sum of all: a. Damages under Coverage A; and b. Medical expenses under Coverage C, which: (1) Can be attributed only to operations at any of the single "designated project s"; and (2) Applies towards any Designated Project General Aggregate Limit as indicated in Paragraph A.1. of this endorsement. Such payments shall not reduce the General Aggregate Limit shown in the Declarations. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 U-GL-2161-A CW (11/17) Page 2 of 3 Includes copyrighted material of Insurance Services Office, Inc., with its permission. 4. Any payments made under Coverage A for damages or under Coverage C for medical expenses shall reduce the Designated Project General Aggregate Limit for that "designated project". Such payments shall also reduce the All Designated Projects Total General Aggregate Limit shown in the Schedule of this endorsement. However, such payments shall not reduce the General Aggregate Limit shown in the Declarations nor shall they reduce any other Designated Project General Aggregate Limit for any other "designated project". 5. The limits shown in the Declarations for Each Occurrence, Damage To Premises Rented To You and Medical Expense continue to apply. However, instead of being subject to the General Aggregate Limit shown in the Declarations, such limits will be subject to the: a. Applicable Designated Project General Aggregate Limit; and b. All Designated Projects Total General Aggregate Limit shown in the Schedule of this endorsement. 6. Paragraph 5. of Section III – Limits Of Insurance is replaced by the following: 5. Subject to: a. The applicable Designated Project General Aggregate Limit as indicated in Paragraph A.1. of this endorsement; and b. The All Designated Projects Total General Aggregate Limit shown in the Schedule of this endorsement, the Each Occurrence Limit is the most we will pay for the sum of: (1) Damages under Coverage A; and (2) Medical expenses under Coverage C, because of all "bodily injury" and "property damage" arising out of any one "occurrence". B. Solely with respect to all sums which the insured becomes legally obligated to pay as damages caused by "occurrences" under Section I – Coverage A, and for all medical expenses caused by accidents under Section I – Coverage C, which cannot be attributed only to operations at a single "designated project": 1. Any payments made under Coverage A for damages or under Coverage C for medical expenses shall reduce the amount available under the General Aggregate Limit or the Products-Completed Operations Aggregate Limit, whichever is applicable; and 2. Such payments shall not reduce: a. Any Designated Project General Aggregate Limit; or b. The All Designated Projects Total General Aggregate Limit shown in the Schedule of this endorsement. C. When coverage for liability arising out of the "products-completed operations hazard" is provided, any payments for damages because of "bodily injury" or "property damage" included in the "products -completed operations hazard" will reduce the Products-Completed Operations Aggregate Limit, and not reduce the: 1. General Aggregate Limit; 2. Designated Project General Aggregate Limit; or 3. All Designated Projects Total General Aggregate Limit shown in the Schedule of this endorsement. D. Solely with respect to this endorsement, the following definition is added to the Definitions Section: "Designated project" means: Each Project described in the Schedule of this endorsement, including operations on and off the project site or location that are necessary or incidental to such Project as described in contract documents. "Designated project" includes the work site(s) associated with such Project and any offsite staging areas, as long as such offsite staging areas are dedicated solely to such Project. Also included are those areas immediately adjacent to such Project, including boundaries of local streets or public easements. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 U-GL-2161-A CW (11/17) Page 3 of 3 Includes copyrighted material of Insurance Services Office, Inc., with its permission. E. Solely with respect to this endorsement, Paragraph 1. of Section III – Limits Of Insurance is replaced by the following: 1. The Limits of Insurance shown in the Declarations, the All Designated Projects Total General Aggregate Limit shown in the Schedule of this endorsement and the rules below fix the most we will pay regardless of the number of: a. Insureds; b. Claims made or "suits" brought; or c. Persons or organizations making claims or bringing "suits". F. The provisions of Section III – Limits Of Insurance not otherwise modified by this endorsement shall continue to apply as stipulated. All other terms, conditions, provisions and exclusions of this policy remain the same. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 U-GL-1521-B CW (01/19) Page 1 of 2 Includes copyrighted material of Insurance Services Office, Inc., with its permission. Blanket Notification to Others of Cancellation or Non-Renewal THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. Policy No. GLO 5570565 00 Effective Date: 11/01/2024 This endorsement applies to insurance provided under the: Commercial General Liability Coverage Part A. If we cancel or non-renew this Coverage Part by written notice to the first Named Insured, we will mail or deliver notification that such Coverage Part has been cancelled or non-renewed to each person or organization shown in a list provided to us by the first Named Insured if you are required by written contact or written agreement to provide such notification. Such list: 1. Must be provided to us prior to cancellation or non-renewal; 2. Must contain the names and addresses of only the persons or organizations requiring notification that such Coverage Part has been cancelled or non-renewed; and 3. Must be in an electronic format that is acceptable to us. B. Our notification as described in Paragraph A. of this endorsement will be based on the most recent list in our records as of the date the notice of cancellation or non-renewal is mailed or delivered to the first Named Insured. We will mail or deliver such notification to each person or organization shown in the list: 1. Within 10 days of the effective date of the notice of cancellation, if we cancel for non-payment of premium; or 2. At least 30 days prior to the effective date of: a. Cancellation, if cancelled for any reason other than nonpayment of premium; or b. Non-renewal, but not including conditional notice of renewal, unless a greater number of days is shown in the Schedule of this endorsement for the mailing or delivering of such notification with respect to Paragraph B.1. or Paragraph B.2. above. C. Our mailing or delivery of notification described in Paragraphs A. and B. of this endorsement is intended as a courtesy only. Our failure to provide such mailing or delivery will not: 1. Extend the Coverage Part cancellation or non-renewal date; 2. Negate the cancellation or non-renewal; or 3. Provide any additional insurance that would not have been provided in the absence of this endorsement. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 U-GL-1521-B CW (01/19) Page 2 of 2 Includes copyrighted material of Insurance Services Office, Inc., with its permission. D. We are not responsible for the accuracy, integrity, timeliness and validity of information contained in the list provided to us as described in Paragraphs A. and B. of this endorsement. SCHEDULE The total number of days for mailing or delivering with respect to Paragraph B.1. of this endorsement is amended to indicate the following number of days: * The total number of days for mailing or delivering with respect to Paragraph B.2. of this endorsement is amended to indicate the following number of days: ** * If a number is not shown here, 10 days continues to apply. ** If a number is not shown here, 30 days continues to apply. All other terms and conditions of this policy remain unchanged. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 POLICY NUMBER: BAP 5570564 00 COMMERCIAL AUTO CA 20 48 10 13 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. CA 20 48 10 13 © Insurance Services Office, Inc., 2011 Page 1 of 1 Wolters Kluwer Financial Services | Uniform FormsTM DESIGNATED INSURED FOR COVERED AUTOS LIABILITY COVERAGE This endorsement modifies insurance provided under the following: AUTO DEALERS COVERAGE FORM BUSINESS AUTO COVERAGE FORM MOTOR CARRIER COVERAGE FORM With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modified by this endorsement. This endorsement identifies person(s) or organization(s) who are "insureds" for Covered Autos Liability Coverage under the Who Is An Insured provision of the Coverage Form. This endorsement does not alter coverage provided in the Coverage Form. This endorsement changes the policy effective on the inception date of the policy unless another date is indicated below. Named Insured: Willscot Holdings Corporation Endorsement Effective Date: 11/01/2024 SCHEDULE Name Of Person(s) Or Organization(s): Any Person or Organization where required by written contract or written agreement and executed prior to loss. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. Each person or organization shown in the Schedule is an "insured" for Covered Autos Liability Coverage, but only to the extent that person or organization qualifies as an "insured" under the Who Is An Insured provision contained in Paragraph A.1. of Section II – Covered Autos Liability Coverage in the Business Auto and Motor Carrier Coverage Forms and Paragraph D.2. of Section I – Covered Autos Coverages of the Auto Dealers Coverage Form. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 POLICY NUMBER: BAP 5570564 00 COMMERCIAL AUTO CA 20 01 11 20 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. CA 20 01 11 20 © Insurance Services Office, Inc., 2019 Page 1 of 2 Wolters Kluwer | Uniform Forms LESSOR – ADDITIONAL INSURED AND LOSS PAYEE This endorsement modifies insurance provided under the following: AUTO DEALERS COVERAGE FORM BUSINESS AUTO COVERAGE FORM MOTOR CARRIER COVERAGE FORM With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modified by the endorsement. This endorsement changes the Policy effective on the inception date of the Policy unless another date is indicated below. Named Insured: Willscot Holdings Corporation Endorsement Effective Date: 11/01/2024 SCHEDULE Insurance Company: Zurich American Insurance Company Policy Number: BAP 5570564 00 Effective Date: 11/01/2024 Expiration Date: 11/01/2025 Named Insured: Willscot Holdings Corporation Address: Additional Insured (Lessor): Only those where required by written contract or written agreement and executed prior to loss. Address: Designation Or Description Of "Leased Autos": Only those where required by written contract or written agreement and executed prior to loss. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 Page 2 of 2 © Insurance Services Office, Inc., 2019 CA 20 01 11 20 Coverages Limit Of Insurance Or Deductible Covered Autos Liability $ Each "Accident" Comprehensive $ Deductible For Each Covered "Leased Auto" Collision $ Deductible For Each Covered "Leased Auto" Specified Causes Of Loss $ Deductible For Each Covered "Leased Auto" Information required to complete this Schedule, if not shown above, will be shown in the Declarations. A. Coverage 1.Any "leased auto" designated or described in the Schedule will be considered a covered "auto" you own and not a covered "auto" you hire or borrow. 2.For a "leased auto" designated or described in the Schedule, the Who Is An Insured provision under Covered Autos Liability Coverage is changed to include as an "insured" the lessor named in the Schedule. However, the lessor is an "insured" only for "bodily injury" or "property damage" resulting from the acts or omissions by: a.You; b.Any of your "employees" or agents; or c.Any person, except the lessor or any "employee" or agent of the lessor, operating a "leased auto" with the permission of any of the above. 3.The coverages provided under this endorsement apply to any "leased auto" described in the Schedule until the expiration date shown in the Schedule, or when the lessor or his or her agent takes possession of the "leased auto", whichever occurs first. B. Loss Payable Clause 1.We will pay, as interest may appear, you and the lessor named in this endorsement for "loss" to a "leased auto". 2.The insurance covers the interest of the lessor unless the "loss" results from fraudulent acts or omissions on your part. 3.If we make any payment to the lessor, we will obtain his or her rights against any other party. C. Cancellation 1.If we cancel the Policy, we will mail notice to the lessor in accordance with the Cancellation Common Policy Condition. 2.If you cancel the Policy, we will mail notice to the lessor. 3.Cancellation ends this agreement. D.The lessor is not liable for payment of your premiums. E. Additional Definition As used in this endorsement: "Leased auto" means an "auto" leased or rented to you, including any substitute, replacement or extra "auto" needed to meet seasonal or other needs, under a leasing or rental agreement that requires you to provide direct primary insurance for the lessor. 10,000,000 1,000,000 1,000,000 Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 POLICY NUMBER: BAP 5570564 00 COMMERCIAL AUTO CA 04 49 11 16 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. CA 04 49 11 16 © Insurance Services Office, Inc., 2016 Page 1 of 1 Wolters Kluwer Financial Services | Uniform FormsTM PRIMARY AND NONCONTRIBUTORY – OTHER INSURANCE CONDITION This endorsement modifies insurance provided under the following: AUTO DEALERS COVERAGE FORM BUSINESS AUTO COVERAGE FORM MOTOR CARRIER COVERAGE FORM With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modified by the endorsement. A. The following is added to the Other Insurance Condition in the Business Auto Coverage Form and the Other Insurance – Primary And Excess Insurance Provisions in the Motor Carrier Coverage Form and supersedes any provision to the contrary: This Coverage Form's Covered Autos Liability Coverage is primary to and will not seek contribution from any other insurance available to an "insured" under your policy provided that: 1. Such "insured" is a Named Insured under such other insurance; and 2. You have agreed in writing in a contract or agreement that this insurance would be primary and would not seek contribution from any other insurance available to such "insured". B. The following is added to the Other Insurance Condition in the Auto Dealers Coverage Form and supersedes any provision to the contrary: This Coverage Form's Covered Autos Liability Coverage and General Liability Coverages are primary to and will not seek contribution from any other insurance available to an "insured" under your policy provided that: 1. Such "insured" is a Named Insured under such other insurance; and 2. You have agreed in writing in a contract or agreement that this insurance would be primary and would not seek contribution from any other insurance available to such "insured". Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 POLICY NUMBER: BAP 5570564 00 COMMERCIAL AUTO CA 04 44 10 13 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. CA 04 44 10 13 © Insurance Services Office, Inc., 2011 Page 1 of 1 Wolters Kluwer Financial Services | Uniform FormsTM WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US (WAIVER OF SUBROGATION) This endorsement modifies insurance provided under the following: AUTO DEALERS COVERAGE FORM BUSINESS AUTO COVERAGE FORM MOTOR CARRIER COVERAGE FORM With respect to coverage provided by this endorsement, the provisions of the Coverage Form apply unless modified by the endorsement. This endorsement changes the policy effective on the inception date of the policy unless another date is indicated below. Named Insured: Willscot Holdings Corporation Endorsement Effective Date: 11/01/2024 SCHEDULE Name(s) Of Person(s) Or Organization(s): Any person or organization where required by written contract and written agreement and executed prior to loss. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. The Transfer Of Rights Of Recovery Against Others To Us condition does not apply to the person(s) or organization(s) shown in the Schedule, but only to the extent that subrogation is waived prior to the "accident" or the "loss" under a contract with that person or organization. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 U-CA-832-B CW (03/23) Page 1 of 2 Includes copyrighted material of Insurance Services Office, Inc., with its permission. Blanket Notification to Others of Cancellation or Non-Renewal THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. Policy No. Effective Date: This endorsement modifies insurance provided under the: Commercial Automobile Coverage Part SCHEDULE The total number of days for mailing or delivering with respect to Paragraph B.1. of this endorsement is amended to indicate the following number of days: * The total number of days for mailing or delivering with respect to Paragraph B.2. of this endorsement is amended to indicate the following number of days: ** * If a number is not shown here, 10 days continues to apply. ** If a number is not shown here, 30 days continues to apply. A. If we cancel or non-renew this Coverage Part by written notice to the first Named Insured, we will mail or deliver notification that such Coverage Part has been cancelled or non-renewed to each person or organization shown in a list provided to us by the first Named Insured if you are required by written contract or written agreement to provide such notification. However, such notification will not be mailed or delivered if a conditional notice of renewal has been sent to the first Named Insured. Such list: 1. Must be provided to us prior to cancellation or non-renewal; 2. Must contain the names and addresses of only the persons or organizations requiring notification that such Coverage Part has been cancelled or non-renewed; and 3. Must be in an electronic format that is acceptable to us. B. Our notification as described in Paragraph A. of this endorsement will be based on the most recent list in our records as of the date the notice of cancellation or non-renewal is mailed or delivered to the first Named Insured. We will mail or deliver such notification to each person or organization shown in the list: 1. Within 10 days of the effective date of the notice of cancellation, if we cancel for non-payment of premium; or 2. At least 30 days prior to the effective date of: a. Cancellation, if cancelled for any reason other than nonpayment of premium; or b. Non-renewal, but not including conditional notice of renewal, unless a greater number of days is shown in the Schedule of this endorsement for the mailing or delivering of such notification with respect to Paragraph B.1. or Paragraph B.2. above. BAP 5570564 00 11/01/2024 Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 U-CA-832-B CW (03/23) Page 2 of 2 Includes copyrighted material of Insurance Services Office, Inc., with its permission. C. Our mailing or delivery of notification described in Paragraphs A. and B. of this endorsement is intended as a courtesy only. Our failure to provide such mailing or delivery will not: 1. Extend the Coverage Part cancellation or non-renewal date; 2. Negate the cancellation or non-renewal; or 3. Provide any additional insurance that would not have been provided in the absence of this endorsement. D. We are not responsible for the accuracy, integrity, timeliness and validity of information contained in the list provided to us as described in Paragraphs A. and B. of this endorsement. All other terms, conditions, provisions and exclusions of this policy remain the same. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 WC124 (4-84) Page 1 of 1 WC 00 03 13 Copyright 1983 National Council on Compensation Insurance, Inc. Uniform FormsTM WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY WC 00 03 13 (Ed. 04-84) WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. (This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us.) This agreement shall not operate directly or indirectly to benefit anyone not named in the Schedule. Schedule Any Person or Organization where required by written contract or written agreement and executed prior to loss. This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated. (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Endorsement Effective: 11/01/2024 Policy No. WC 5570566-00 Endorsement No.: Insured: Willscot Holdings Corporation Premium $: INCL Insurance Company: American Zurich Insurance Company Countersigned by Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 WC 252 (4-84) WC 04 03 06 (Ed. 4-84) Page 1 of 1 WORKERS’ COMPENSATION AND EMPLOYERS’ LIABILITY INSURANCE POLICY WC 04 03 06 (Ed. 4-84) WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT— CALIFORNIA This endorsement changes the policy to which it is attached effective on the inception date of the policy unless a different date is indicated below. (The following “attaching clause” need be completed only when this endorsement is issued subsequent to preparation of the pol icy.) This endorsement, effective on 11/01/2024 at 12:01 A.M. standard time, forms a part of (DATE) Policy No. WC 5570566-00 Endorsement of the AMERICAN ZURICH INSURNACE COMPANY (NAME OF INSURANCE COMPANY) issued to Willscot Holdings Corporation Premium (if any) $ INCL Authorized Representative We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. (This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us.) You must maintain payroll records accurately segregating the remuneration of your employees while engaged in the work described in the Schedule. The additional premium for this endorsement shall be % of the California workers’ compensation pre- mium otherwise due on such remuneration. Schedule Person or Organization Job Description Any Person or Organization where required by written contract or written agreement and executed prior to loss. Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 WC124 (4-84) Page 1 of 1 WC 00 03 13 Copyright 1983 National Council on Compensation Insurance, Inc. Uniform FormsTM WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY WC 00 03 13 (Ed. 04-84) WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. (This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us.) This agreement shall not operate directly or indirectly to benefit anyone not named in the Schedule. Schedule Any Person or Organization where required by written contract or written agreement and executed prior to loss. This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated. (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Endorsement Effective: 11/01/2024 Policy No. WC 5570563-00 Endorsement No.: Insured: Willscot Holdings Corporation Premium $: INCL Insurance Company: Zurich American Insurance Company Countersigned by Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 WC 42 03 04 B © Copyright 2014 National Council on Compensation Insurance, Inc. All Rights Reserved. Page 1 of 1 (Ed. 06-14) Wolters Kluwer Financial Services | Uniform FormsTM WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY WC 42 03 04 B (Ed. 6-14) TEXAS WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT This endorsement applies only to the insurance provided by the policy because Texas is shown in Item 3.A. of the Information Page. We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule, but this waiver applies only with respect to bodily injury arising out of the operations described in the Schedule where you are required by a written contract to obtain this waiver from us. This endorsement shall not operate directly or indirectly to benefit anyone not named in the Schedule. The premium for this endorsement is shown in the Schedule. Schedule 1. ( ) Specific Waiver Name of person or organization ( X ) Blanket Waiver Any person or organization for whom the Named Insured has agreed by written contract to furnish this waiver. 2. Operations: ALL PERSONS AND/OR ORGANIZATIONS THAT ARE REQUIRED BY WRITTEN CONTRACT OR AGREEMENT WITH THE INSURED, EXECUTED PRIOR TO THE ACCIDENT OR LOSS, THAT WAIVER OF SUBROGATION BE PROVIDED UNDER THIS POLICY FOR WORK PERFORMED BY YOU FOR THAT PERSON AND/OR ORGANIZATION 3. Premium: The premium charge for this endorsement shall be percent of the premium developed on payroll in connection with work performed for the above person(s) or organization(s) arising out of the operations described. 4. Advance Premium: This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated. (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Endorsement Effective 11/01/2024 Policy No. WC5570566-00 Endorsement Insured WillScot Holdings Corporation Premium INCL. Insurance Company AMERICAN ZURICH INSURANCE COMPANY Countersigned by Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 WC 99 06 43 Page 1 of 1 (Ed. 01-13) Includes copyright material of the National Council on Compensation Insurance, Inc. used with its permission. © 2012 Copyright National Council on Compensation Insurance, Inc. All Rights Reserved. WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY WC 99 06 43 BLANKET NOTIFICATION TO OTHERS OF CANCELLATION OR NONRENEWAL ENDORSEMENT This endorsement adds the following to Part Six of the policy. PART SIX CONDITIONS Blanket Notification to Others of Cancellation or Nonrenewal 1. If we cancel or non-renew this policy by written notice to you, we will mail or deliver notification that such policy has been cancelled or non-renewed to each person or organization shown in a list provided to us by you if you are required by written contract or written agreement to provide such notification. However, such notification will not be mailed or delivered if a conditional notice of renewal has been sent to you. Such list: a. Must be provided to us prior to cancellation or non-renewal; b. Must contain the names and addresses of only the persons or organizations requiring notification that such policy has been cancelled or non-renewed; and c. Must be in an electronic format that is acceptable to us. 2. Our notification as described in Paragraph 1. above will be based on the most recent list in our records as of the date the notice of cancellation or non-renewal is mailed or delivered to you. We will mail or deliver such notification to each person or organization shown in the list: a. Within seven days of the effective date of the notice of cancellation, if we cancel for non-payment of premium; or b. At least 30 days prior to the effective date of: (1) Cancellation, if cancelled for any reason other than nonpayment of premium; or (2) Non-renewal, but not including conditional notice of renewal. 3. Our mailing or delivery of notification described in Paragraphs 1. and 2. above is intended as a courtesy only. Our failure to provide such mailing or delivery will not: a. Extend the policy cancellation or non-renewal date; b. Negate the cancellation or non-renewal; or c. Provide any additional insurance that would not have been provided in the absence of this endorsement. 4. We are not responsible for the accuracy, integrity, timeliness and validity of information contained in the list provided to us as described in Paragraphs 1. and 2. above. All other terms and conditions of this policy remain unchanged. This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated. (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Endorsement Effective: 11/01/2024 Policy No.: WC 5570566-00 Endorsement No.: Insured: Willscot Holdings Corporation Premium $: INCL Insurance Company: American Zurich Insurance Company Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 WC 99 06 43 Page 1 of 1 (Ed. 01-13) Includes copyright material of the National Council on Compensation Insurance, Inc. used with its permission. © 2012 Copyright National Council on Compensation Insurance, Inc. All Rights Reserved. WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY WC 99 06 43 BLANKET NOTIFICATION TO OTHERS OF CANCELLATION OR NONRENEWAL ENDORSEMENT This endorsement adds the following to Part Six of the policy. PART SIX CONDITIONS Blanket Notification to Others of Cancellation or Nonrenewal 1. If we cancel or non-renew this policy by written notice to you, we will mail or deliver notification that such policy has been cancelled or non-renewed to each person or organization shown in a list provided to us by you if you are required by written contract or written agreement to provide such notification. However, such notification will not be mailed or delivered if a conditional notice of renewal has been sent to you. Such list: a. Must be provided to us prior to cancellation or non-renewal; b. Must contain the names and addresses of only the persons or organizations requiring notification that such policy has been cancelled or non-renewed; and c. Must be in an electronic format that is acceptable to us. 2. Our notification as described in Paragraph 1. above will be based on the most recent list in our records as of the date the notice of cancellation or non-renewal is mailed or delivered to you. We will mail or deliver such notification to each person or organization shown in the list: a. Within seven days of the effective date of the notice of cancellation, if we cancel for non-payment of premium; or b. At least 30 days prior to the effective date of: (1) Cancellation, if cancelled for any reason other than nonpayment of premium; or (2) Non-renewal, but not including conditional notice of renewal. 3. Our mailing or delivery of notification described in Paragraphs 1. and 2. above is intended as a courtesy only. Our failure to provide such mailing or delivery will not: a. Extend the policy cancellation or non-renewal date; b. Negate the cancellation or non-renewal; or c. Provide any additional insurance that would not have been provided in the absence of this endorsement. 4. We are not responsible for the accuracy, integrity, timeliness and validity of information contained in the list provided to us as described in Paragraphs 1. and 2. above. All other terms and conditions of this policy remain unchanged. This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated. (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Endorsement Effective: 11/01/2024 Policy No.: WC 5570563-00 Endorsement No.: Insured: Willscot Holdings Corporation Premium $: INCL Insurance Company: Zurich American Insurance Company Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 WC 00 03 03 C Page 1 of 1 (Ed. 10-04) Copyright 2004 National Council on Compensation Insurance, Inc. UNIFORM WORKERS COMPENSATION AND EMPLOYERS LIABILITY INSURANCE POLICY WC 00 03 03 C (Ed. 10-04) EMPLOYERS LIABILITY COVERAGE ENDORSEMENT This endorsement applies only to work in the states shown in the Schedule. A. Part One (Workers Compensation Insurance) does not apply to work in a state shown in the Schedule. B. Part Two (Employers Liability Insurance) applies to work in states shown in the Schedule as though they were shown in Item 3.A. of the Information Page. C. Part Two (Employers Liability Insurance), C. Exclusions is changed by adding these exclusions. This insurance does not cover 13. bodily injury to an employee when you are deprived of common law defenses or are subject to penalty because of your failure to secure your obligations under the workers compensation law of any state shown in the Schedule or otherwise fail to comply with that law. Schedule States ND, OH, WA, WY This endorsement changes the policy to which it is attached and is effective on the date issued unless otherwise stated. (The information below is required only when this endorsement is issued subsequent to preparation of the policy.) Endorsement 11/01/2024 Effective Policy No. WC 5570566-00 Endorsement Insured Willscot Holdings Corporation Premium INCL Insurance Company American Zurich Insurance Company Countersigned by __________________________________________ Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 CITY OF PALM SPRINGS 3200 E TAHQUITZ CANYON WAY, PALM SPRINGS, CA 92262 (760) 322-8328 BUSINESS LICENSE CERTIFICATE Fees Paid:$161.00 ISSUANCE OF THIS LICENSE DOES NOT ENTITLE THE LICENSEE TO OPERATE OR MAINTAIN A BUSINESS IN VIOLATION OF ANY OTHER LAW OR ORDINANCE. THIS IS NOT AN ENDORSEMENT OF THE ACTIVITY NOR OF THE APPLICANT'S QUALIFICATIONS. Business Name:WILLIAMS SCOTSMAN INC DBA: Owner:Williams Scotsman, Inc. Mailing Address:4646 E VAN BURREN ST STE 400 PHOENIX, AZ 85008 License Number:OC-007824-2024 Expiration Date:12/11/2025 PLEASE NOTE THAT IT IS YOUR RESPONSIBILITY TO RENEW AND UPDATE THIS LICENSE ANNUALLY. Business Location:4646 E VAN BURREN ST SUITE 400, PHOENIX, AZ 85008 Business Description:TRAILER RENTALS TO BE POSTED IN A CONSPICUOUS PLACE Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 Your Sales Representative Robert Henlon robert.henlon@willscot.com Agreement Number: Q-1879899 Revision: 1 Date: 9/26/2024 Expiration Date: 10/26/2024 Master Lease Order Lessee:0010077074 PALM SPRINGS CITY OF 200 S CIVIC DR PALM SPRINGS, CA 92262 Contact: Ryan Phay 200 S CIVIC DR PALM SPRINGS, CA 92262, US Phone: 7603228272 Email: ryan.phay@palmspringsca.gov Ship To Address: PALM SPRINGS, CA 92262, US Estimated Delivery Date :10/10/2024 Rental Pricing Per Billing Cycle Quantity Price Extended 20' STANDARD TRI CAM CONTAINER 1 $ 185.00 $ 185.00 Personal Property Expense 1 $ 9.25 $ 9.25 Minimum Lease Billing Period: 12 Total Recurring Building Charges:$ 185.00 Billing Cycle : 28 days Subtotal of Other Recurring Charges:$ 9.25 Total Recurring Charges Per Billing Cycle:$ 194.25 Total Recurring Charges Per Billing Cycle Including Estimated Taxes:$ 212.22 Estimated Delivery And Installation Delivery - 8' wide Flatbed 1 $ 221.00 $ 221.00 Return - 8' wide Flatbed 1 $ 221.00 $ 221.00 Fuel Surcharge Return 1 $ 0.00 $ 0.00 Fuel Surcharge Delivery 1 $ 0.00 $ 0.00 Essentials Delivery Charge 1 $ 0.00 $ 0.00 Total Delivery and Installation Charges:$ 442.00 Total Delivery and Installation Charges Including Estimated Taxes:$ 482.88 Estimated Final Return Charges* Due On Final Invoice*:$ 0.00 Due On Final Invoice Including Estimated Taxes*:$ 0.00 Total Including Recurring Billing Charges, Delivery, Installation and Return**:$ 2,773.00 Total Including Recurring Billing Charges, Delivery, Installation and Return Including Estimated Taxes**:$ 3,029.52 Summary of Charges Model: 20' STANDARD TRI CAM CONTAINER Quantity: 1 Total Charges for (1) Building(s): $ 2,773.00 Total Charges for (1) Building(s) Including Estimated Tax: $ 3,029.52 Williams Scotsman, Inc. 4646 East Van Buren St, Suite 400, Phoenix, AZ 85005 1-800-782-1500 Page 1 of 2 Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814 Your Sales Representative Robert Henlon robert.henlon@willscot.com Agreement Number: Q-1879899 Revision: 1 Date: 9/26/2024 Expiration Date: 10/26/2024 Billing & Payment Terms 1. Lessor reserves the right to request Payment in advance of the Delivery Date, and Lessee may be required to make payment in advance to secure its performance of this Lease. Advance payments may include initial, final and/or recurring charges and will be applied to applicable invoices. Lessor reserves the right to charge an administrative fee for special billing requests. 2. Invoices will be generated on a 28 Day Billing Cycle, in advance, with payment due no later than Net 30 Days after invoice issuance. 3. AMOUNTS UNPAID WHEN DUE SHALL BE CHARGED INTEREST OF UP TO 1½% PER BILLING CYCLE OF THE UNPAID AMOUNT FOR THE PERIOD UNPAID [CUSTOMER EXEMPT], AND AN ADMINISTRATIVE CHARGE PER BILLING CYCLE THE INVOICE REMAINS UNPAID.[CUSTOMER EXEMPT] 4. Initial Invoice Charges may include first and last Billing Cycle charges, delivery and installation charges, estimated charges for pick-up, teardown and Equipment removal, as well as any fuel surcharges. Final charges for pick-up, teardown and Equipment removal will be finalized at the time of pick-up based on existing site conditions. Upon the expiration of the Minimum Lease Term, the Lessor may make changes to the Lease rate, pick-up, teardown, removal, fuel surcharges and/or other charges. 5. The Initial Invoice will be issued on the earlier of the confirmation date or Delivery Date. In the event Lessee requests a delay to the delivery, as agreed to in the Confirmation, the Initial Invoice will be issued solely for the Equipment lease charges and a Storage Fee equal to 50% of the Lease, and all remaining Initial Invoice Charges will be invoiced on the Delivery Date. Lessee agrees that upon Termination prior to the Minimum Lease Term, Lessee shall pay the remaining payments for the unfulfilled Minimum Lease Term, and any applicable charges related to the Equipment, plus all return charges. Optional Insurance and Optional Coverage General Liability Insurance If (a.) quoted on the pricing page(s) or (b.) initialed in the optional section of the pricing page(s), Customer elects to participate in the General Liability Insurance Program, whereby Lessee will receive insurance coverage through American Southern Insurance Company ("Insurer") and administered by Allen Insurance Group ("Agent"). The Lessee acknowledges and agrees that the policy issued by the Insurer is a third party liability policy that covers those amounts, subject to policy exclusions, that Lessee is legally obligated to pay due to bodily injury and property damage arising from the use and occupancy of Equipment leased from Lessor up to the policy limits. Coverage is subject to underwriting and specific terms and conditions and exclusions set forth in the policy. An outline of coverage is available upon request. Loss Damage If (a.) quoted on the pricing page(s) or (b.) initialed in the optional section of the pricing page(s), Lessee elects to participate in the Loss Damage Waiver Program. Lessee understands and agrees that under this program and subject to any exclusions, the Lessor waives, for a fee, Lessee's obligation to carry Commercial Property Insurance and Lessee's liability for repair or replacement of the Equipment leased from Lessor resulting in loss or damage. Please refer to the LOSS DAMAGE WAIVER PROGRAM ADDENDUM for specific details on coverage, exclusions and restrictions on coverage. The Loss Damage Waiver is not and shall not constitute a contract for insurance. Contents Insurance If (a.) quoted on the pricing page(s) or (b.) initialed in the optional section of the pricing page(s), Lessee elects to participate in the Contents Insurance Coverage Program, whereby Lessee will receive insurance coverage through Airpark Insurance ("Insurer") and administered by Falvey Insurance Group, Ltd. ("Falvey")) as Managing General Agent of those Interested Underwriters at Lloyd’s, London ("Agent"). The Lessee acknowledges and agrees that the policy issued by the Insurer is a third party property policy that, subject to policy exclusions, provides comprehensive contents coverage and adds an additional layer of protection for the stored contents up to the selected limit of coverage. Coverage is subject to underwriting and specific terms and conditions and exclusions set forth in the policy. An outline of coverage is available upon request. Terms & Conditions Lessee hereby acknowledges and agrees to be bound by the Master Equipment Lease Agreement dated [1/16/2024] between the Lessee and Lessor in its entirety, which is incorporated herein by reference, and Lessee agrees to Lease the Equipment from Lessor subject to the terms therein. Acceptance and Authority Lessee represents and warrants they have the authority to agree to the terms and conditions stated in this Agreement by (1) signing this document, (2) executing an Order that references this Agreement, (3) taking delivery of the Equipment, or (4) other commercially acceptable means methods and, by doing so, this Agreement shall become legally binding. Lessor will consider the Order rejected if changes have been made to the Order by Lessee. Lessee: PALM SPRINGS CITY OF Signature:\s1\Date:\d1\ Print Name:\n1\Title:\t1\ PO#: Williams Scotsman, Inc. 4646 East Van Buren St, Suite 400, Phoenix, AZ 85005 1-800-782-1500 Page 2 of 2 Docusign Envelope ID: 50317676-9857-4CF0-A0DA-8EF6E04B1814