Loading...
HomeMy WebLinkAbout24B290 - United Paint & Coatings Co.CONTRACT ABSTRACT Contract/Amendment Name of Contract: Company Name: Company Contact: Email: Summary of Services: Contract Price: Contract Term: Public Integrity/ Business Disclosure Forms: Contract Administration Lead Department: Contract Administrator/ Ext: Contract Approvals Council/City Manager Approval Date: Agreement Number: Amendment Number: Contract Compliance Exhibits: Insurance: Routed By: Bonds: Business License: Sole Source Co-Op CoOp Agmt #: Sole Source Documents: CoOp Name: CoOp Pricing: By: Submitted on: Contract Abstract Form Rev 8.16.23 Authorized Signers: Name, Email (Corporations require 2 signatures) On-Call Painting & Wallcovering Services (Secondary) United Paint & Coatings Co. Cristian Gonzalez; Ulysses Gonzalez, Sr. Project Mgr admin@unitedcontractingcompany.com; PM: 442-899-8893 provide on-call painting & wallcovering services $420,000 12/01/2024 - 11/30/2027 Yes Cristian Gonzalez, admin@unitedcontractingcompany.com Maintenance & Facilities David McAbee November 21, 2024 24B290 N/A Yes Yes Yes Procurement N/A No IFB 24-36 N/A N/A N/A October 30, 2024 Brian Sotak-Rossman Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Page 1 of 21 CONTRACT SERVICES AGREEMENT 24B290 ON-CALL PAINTING AND WALLCOVERING SERVICES THIS AGREEMENT FOR CONTRACT SERVICES (“Agreement”) is made and entered into on December 1, 2024, by and between the City of Palm Springs, a California charter city and municipal corporation (“City”), and United Paint & Coatings Co., a California Sole Proprietor, (“Contractor”). City and Contractor are individually referred to as “Party” and are collectively referred to as the “Parties”. RECITALS A. City requires the services of a licensed and qualified firm to provide on-call painting and wallcovering services, (“Project”). B. Contractor has submitted to City a Bid to provide on-call painting and wallcovering services, under the terms of this Agreement. C. Based on its experience, education, training, and reputation, Contractor is qualified and desires to provide the necessary services to City for the Project. D. City desires to retain the services of Contractor for the Project. NOW, THEREFORE, in consideration of the promises and mutual obligations, covenants, and conditions contained herein, and other valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties agree as follows: AGREEMENT 1. CONTRACTOR SERVICES 1.1 Scope of Services. In compliance with all terms and conditions of this Agreement, Contractor shall provide services to City as described in the Scope of Services/Work attached to this Agreement as Exhibit “A” and incorporated herein by reference (the “Services” or “Work”). Exhibit "A" includes the agreed upon schedule of performance and the schedule of fees. Contractor warrants that the Services shall be performed in a competent, professional, and satisfactory manner consistent with the level of care and skill ordinarily exercised by high quality, experienced, and well qualified members of the profession currently practicing under similar conditions. In the event of any inconsistency between the terms contained in the Scope of Services/Work and the terms set forth in this Agreement, the terms set forth in this Agreement shall govern. 1.2 Compliance with Law. Contractor shall comply with all applicable federal, state, and local laws, statutes and ordinances and all lawful orders, rules, and regulations when performing the Services. Contractor shall be liable for all violations of such laws and regulations in connection with the Services and this Agreement. 1.3 Licenses and Permits. Contractor shall obtain at its sole cost and expense such licenses, permits, and approvals as may be required by law for the performance of the Services required by this Agreement. 1.4 Familiarity with Work. By executing this Agreement, Contractor warrants that it has carefully considered how the Work should be performed and fully understands the facilities, difficulties, and restrictions attending performance of the Work under this Agreement. 2. TIME FOR COMPLETION Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Page 2 of 21 The time for completion of the Services to be performed by Contractor is an essential condition of this Agreement. Contractor shall prosecute regularly and diligently the work of this Agreement according to the agreed upon schedule of performance set forth in Exhibit “A.” Neither Party shall be accountable for delays in performance caused by any condition beyond the reasonable control and without the fault or negligence of the non-performing Party. Delays shall not entitle Contractor to any additional compensation regardless of the Party responsible for the delay. 3. COMPENSATION OF CONTRACTOR 3.1 Compensation of Contractor. Contractor shall be compensated and reimbursed for the services rendered under this Agreement in accordance with the schedule of fees set forth in Exhibit “A”. The total amount of Compensation shall not exceed $420,000. 3.2 Method of Payment. In any month in which Contractor wishes to receive payment, Contractor shall submit to City an invoice for Services rendered prior to the date of the invoice, no later than the first working day of such month, in the form approved by City’s finance director. Payments shall be based on the hourly rates set forth in Exhibit “A” for authorized services performed. City shall pay Contractor for all expenses stated in the invoice that are approved by City and consistent with this Agreement, within thirty (30) days of receipt of Contractor’s invoice. 3.3 Changes. In the event any change or changes in the Services is requested by City, Parties shall execute a written amendment to this Agreement, specifying all proposed amendments, including, but not limited to, any additional fees. An amendment may be entered into: A. To provide for revisions or modifications to documents, work product, or Work, when required by the enactment or revision of any subsequent law; or B. To provide for additional services not included in this Agreement or not customarily furnished in accordance with generally accepted practice in Contractor’s profession. 3.4 Appropriations. This Agreement is subject to, and contingent upon, funds being appropriated by the City Council of City for each fiscal year. If such appropriations are not made, this Agreement shall automatically terminate without penalty to City. 4. PERFORMANCE SCHEDULE 4.1 Time of Essence. Time is of the essence in the performance of this Agreement. 4.2 Schedule of Performance. All Services rendered under this Agreement shall be performed under the agreed upon schedule of performance set forth in Exhibit “A.” Any time period extension must be approved in writing by the Contract Officer. 4.3 Force Majeure. The time for performance of Services to be rendered under this Agreement may be extended because of any delays due to a Force Majeure Event if Contractor notifies the Contract Officer within ten (10) days of the commencement of the Force Majeure Event. A Force Majeure Event shall mean an event that materially affects the Contractor’s performance and is one or more of the following: (1) Acts of God or other natural disasters occurring at the project site; (2) terrorism or other acts of a public enemy; (3) orders of governmental authorities (including, without limitation, unreasonable and unforeseeable delay in the issuance of permits or approvals by governmental authorities that are required for the Work); and (4) pandemics, epidemics or quarantine restrictions. For purposes of this section, “orders of governmental authorities,” includes ordinances, emergency proclamations and orders, rules to protect the public health, welfare and safety, and other actions of the City in its capacity as a municipal authority. After Contractor notification, the Contract Officer shall investigate the facts and the extent of any necessary delay, and extend the time for performing the Services for the period of the enforced delay when and if, in the Contract Officer’s judgment, such delay is justified. The Contract Officer’s determination shall be final and conclusive upon the Parties to this Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Page 3 of 21 Agreement. The Contractor will not receive an adjustment to the contract price or any other compensation. Notwithstanding the foregoing, the City may still terminate this Agreement in accordance with the termination provisions of this Agreement. 4.4 Term. Unless earlier terminated in accordance with Section 4.5 of this Agreement, this Agreement shall continue in full force and effect for a period of three years, commencing on December 1, 2024, and ending on November 30, 2027, unless extended by mutual written agreement of the Parties. In addition, the term may be extended at the sole discretion of the City upon written notice to the Contractor, for two (2) additional one (1) year terms. 4.5 Termination Prior to Expiration of Term. City may terminate this Agreement at any time, with or without cause, upon thirty (30) days written notice to Contractor. Where termination is due to the fault of Contractor and constitutes an immediate danger to health, safety, and general welfare, the period of notice shall be such shorter time as may be determined by the City. Upon receipt of the notice of termination, Contractor shall immediately cease all Services except such as may be specifically approved by the Contract Officer. Contractor shall be entitled to compensation for all Services rendered prior to receipt of the notice of termination and for any Services authorized by the Contract Officer after such notice. City shall not be liable for any costs other than the charges or portions thereof which are specified herein. Contractor shall not be entitled to payment for unperformed Services and shall not be entitled to damages or compensation for termination of Work. If the termination is for cause, the City shall have the right to take whatever steps it deems necessary to correct Contractor's deficiencies and charge the cost thereof to Contractor, who shall be liable for the full cost of the City's corrective action. Contractor may not terminate this Agreement except for cause, upon thirty (30) days written notice to City. 5. COORDINATION OF WORK 5.1 Representative of Contractor. The following principal of Contractor is designated as being the principal and representative of Contractor authorized to act and make all decisions in its behalf with respect to the specified Services: Cristian Gonzalez, Owner. It is expressly understood that the experience, knowledge, education, capability, and reputation of the foregoing principal is a substantial inducement for City to enter into this Agreement. Therefore, the foregoing principal shall be responsible during the term of this Agreement for directing all activities of Contractor and devoting sufficient time to personally supervise the Services under this Agreement. The foregoing principal may not be changed by Contractor without prior written approval of the Contract Officer. 5.2 Contract Officer. The Contract Officer shall be the City Manager or his/her designee ("Contract Officer"). Contractor shall be responsible for keeping the Contract Officer fully informed of the progress of the performance of the Services. Contractor shall refer any decisions that must be made by City to the Contract Officer. Unless otherwise specified, any approval of City shall mean the approval of the Contract Officer. 5.3 Prohibition Against Subcontracting or Assignment. The experience, knowledge, education, capability, and reputation of Contractor, its principals, and employees, were a substantial inducement for City to enter into this Agreement. Contractor shall not contract with any other individual or entity to perform any Services required under this Agreement without the City's express written approval. In addition, neither this Agreement nor any interest may be assigned or transferred, voluntarily or by operation of law, without the prior written approval of City. Subcontracts, if any, shall contain a provisions making them subject to all provisions stipulated in this Agreement including without limitation the insurance and indemnification requirements. If Contractor is permitted to subcontract any part of this Agreement by City, Contractor shall be responsible to City for the acts and omissions of its subcontractor(s) in the same manner as it is for persons directly employed. Nothing contained in this Agreement shall create any contractual relationships between any subcontractor and City. Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Page 4 of 21 5.4 Independent Contractor. Neither City nor any of its employees shall have any control over the manner, mode, or means by which Contractor, its agents, or employees, perform the Services required, except as otherwise specified. Contractor shall perform all required Services as an independent contractor of City and shall not be an employee of City and shall remain at all times as to City a wholly independent contractor with only such obligations as are consistent with that role; however, City shall have the right to review Contractor’s work product, result, and advice. Contractor shall not at any time or in any manner represent that it or any of its agents or employees are agents or employees of City. Contractor shall pay all wages, salaries, and other amounts due personnel in connection with their performance under this Agreement and as required by law. Contractor shall be responsible for all reports and obligations respecting such personnel, including, but not limited to: social security taxes, income tax withholding, unemployment insurance, and workers’ compensation insurance. Contractor shall not have any authority to bind City in any manner. 5.5 Personnel. Contractor agrees to assign the following individuals to perform the services in this Agreement. Contractor shall not alter the assignment of the following personnel without the prior written approval of the Contract Officer. Acting through the City Manager, the City shall have the unrestricted right to order the removal of any personnel assigned by Contractor by providing written notice to Contractor. Name: Title: (to be determined) 5.6 California Labor Code Requirements. A. Contractor is aware of the requirements of California Labor Code Sections 1720 et seq. and 1770 et seq., which require the payment of prevailing wage rates and the performance of other requirements on certain “public works” and “maintenance” projects (“Prevailing Wage Laws”). If the Services are being performed as part of an applicable “public works” or “maintenance” project, as defined by the Prevailing Wage Laws, and if the total compensation is $15,000 or more for maintenance or $25,000 or more for construction, alteration, demolition, installation, or repair, Contractor agrees to fully comply with such Prevailing Wage Laws. Contractor shall defend, indemnify, and hold the City, its officials, officers, employees, and agents free and harmless from any claims, liabilities, costs, penalties, or interest arising out of any failure or alleged failure to comply with the Prevailing Wage Laws. It shall be mandatory upon the Contractor and all subcontractors to comply with all California Labor Code provisions, which include but are not limited to prevailing wages (Labor Code Sections 1771, 1774 and 1775), employment of apprentices (Labor Code Section 1777.5), certified payroll records (Labor Code Sections 1771.4 and 1776), hours of labor (Labor Code Sections 1813 and 1815) and debarment of contractors and subcontractors (Labor Code Section 1777.1). B. If the Services are being performed as part of an applicable “public works” or “maintenance” project and if the total compensation is $15,000 or more for maintenance or $25,000 or more for construction, alteration, demolition, installation, or repair, then pursuant to Labor Code Sections 1725.5 and 1771.1, the Contractor and all subcontractors performing such Services must be registered with the Department of Industrial Relations. Contractor shall maintain registration for the duration of the Project and require the same of any subcontractors, as applicable. This Agreement may also be subject to compliance monitoring and enforcement by the Department of Industrial Relations. It shall be Contractor’s sole responsibility to comply with all applicable registration and labor compliance requirements. 6. INSURANCE Contractor shall procure and maintain, at its sole cost and expense, policies of insurance as set forth in the attached Exhibit "B", incorporated herein by reference. 7. INDEMNIFICATION. Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Page 5 of 21 7.1 Indemnification. To the fullest extent permitted by law, Contractor shall defend (at Contractor’s sole cost and expense), indemnify, protect, and hold harmless City, its elected officials, officers, employees, agents, and volunteers (collectively the “Indemnified Parties”), from and against any and all liabilities, actions, suits, claims, demands, losses, costs, judgments, arbitration awards, settlements, damages, demands, orders, penalties, and expenses including legal costs and attorney fees (collectively “Claims”), including but not limited to Claims arising from injuries to or death of persons (Contractor’s employees included), for damage to property, including property owned by City, for any violation of any federal, state, or local law or ordinance or in any manner arising out of, pertaining to, or incident to any acts, errors or omissions, or willful misconduct committed by Contractor, its officers, employees, representatives, and agents, that arise out of or relate to Contractor’s performance of Services or this Agreement. This indemnification clause excludes Claims arising from the sole negligence or willful misconduct of the Indemnified Parties. Under no circumstances shall the insurance requirements and limits set forth in this Agreement be construed to limit Contractor’s indemnification obligation or other liability under this Agreement. Contractor’s indemnification obligation shall survive the expiration or earlier termination of this Agreement until all actions against the Indemnified Parties for such matters indemnified are fully and finally barred by the applicable statute of limitations or, if an action is timely filed, until such action is final. 7.2 Design Professional Services Indemnification and Reimbursement. If Contractor’s obligation to defend, indemnify, and/or hold harmless arises out of Contractor’s performance as a “design professional” (as that term is defined under Civil Code section 2782.8), then, and only to the extent required by Civil Code section 2782.8, which is fully incorporated herein, Contractor’s indemnification obligation shall be limited to the extent which the Claims arise out of, pertain to, or relate to the negligence, recklessness, or willful misconduct of the Contractor in the performance of the Services or this Agreement, and, upon Contractor obtaining a final adjudication by a court of competent jurisdiction, Contractor’s liability for such claim, including the cost to defend, shall not exceed the Contractor’s proportionate percentage of fault. 8. RECORDS AND REPORTS 8.1 Reports. Contractor shall periodically prepare and submit to the Contract Officer reports concerning the performance of the Services required by this Agreement, or as the Contract Officer shall require. 8.2 Records. Contractor shall keep complete, accurate, and detailed accounts of all time, costs, expenses, and expenditures pertaining in any way to this Agreement. Contractor shall keep such books and records as shall be necessary to properly perform the Services required by this Agreement and enable the Contract Officer to evaluate the performance of such Services. The Contract Officer shall have full and free access to such books and records at all reasonable times, including the right to inspect, copy, audit, and make records and transcripts from such records. 8.3 Ownership of Documents. All drawings, specifications, reports, records, documents, and other materials prepared by Contractor in the performance of this Agreement shall be the property of City. Contractor shall deliver all above-referenced documents to City upon request of the Contract Officer or upon the termination of this Agreement. Contractor shall have no claim for further employment or additional compensation as a result of the exercise by City of its full rights or ownership of the documents and materials. Contractor may retain copies of such documents for Contractor's own use. Contractor shall have an unrestricted right to use the concepts embodied in such documents. 8.4 Release of Documents. All drawings, specifications, reports, records, documents, and other materials prepared by Contractor in the performance of Services under this Agreement shall not be released publicly without the prior written approval of the Contract Officer. Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Page 6 of 21 8.5 Audit and Inspection of Records. After receipt of reasonable notice and during the regular business hours of City, Contractor shall provide City, or other agents of City, such access to Contractor’s books, records, payroll documents, and facilities as City deems necessary to examine, copy, audit, and inspect all accounting books, records, work data, documents, and activities directly related to Contractor’s performance under this Agreement. Contractor shall maintain such books, records, data, and documents in accordance with generally accepted accounting principles and shall clearly identify and make such items readily accessible to such parties during the term of this Agreement and for a period of three (3) years from the date of final payment by City hereunder. 9. ENFORCEMENT OF AGREEMENT 9.1 California Law. This Agreement shall be construed and interpreted both as to validity and to performance of the parties in accordance with the laws of the State of California. Legal actions concerning any dispute, claim, or matter arising out of or in relation to this Agreement shall be instituted in the Superior Court of the County of Riverside, State of California, or any other appropriate court in such county, and Contractor covenants and agrees to submit to the personal jurisdiction of such court in the event of such action. 9.2 Interpretation. This Agreement shall be construed as a whole according to its fair language and common meaning to achieve the objectives and purposes of the Parties. The terms of this Agreement are contractual and the result of negotiation between the Parties. Accordingly, any rule of construction of contracts (including, without limitation, California Civil Code Section 1654) that ambiguities are to be construed against the drafting party, shall not be employed in the interpretation of this Agreement. The caption headings of the various sections and paragraphs of this Agreement are for convenience and identification purposes only and shall not be deemed to limit, expand, or define the contents of the respective sections or paragraphs. 9.3 Waiver. No delay or omission in the exercise of any right or remedy of a non- defaulting Party on any default shall impair such right or remedy or be construed as a waiver. No consent or approval of City shall be deemed to waive or render unnecessary City’s consent to or approval of any subsequent act of Contractor. Any waiver by either Party of any default must be in writing. No such waiver shall be a waiver of any other default concerning the same or any other provision of this Agreement. 9.4 Rights and Remedies are Cumulative. Except with respect to rights and remedies expressly declared to be exclusive in this Agreement, the rights and remedies of the parties are cumulative. The exercise by either Party of one or more of such rights or remedies shall not preclude the exercise by it, at the same or different times, of any other rights or remedies for the same default or any other default by the other Party. 9.5 Legal Action. In addition to any other rights or remedies, either Party may take legal action, in law or in equity, to cure, correct, or remedy any default, to recover damages for any default, to compel specific performance of this Agreement, to obtain injunctive relief, a declaratory judgment, or any other remedy consistent with the purposes of this Agreement. 9.6 Attorney Fees. In the event any dispute between the Parties with respect to this Agreement results in litigation or any non-judicial proceeding, the prevailing Party shall be entitled, in addition to such other relief as may be granted, to recover from the non-prevailing Party all reasonable costs and expenses. These include but are not limited to reasonable attorney fees, expert contractor fees, court costs and all fees, costs, and expenses incurred in any appeal or in collection of any judgment entered in such proceeding. 10. CITY OFFICERS AND EMPLOYEES: NON-DISCRIMINATION 10.1 Non-Liability of City Officers and Employees. No officer or employee of City shall be personally liable to the Contractor, or any successor-in-interest, in the event of any default Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Page 7 of 21 or breach by City or for any amount which may become due to the Contractor or its successor, or for breach of any obligation of the terms of this Agreement. 10.2 Conflict of Interest. Contractor acknowledges that no officer or employee of the City has or shall have any direct or indirect financial interest in this Agreement, nor shall Contractor enter into any agreement of any kind with any such officer or employee during the term of this Agreement and for one (1) year thereafter. Contractor warrants that Contractor has not paid or given, and will not pay or give, any third party any money or other consideration in exchange for obtaining this Agreement. 10.3 Covenant Against Discrimination. In connection with its performance under this Agreement, Contractor shall not discriminate against any employee or applicant for employment because of actual or perceived race, religion, color, sex, age, marital status, ancestry, national origin ( i.e., place of origin, immigration status, cultural or linguistic characteristics, or ethnicity), sexual orientation, gender identity, gender expression, physical or mental disability, or medical condition (each a “prohibited basis”). Contractor shall ensure that applicants are employed, and that employees are treated during their employment, without regard to any prohibited basis. As a condition precedent to City’s lawful capacity to enter this Agreement, and in executing this Agreement, Contractor certifies that its actions and omissions hereunder shall not incorporate any discrimination arising from or related to any prohibited basis in any Contractor activity, including but not limited to the following: employment, upgrading, demotion or transfer; recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship; and further, that Contractor is in full compliance with the provisions of Palm Springs Municipal Code Section 7.09.040, including without limitation the provision of benefits, relating to non-discrimination in city contracting. 11. MISCELLANEOUS PROVISIONS 11.1 Notice. Any notice, demand, request, consent, approval, or communication that either Party desires, or is required to give to the other Party or any other person shall be in writing and either served personally or sent by pre-paid, first-class mail to the address set forth below. Notice shall be deemed communicated seventy-two (72) hours from the time of mailing if mailed as provided in this Section. Either Party may change its address by notifying the other Party of the change of address in writing. To City: City of Palm Springs Attention: City Manager/ City Clerk 3200 E. Tahquitz Canyon Way Palm Springs, California 92262 To Contractor: United Paint & Coatings Co. Attention: Cristian Gonzalez 50485 Jalisco Ave. Coachella, CA 92236 11.2 Integrated Agreement. This Agreement constitutes the entire understanding between the Parties and supersedes and cancels all prior negotiations, arrangements, agreements, representations, and understandings, if any, made by or among the Parties with respect to the subject matter in this Agreement. 11.3 Amendment. No amendments or other modifications of this Agreement shall be binding unless through written agreement signed by all Parties. 11.4 Severability. Whenever possible, each provision of this Agreement shall be interpreted in such a manner as to be effective and valid under applicable law. In the event that any one or more of the phrases, sentences, clauses, paragraphs, or sections contained in this Agreement shall be declared invalid or unenforceable by valid judgment or decree of a court of Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Page 8 of 21 competent jurisdiction, such invalidity or unenforceability shall not affect any of the remaining phrases, sentences, clauses, paragraphs, or sections of this Agreement, which shall be interpreted to carry out the intent of the Parties. 11.5 Successors in Interest. This Agreement shall be binding upon and inure to the benefit of the Parties’ successors and assignees. 11.6 Third Party Beneficiary. Except as may be expressly provided for in this Agreement, nothing contained in this Agreement is intended to confer, nor shall this Agreement be construed as conferring, any rights, including, without limitation, any rights as a third-party beneficiary or otherwise, upon any entity or person not a party to this Agreement. 11.7 Recitals. The above-referenced Recitals are hereby incorporated into the Agreement as though fully set forth in this Agreement and each Party acknowledges and agrees that such Party is bound, for purposes of this Agreement, by the same. 11.8 Authority. The persons executing this Agreement on behalf of the Parties warrant that they are duly authorized to execute this Agreement on behalf of Parties and that by so executing this Agreement the Parties are formally bound to the provisions of this Agreement. 11.9 Counterparts. This Agreement may be signed in counterparts, each of which shall constitute an original. 11.10 Compliance with Economic Sanctions in Response to Russia's Actions in Ukraine. When funding for the services is provided, in whole or in part, by an agency controlled of the State of California, Consultant shall fully and adequately comply with California Executive Order N-6-22 (“Russian Sanctions Program”). As part of this compliance process, Consultant shall also certify compliance with the Russian Sanctions Program by completing the form located in Exhibit “C” (Russian Sanctions Certification), attached hereto and incorporated herein by reference. Consultant shall also require any subconsultants to comply with the Russian Sanctions Program and certify compliance pursuant to this Section. [SIGNATURES ON NEXT PAGE] Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Page 9 of 21 SIGNATURE PAGE TO CONTRACT SERVICES AGREEMENT BY AND BETWEEN THE CITY OF PALM SPRINGS AND UNITED PAINT & COATINGS CO. IN WITNESS WHEREOF, the Parties have executed this Agreement as of the dates stated below. CONTRACTOR: By: _____________________________ By: _____________________________ Signature Signature (2nd signature required for Corporation) Date: ___________________________ Date: ___________________________ CITY OF PALM SPRINGS: APPROVED BY CITY COUNCIL: Date: ________________ Item No. ________________ APPROVED AS TO FORM: ATTEST: By: _____________________________ By: _____________________________ City Attorney City Clerk APPROVED: By: _____________________________ Date: ____________________________ City Manager – over $50,000 Deputy/Assistant City Manager – up to $50,000 Director – up to $25,000 Manager – up to $5,000 Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 11/7/2024 11/21/2024 1F 11/21/2024 Page 10 of 21 EXHIBIT “A” SCOPE OF SERVICES/WORK Including, Schedule of Fees And Schedule of Performance Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Page 11 of 21 1.1 Background: The Contractor will provide on-call painting and wallcovering services at various City of Palm Springs Buildings and Facilities. 1.2 Scope: A. Contractor shall furnish labor, site supervision, materials, and equipment to perform painting and wallcovering (Work) on an as-requested basis in city facilities included in this solicitation. The scope of Work shall include, but is not limited to general painting, repainting, repair, finishing, refinishing, remedial plastering and patching, sheet rock finish taping (only), patching, joint preparation, graffiti removal, surface preparation and installation of wall covering, repairs and related maintenance. Contractor must provide proper signage and/or protection to prevent staff & public from coming into contact with wet paint and/or plaster. Contractor may be required to move furniture when working on interior projects. B. Contractor must only use Low-VOC paint. C. All work shall be performed by and billed to the lowest applicable job class level. The majority of the Work requested under this contract is to be performed by one (1) trade person per job. All service shall be performed by personnel who are journeyman level (or equivalent according to industry norms) as described by industry standards. The Contractor must receive prior written approval from the City before assigning more than one (1) trade person per job. On jobs requiring more than three (3) trade persons, the Contractor shall be required to designate one (1) employee to perform the duties and responsibilities of Foreman and that person shall receive compensation as such. D. Contractor must attend pre-construction walkthroughs on all projects. E. Contractor must provide paint color and finish submittals to City’s Project Manager for review/approval. F. Contractor shall be responsible for setting up proper site protection prior to commencing services, as well as daily clean-up following completion of work. G. The Contractor shall be solely responsible for correcting any damages caused by on- site work, due to improperly protecting property. H. Response time: 1. Contractor shall respond to department within 48 hours from request for work. 2. Contractor shall respond to emergency calls for service or repair within twenty-four (24) hours. 3. Emergency responses include weekends, after-hours and holidays. I. Contractor shall have weekly written communication with the City Project Manager to provide project updates and provide forthcoming schedule updates. J. Historic Properties: Contractor shall have knowledge of the City of Palm Springs Historic buildings and the various historic classifications that shall define and outline the repair and improvements allowed. 1. Contractor shall discuss all modifications with the City Project Manager prior to commencement of work. 2. Contractor shall make themselves aware of the City’s historic properties: https://www.palmspringsca.gov/government/departments/planning/historic- resources/historic-properties Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Page 12 of 21 K. Correction of work deficiencies: 1. The Contractor shall correct work rejected by the City as failing to conform to the requirements in the project documents within thirty days. The Contractor shall bear the cost of correcting such rejected work, including the costs of uncovering, replacement, and additional testing. 2. If the Contractor fails to commence correction of nonconforming work within a seven-day period after written notice, the city may correct the deficiencies by other means. In such case, the City may exercise rights and remedies as provided in section 9.4 of agreement. 3. In addition to the Contractor’s other obligations, the contractor shall, for a period of one year after substantial completion, correct work not conforming to the requirements of the work. L. Compliance with regulations and permits: Contractor shall comply with or exceed all relevant statutes, codes, rules, and regulations as may be applicable to this contract and shall be responsible for securing any and all permits as required by the governing authority. The City shall reimburse the Contractor for only the actual cost of said permits. M. Equipment and supplies: Contractor is to provide, at no additional cost to the City, all necessary equipment, hand, and power tools and supplies typically used by the job classification and/or assigned trade person. Mechanical or other equipment used for Work must be of a type that is approved by the industry and shall be operated in such a manner as not to cause danger of any nature to employees or other persons or damage to the building structure, fixtures, furnishings, etc. The City, at its sole and absolute discretion, may approve to pay for equipment, tools, or materials it determines is not typical of that job classification. Contractor must not store equipment and/or supplies on any City property. N. General safety requirements: The Contractor shall be responsible for all safety precautions required in connection with their work, including regulations of the Occupational Safety and Health Administration (OSHA) and other governing agencies. The City reserves the right to oversee all service work from a safety standpoint and require the Contractor to take appropriate action to ensure safety and code compliance. O. Damages: Necessary precautions shall be taken at all times to protect persons, property and equipment from injury or damage. Any damage shall be reported, reviewed, and discussed with the City Project Manager. P. Security: 1. The Contractor is responsible for ensuring all entries/exits to the work area are secure during the discharge of their duties (doors and gates must not be propped open). The Contractor does not have the authority and shall not grant access to any person requesting entry into the building or specific work area. 2. Any items or articles of apparent value found by the Contractor’s personnel in any areas of the building or site shall be turned over to the City Project Manager or on- site Security. Any suspicious articles that may be found, or persons loitering or conducting themselves in a manner to arouse suspicion or possibly in need of help, shall be immediately reported to Police. Q. Disposal and salvage of waste material: Contractor must dispose of or salvage all waste material generated by its service operations under the contract in an off-site location, in compliance with all applicable laws and regulations. City encourages Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Page 13 of 21 Contractor to salvage material in an environmentally friendly manner if possible. City retains the right to retain materials or have another party salvage material, at the discretion and direction of the City Project Manager. R. Uniforms and vehicles: 1. The Contractor shall be required to properly uniform its service personnel, and they shall present a clean and neat appearance at all times. Day service personnel shall have color-coordinated shirts with company name and/or logo provided by the Contractor. 2. Contractor vehicles must display company logo and name. 1.3 Pricing: A. The pricing included in this Contract shall be firm for the first year. B. The unit prices may be adjusted (decreased or increased) once a year to correspond with the most recent annual change to the Consumer Price Index for All Urban Consumers as published by the U.S. Bureaus of Labor Statistics for the Riverside-San Bernardino-Ontario Areas. C. The City will only pay for the items listed on the bid form, and permit and disposal fees. This does not include access to public utilities. Contractor must incorporate all of its costs in its unit bid prices, including but not limited to labor, supervision, project management, overhead, profit, onboarding training, travel, mileage, truck charges, fuel charges, service call charges, parking, delivery, portal-to-portal charges, environmental fees, shop supplies and consumable incidental materials. The City will not pay for subcontractors, rental of equipment/tools, and purchase of materials/supplies unless the City authorized payment of the applicable items. 1.4 Payment: The resulting contract for these services is an on-call as needed contract. No specific amount of work is guaranteed. The contract value is an estimated value only. All work authorized under the contract will be compensated on a time and material basis as outlined in the Invoicing Section. 1.5 Invoicing: Contractor will submit an itemized invoice monthly. Billings must reference a purchase order number and shall indicate the unit (contract) price. Contractor will be paid for the actual hours worked at the rates shown in the contract. Parts, materials, equipment, and subcontractor costs will be compensated at actual cost with receipts required with allowable markup as outline in the contract. Contractor shall break out the line items on the invoice in accordance with the line items on the bid form. Contractor must provide back-up documentation for materials, subcontractor, rented equipment, permits, disposal and recycling fees. Invoices that are submitted with incorrect prices may be returned for correction before any payments to the contractor are authorized. It shall be the contractor’s responsibility to submit a correct invoice. The City shall not be responsible for payment until a correct invoice is received. The invoice shall be accompanied by receipts, dated, and signed by a City Employee, verifying the work was done. Invoices and receipts will be submitted to the Contract Officer for approval. All invoices are to be sent as one document, per month to: Facilities.Billing@palmspringsca.gov. 1.6 Special Security Requirements: A. Police Department: Any personnel of Contractor assigned to perform services at the Palm Springs Police Department must pass a Criminal History Records Check (CHRC) prior to performing services at this facility. The CHRC(s) will be provided at no charge Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Page 14 of 21 to Contractor. Contractor shall coordinate the record checks with the City’s Contract Officer. The City will accept as evidence of passing such a test a LiveScan card issued by another government agency. B. Palm Springs International Airport: 1. Contractor will be required to complete and maintain authorized signatory training and maintain an authorized signatory on staff. 2. Contractor and affiliates will be required to obtain appropriate S.I.D.A Badges. Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Page 15 of 21 Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Page 16 of 21 Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Page 17 of 21 EXHIBIT “B” INSURANCE PROVISIONS Including Verification of Coverage, Sufficiency of Insurers, Errors and Omissions Coverage, Minimum Scope of Insurance, Deductibles and Self-Insured Retentions, and Severability of Interests (Separation of Insureds) Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Page 18 of 21 INSURANCE 1. Procurement and Maintenance of Insurance. Contractor shall procure and maintain public liability and property damage insurance against all claims for injuries against persons or damages to property resulting from Contractor’s performance under this Agreement. Contractor shall procure and maintain all insurance at its sole cost and expense, in a form and content satisfactory to the City, and submit concurrently with its execution of this Agreement. Contractor shall also carry workers’ compensation insurance in accordance with California workers’ compensation laws. Such insurance shall be kept in full force and effect during the term of this Agreement, including any extensions. Such insurance shall not be cancelable without thirty (30) days advance written notice to City of any proposed cancellation. Certificates of insurance evidencing the foregoing and designating the City, its elected officials, officers, employees, agents, and volunteers as additional named insureds by original endorsement shall be delivered to and approved by City prior to commencement of services. The procuring of such insurance and the delivery of policies, certificates, and endorsements evidencing the same shall not be construed as a limitation of Contractor’s obligation to indemnify City, its elected officials, officers, agents, employees, and volunteers. 2. Minimum Scope of Insurance. The minimum amount of insurance required under this Agreement shall be as follows: 1. Comprehensive general liability and personal injury with limits of at least one million dollars ($1,000,000.00) combined single limit coverage per occurrence and two million dollars ($2,000,000) general aggregate; 2. Automobile liability insurance with limits of at least one million dollars ($1,000,000.00) per occurrence; 3. Professional liability (errors and omissions) insurance with limits of at least one million dollars ($1,000,000.00) per occurrence and two million dollars ($2,000,000) annual aggregate is: _________ required ___x_____ is not required; 4. Workers’ Compensation insurance in the statutory amount as required by the State of California and Employer’s Liability Insurance with limits of at least one million dollars $1 million per occurrence. If Contractor has no employees, Contractor shall complete the City’s Invitation for Waiver of Workers’ Compensation Insurance Requirement form. 3. Primary Insurance. For any claims related to this Agreement, Contractor’s insurance coverage shall be primary with respect to the City and its respective elected officials, officers, employees, agents, and volunteers. Any insurance or self-insurance maintained by City and its respective elected officials, officers, employees, agents, and volunteers shall be in excess of Contractor’s insurance and shall not contribute with it. For Workers’ Compensation and Employer’s Liability Insurance only, the insurer shall waive all rights of subrogation and contribution it may have against City, its elected officials, officers, employees, agents, and volunteers. 4. Errors and Omissions Coverage. If Errors & Omissions Insurance is required, and if Contractor provides claims made professional liability insurance, Contractor shall also agree in writing either (1) to purchase tail insurance in the amount required by this Agreement to cover claims made within three years of the completion of Contractor’s services under this Agreement, or (2) to maintain professional liability insurance coverage with the same carrier in the amount required by this Agreement for at least three years after completion of Contractor’s services under this Agreement. Contractor shall also be required to provide evidence to City of the purchase of the required tail insurance or continuation of the professional liability policy. Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Page 19 of 21 5. Sufficiency of Insurers. Insurance required in this Agreement shall be provided by authorized insurers in good standing with the State of California. Coverage shall be provided by insurers admitted in the State of California with an A.M. Best’s Key Rating of B++, Class VII, or better, unless otherwise acceptable to the City. 6. Verification of Coverage. Contractor shall furnish City with both certificates of insurance and endorsements, including additional insured endorsements, effecting all of the coverages required by this Agreement. The certificates and endorsements are to be signed by a person authorized by that insurer to bind coverage on its behalf. All proof of insurance is to be received and approved by the City before work commences. City reserves the right to require Contractor’s insurers to provide complete, certified copies of all required insurance policies at any time. Additional insured endorsements are not required for Errors and Omissions and Workers’ Compensation policies. Verification of Insurance coverage may be provided by: (1) an approved General and/or Auto Liability Endorsement Form for the City of Palm Springs or (2) an acceptable Certificate of Liability Insurance Coverage with an approved Additional Insured Endorsement with the following endorsements stated on the certificate: A. "The City of Palm Springs, its officials, employees, and agents are named as an additional insured…” ("as respects City of Palm Springs Contract No.___" or "for any and all work performed with the City" may be included in this statement). B. "This insurance is primary and non-contributory over any insurance or self-insurance the City may have..." ("as respects City of Palm Springs Contract No.___" or "for any and all work performed with the City" may be included in this statement). C. "Should any of the above described policies be canceled before the expiration date thereof, the issuing company will mail 30 days written notice to the Certificate Holder named." Language such as, “endeavor to” mail and "but failure to mail such notice shall impose no obligation or liability of any kind upon the company, its agents or representative" is not acceptable and must be crossed out. D. Both the Workers’ Compensation and Employers' Liability policies shall contain the insurer's waiver of subrogation in favor of City, its elected officials, officers, employees, agents, and volunteers. In addition to the endorsements listed above, the City of Palm Springs shall be named the certificate holder on the policies. All certificates of insurance and endorsements are to be received and approved by the City before work commences. All certificates of insurance must be authorized by a person with authority to bind coverage, whether that is the authorized agent/broker or insurance underwriter. Failure to obtain the required documents prior to the commencement of work shall not waive the Contractor’s obligation to provide them. 7. Deductibles and Self-Insured Retentions. Any deductibles or self-insured retentions must be declared to and approved by the City prior to commencing any work or services under Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Page 20 of 21 this Agreement. At the option of the City, either (1) the insurer shall reduce or eliminate such deductibles or self-insured retentions with respect to the City, its elected officials, officers, employees, agents, and volunteers; or (2) Contractor shall procure a bond guaranteeing payment of losses and related investigations, claim administration, and defense expenses. Certificates of Insurance must include evidence of the amount of any deductible or self-insured retention under the policy. Contractor guarantees payment of all deductibles and self-insured retentions. 8. Severability of Interests (Separation of Insureds). This insurance applies separately to each insured against whom claim is made or suit is brought except with respect to the limits of the insurer’s liability. Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Page 21 of 21 EXHIBIT “C” Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 CITY OF PALM SPRINGS 3200 E TAHQUITZ CANYON WAY, PALM SPRINGS, CA 92262 (760) 322-8328 BUSINESS LICENSE CERTIFICATE Fees Paid:$173.00 ISSUANCE OF THIS LICENSE DOES NOT ENTITLE THE LICENSEE TO OPERATE OR MAINTAIN A BUSINESS IN VIOLATION OF ANY OTHER LAW OR ORDINANCE. THIS IS NOT AN ENDORSEMENT OF THE ACTIVITY NOR OF THE APPLICANT'S QUALIFICATIONS. Business Name:UNITED PAINT & COATINGS CO DBA: Owner:UNITED PAINT & COATINGS CO Mailing Address:50485 JALISCO AVE COACHELLA, CA 92236 License Number:CBL-005240-2024 Expiration Date:02/28/2025 PLEASE NOTE THAT IT IS YOUR RESPONSIBILITY TO RENEW AND UPDATE THIS LICENSE ANNUALLY. Business Location:50485 JALISCO AVE, COACHELLA, CA 92236 Business Description:Contractor - General / Painting TO BE POSTED IN A CONSPICUOUS PLACE Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 10/31/2024 Ascend Insurance Agency 36917 Cook St. Ste 101 Palm Desert, CA 92211 License #: 0F44130 Ana Santos (760)341-3477 (760)341-3476 ana@ascendins.com 00007852-0 1 Cristian Gonzalez DBA: United Paint & Coatings Co 50485 Jalisco Ave Coachella, CA 92236-5344 Nautilus Insurance Company 17370 A N Y NN1717062 07/25/2024 07/25/2025X X X 1,000,000 100,000 5,000 1,000,000 2,000,000 2,000,000 California Automobile Insurance Company 38342 B Y Y BA040000075882 09/09/2024 09/09/2025 X 1,000,000 Employers Preferred Ins. Co.10346 C EIG5608524-00 07/11/2024 07/11/2025 Y X 1,000,000 1,000,000 1,000,000 The City of Palm Springs, its officials, employees, and agents are named as an additional insured for any and all work performed with the City. Insurance is Primary and Non-Contributory as per attached endorsements. Waivers of subrogation included as per attached. *30 day notice of cancellation will be given, except for a 10-day notice for non-payment of premiums* City of Palm Springs Palm Springs, CA 92262 (ACS) Printed by ACS on 10/31/2024 at 04:54PM ANY PROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? INSR ADDL SUBR LTR INSD WVD DATE (MM/DD/YYYY) PRODUCER CONTACT NAME: FAXPHONE (A/C, No):(A/C, No, Ext): E-MAIL ADDRESS: INSURER A : INSURED INSURER B : INSURER C : INSURER D : INSURER E : INSURER F : POLICY NUMBER POLICY EFF POLICY EXPTYPE OF INSURANCE LIMITS(MM/DD/YYYY)(MM/DD/YYYY) AUTOMOBILE LIABILITY UMBRELLA LIAB EXCESS LIAB WORKERS COMPENSATION AND EMPLOYERS' LIABILITY DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) AUTHORIZED REPRESENTATIVE EACH OCCURRENCE $ DAMAGE TO RENTED CLAIMS-MADE OCCUR $PREMISES (Ea occurrence) MED EXP (Any one person)$ PERSONAL & ADV INJURY $ GEN'L AGGREGATE LIMIT APPLIES PER:GENERAL AGGREGATE $ PRO-POLICY LOC PRODUCTS - COMP/OP AGG $JECT OTHER:$ COMBINED SINGLE LIMIT $(Ea accident) ANY AUTO BODILY INJURY (Per person)$ OWNED SCHEDULED BODILY INJURY (Per accident)$AUTOS ONLY AUTOS HIRED NON-OWNED PROPERTY DAMAGE $AUTOS ONLY AUTOS ONLY (Per accident) $ OCCUR EACH OCCURRENCE $ CLAIMS-MADE AGGREGATE $ DED RETENTION $$ PER OTH- STATUTE ER E.L. EACH ACCIDENT $ E.L. DISEASE - EA EMPLOYEE $ If yes, describe under E.L. DISEASE - POLICY LIMIT $DESCRIPTION OF OPERATIONS below INSURER(S) AFFORDING COVERAGE NAIC # COMMERCIAL GENERAL LIABILITY Y / N N / A (Mandatory in NH) SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). COVERAGES CERTIFICATE NUMBER:REVISION NUMBER: CERTIFICATE HOLDER CANCELLATION © 1988-2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORDACORD 25 (2016/03) CERTIFICATE OF LIABILITY INSURANCE Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Policy Number: NN1717062 Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Copyright 2017 Mercury Insurance Services, LLC. All rights reserved. MCA85100817-CA Includes copyrighted material of Insurance Services Office, Inc., with its Permission Page 1 of 6 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. Business Auto Broadening Endorsement This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE FORM I. NEWLY ACQUIRED OR FORMED ENTITY (BROAD FORM NAMED INSURED) II. EMPLOYEES AS INSUREDS III. AUTOMATIC ADDITIONAL INSURED IV. EMPLOYEE HIRED AUTO LIABILITY V. SUPPLEMENTARY PAYMENTS VI. FELLOW EMPLOYEE COVERAGE VII. ADDITIONAL TRANSPORTATION EXPENSE VIII. HIRED AUTO PHYSICAL DAMAGE COVERAGE IX. ACCIDENTAL AIRBAG DEPLOYMENT COVERAGE X. LOAN/LEASE GAP COVERAGE XI. GLASS REPAIR – DEDUCTIBLE WAIVER XII. TWO OR MORE DEDUCTIBLES XIII. AMENDED DUTIES IN EVENT OF ACCIDENT, CLAIM, SUIT OR LOSS XIV. WAIVER OF SUBROGATION XV. UNINTENTIONAL ERROR, OMISSION, OR FAILURE TO DISCLOSE HAZARDS XVI. EMPLOYEE HIRED AUTO PHYSICAL DAMAGE XVII. PRIMARY AND NONCONTRIBUTORY IF REQUIRED BY CONTRACT XVIII. HIRED AUTO – COVERAGE TERRITORY XIX. BODILY INJURY REDEFINED TO INCLUDE RESULTANT MENTAL ANGUISH Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Copyright 2017 Mercury Insurance Services, LLC. All rights reserved. MCA85100817-CA Includes copyrighted material of Insurance Services Office, Inc., with its Permission Page 2 of 6 BUSINESS AUTO COVERAGE FORM I. NEWLY ACQUIRED OR FORMED ENTITY (Broad Form Named Insured) SECTION II - LIABILITY COVERAGE, A. Coverage, 1. Who Is An Insured, the following is added: d. Any business entity newly acquired or formed by you during the policy period provided you own 50% or more of the business entity and the business entity is not separately insured for Business Auto Coverage. Coverage is extended up to a maximum of 180 days following acquisition or formation of the business entity. Coverage under this provision is afforded only until the end of the policy period. Coverage does not apply to an “accident” which occurred before you acquired or formed the organization. II. EMPLOYEES AS INSUREDS SECTION II - LIABILITY COVERAGE, A. Coverage, 1. Who Is An Insured, the following is added: e. Any “employee” of yours is an "insured" while using a covered “auto" you don't own, hire or borrow in your business or your personal affairs. III. AUTOMATIC ADDITIONAL INSURED SECTION II - LIABILITY COVERAGE, A. Coverage, 1. Who Is An Insured, the following is added: f. Any person or organization that you are required to include as additional insured on the Coverage Form in a written contract or agreement that is signed and executed by you before the "bodily injury" or "property damage" occurs and that is in effect during the policy period is an "insured" for Liability Coverage, but only for damages to which this insurance applies and only to the extent that person or organization qualifies as an "insured" under the Who Is An Insured provision contained in Section II. IV. EMPLOYEE HIRED AUTO LIABILITY SECTION II - LIABILITY COVERAGE, A. Coverage, 1. Who Is An Insured, the following is added: g. An "employee" of yours is an "insured" while operating an "auto" hired or rented under a contract or agreement in that "employee's" name, with your permission, while performing duties related to the conduct of your business. V. SUPPLEMENTARY PAYMENTS SECTION II – LIABILITY COVERAGE, A. Coverage, 2. Coverage Extensions, a. Supplementary Payments, Subparagraphs (2) and (4) are replaced by the following: (2) Up to $3,000 for cost of bail bonds (including bonds for related traffic law violations) required because of an "accident" we cover. We are not obligated to furnish these bonds. (4) All reasonable expenses incurred by the "insured" at our request, including actual loss of earnings up to $500 a day because of time off from work. Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Copyright 2017 Mercury Insurance Services, LLC. All rights reserved. MCA85100817-CA Includes copyrighted material of Insurance Services Office, Inc., with its Permission Page 3 of 6 VI. FELLOW EMPLOYEE COVERAGE: SECTION II – LIABILITY COVERAGE, B. Exclusions, 5. Fellow Employee This exclusion does not apply if you have workers’ compensation insurance in-force covering all of your “employees”. Coverage is excess over any other collectible insurance. VII. ADDITIONAL TRANSPORTATION EXPENSE SECTION III - PHYSICAL DAMAGE COVERAGE, A. Coverage, 4. Coverage Extensions, a. Transportation Expenses, is replaced with the following: We will pay up to $50 per day to a maximum of $1000 for temporary transportation expense incurred by you because of the total theft of a covered "auto" of the private passenger type. We will pay only for those covered "autos" for which you carry either Comprehensive or Specified Causes of Loss Coverage. We will pay for temporary transportation expenses incurred during the period beginning 48 hours after the theft and ending, regardless of the policy’s expiration, when the covered "auto" is returned to use or we pay for its "loss". If your business shown in the Declarations is other than an auto dealership, we will also pay up to $1,000 for reasonable and necessary costs incurred by you to return a stolen covered auto from the place where it is recovered to its usual garaging location. VIII. HIRED AUTO PHYSICAL DAMAGE COVERAGE SECTION III – PHYSICAL DAMAGE COVERAGE, A. Coverage, 4. Coverage Extensions, the following is added: c. If Liability Coverage is provided in this policy on a Symbol 1 or a Symbol 8 basis and Comprehensive, Specified Causes of Loss, or Collision coverages are provided under this coverage form for any "auto" you own, then the Physical Damage Coverages provided are extended to "autos" you hire, subject to the following limit: (1) The most we will pay for "loss" to any hired "auto" is $50,000 or Actual Cash Value or Cost of Repair, whichever is less (2) $500 deductible will apply to any loss under this coverage extension, except that no deductible shall apply to “loss” caused by fire or lightning Subject to the above limit and deductible we will provide coverage equal to the broadest coverage applicable to any covered "auto" you own of similar size and type. This coverage extension is excess coverage over any other collectible insurance. IX. ACCIDENTAL AIRBAG DEPLOYMENT COVERAGE SECTION III - PHYSICAL DAMAGE COVERAGE, B. Exclusions, 3.a., is amended to add the following: This exclusion does not apply to the accidental discharge of an airbag. Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Copyright 2017 Mercury Insurance Services, LLC. All rights reserved. MCA85100817-CA Includes copyrighted material of Insurance Services Office, Inc., with its Permission Page 4 of 6 X. LOAN/LEASE GAP COVERAGE SECTION III - PHYSICAL DAMAGE COVERAGE C. Limit of Insurance, the following is added: 4. In the event of a "total loss" to a covered "auto" shown in the schedule or declarations for which Collision and Comprehensive Coverage apply, we will pay any unpaid amount due on the lease or loan for that covered “auto,” less: a. The amount paid under the Physical Damage Coverage Section of the policy; and b. Any: (1) Overdue lease/loan payments at the time of the “loss”; (2) Financial penalties imposed under a lease for excessive use, abnormal wear and tear or high mileage. (3) Security deposits not returned by the lessor; (4) Costs for extended warranties, Credit Life Insurance, Health, Accident or Disability Insurance purchased with the loan or lease; and (5) Carry-over balances from previous loans or leases. The most we will pay under Auto Loan/Lease Gap Coverage for an insured auto is 25% of the actual cash value of that insured auto at the time of the loss. XI. GLASS REPAIR – DEDUCTIBLE WAIVER SECTION III - PHYSICAL DAMAGE COVERAGE, D. Deductible, the following is added: No deductible applies to glass damage if the glass is repaired rather than replaced. XII. TWO OR MORE DEDUCTIBLES SECTION III -PHYSICAL DAMAGE COVERAGE, D. Deductible, the following is added: If two or more "company" policies or coverage forms apply to the same accident: 1. If the applicable Business Auto deductible is the smallest, it will be waived; or 2. If the applicable Business Auto deductible is not the smallest, it will be reduced by the amount of the smallest deductible; or 3. If the loss involves two or more Business Auto coverage forms or policies the smallest deductible will be waived. For the purpose of this endorsement "company” means the company providing this insurance and any of the affiliated members of the Mercury Insurance Group of companies. XIII. AMENDED DUTIES IN EVENT OF ACCIDENT, CLAIM, SUIT OR LOSS The requirement in SECTION IV, BUSINESS AUTO CONDITIONS, A. Loss Conditions, 2. Duties In The Event Of Accident, Claim, Suit, Or Loss, a., In the event of "accident", you must notify us of an "accident" applies only when the "accident" is known to: (1) You, if you are an individual; (2) A partner, if you are a partnership; (3) A member, if you are a limited liability company; or (4) An executive officer or insurance manager, if you are a corporation. Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Copyright 2017 Mercury Insurance Services, LLC. All rights reserved. MCA85100817-CA Includes copyrighted material of Insurance Services Office, Inc., with its Permission Page 5 of 6 XIV. WAIVER OF SUBROGATION SECTION IV - BUSINESS AUTO CONDITIONS, A. Loss Conditions, 5. Transfer of Rights Of Recovery Against Others To Us, section is replaced by the following: 5. Transfer Of Rights Of Recovery Against Others To Us We waive any right of recovery we may have against any person or organization to the extent required of you by a written contract executed prior to any "accident" or "loss", provided that the "accident" or "loss" arises out of the operations contemplated by such contract. The waiver applies only to the person or organization designated in such contract. XV. UNINTENTIONAL ERROR, OMISSION, OR FAILURE TO DISCLOSE HAZARDS SECTION IV - BUSINESS AUTO CONDITIONS, B. General Conditions, 2. Concealment, Misrepresentation, or Fraud, the following is added: Any unintentional omission of or error in information given by you, or unintentional failure to disclose all exposures or hazards existing as of the effective date or at any time during the policy period shall not invalidate or adversely affect the coverage for such exposure or hazard or prejudice your rights under this insurance. However, you must report the undisclosed exposure or hazard to us as soon as reasonably possible after its discovery. This provision does not affect our right to collect additional premium or exercise our right of cancellation or non-renewal. XVI. EMPLOYEE HIRED AUTO PHYSICAL DAMAGE SECTION IV – BUSINESS AUTO CONDITIONS, B. General Conditions, 5. Other Insurance, b. For Hired Auto Physical Damage Coverage, is replaced by the following: b. For Hired Auto Physical Damage Coverage, the following are deemed to be covered "autos" you own: 1. Any covered "auto" you lease, hire, rent or borrow; and 2. Any covered "auto" hired or rented by your "employee" under a contract in that individual "employee's" name, with your permission, while performing duties related to the conduct of your business. However, any "auto" that is leased, hired, rented or borrowed with a driver is not a covered "auto". XVII. PRIMARY AND NONCONTRIBUTORY IF REQUIRED BY CONTRACT SECTION IV – BUSINESS AUTO CONDITIONS, B. General Conditions, 5. Other Insurance, the following is added and supersedes any provision to the contrary: e. This insurance is primary to and will not seek contribution from any other insurance available to an additional insured under your policy provided that: (1) The additional insured is a Named Insured under such other insurance; and (2) You have agreed in writing in a contract or agreement that this insurance would be primary and would not seek contribution from any other insurance available to the additional insured. Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037 Copyright 2017 Mercury Insurance Services, LLC. All rights reserved. MCA85100817-CA Includes copyrighted material of Insurance Services Office, Inc., with its Permission Page 6 of 6 XVIII. HIRED AUTO - COVERAGE TERRITORY SECTION IV - BUSINESS AUTO CONDITIONS, B. General Conditions, 7. Policy Period, Coverage Territory, e. Anywhere in the world if:, is replaced by the following: e. Anywhere in the world if: (1) A covered "auto" is leased, hired, rented or borrowed without a driver for a period of 30 days or less; and (2) The "insured’s" responsibility to pay damages is determined in a "suit" on the merits, in the United States of America, the territories and possessions of the United States of America, Puerto Rico, or Canada or in a settlement we agree to. XIX. BODILY INJURY REDEFINED TO INCLUDE RESULTANT MENTAL ANGUISH SECTION V – DEFINITIONS, C. "Bodily Injury” is amended by adding the following: "Bodily injury" also includes mental anguish but only when the mental anguish arises from other bodily injury, sickness, or disease. Docusign Envelope ID: 898958AB-6200-46BC-A060-E25663F2A037