Loading...
The URL can be used to link to this page
Your browser does not support the video tag.
Home
My WebLink
About
A9145 - MOHAWK COMMERCIAL, Inc
CONTRACT ABSTRACT Contract/Amendment Name of Contract: Company Name: Company Contact: Email: Summary of Services: Contract Price: Contract Term: Public Integrity/ Business Disclosure Forms: Contract Administration Lead Department: Contract Administrator/ Ext: Contract Approvals Council/City Manager Approval Date: Agreement Number: Amendment Number: Contract Compliance Exhibits: Insurance: Routed By: Bonds: Business License: Sole Source Co-Op CoOp Agmt #: Sole Source Documents: CoOp Name: CoOp Pricing: By: Submitted on: Contract Abstract Form Rev 8.16.23 Authorized Signers: Name, Email (Corporations require 2 signatures) Systemwide Flooring and Installation Services Mohawk Commercial, Inc. Derek Carnes derek)carnes@mohawkind.com Systemwide Flooring and Installation Services $540,000.00 ( Including A#3 $80,000.00) June 15, 2022 through June 14, 2026 (with 1 yr extention) Mike Gallman; mike_gallman@mohawkind.com Alex Munhoz; alex_munhoz@mohawkind.com Public Works / Facilities David McAbee / Daniel Martinez A9145 3 - - - Department - No 2020002149 Omnia Yes 06/09/2025 Michele Alley Docusign Envelope ID: 337A407F-FAC8-416E-8C95-7C57FBD21523 55575.18100\42913029.1 Page 1 of 3 (BB&K 2024) AMENDMENT NO. 03 TO THE SYSTEMWIDE FLOORING AND INSTALLATION SERVICES A9145 BETWEEN THE CITY PALM SPRINGS AND MOHAWK COMMERCIAL, INC. 1. Parties and Date. This Amendment No. 03 to the Systemwide flooring and installation services (A9145), is made and entered into as of this 9th day of June 2025, by and between the City of Palm Springs, a California charter city and municipal corporation (“City”), and Mohawk Commercial, Inc., a Delaware corporation. City and Contractor, are sometimes individually referred to as “Party” and collectively as “Parties.” 2. Recitals. 2.1 Agreement. On June 15, 2022, the City Manager approved A9145, made and entered into reference to the competitively solicited Omina Partners Contract No. 2020002149 with Contractor (“Cooperative Agreement”). 2.2 Amendment No. 01, Amendment. City and Contractor entered into Amendment No. 01 to the Agreement, dated December 8, 2022, for the purpose of extending the term to continue through June 14, 2025, and amend funds by adding $225,000.00, for a total contract balance not to exceed $300,000.00. 2.3 Amendment No. 02, Amendment. City and Contractor entered into Amendment No. 02 to the Agreement, dated March 18, 2024, for the purpose of extending the term to continue through June 14, 2025, and amend funds by adding $160,000.00 for a total contract balance not to exceed $460,000.00. 2.4 Amendment Purpose. City and Contractor now desire to amend the Agreement to continue services by extending one (1) year and adding $80,000.00 no to exceed the amount of $540,000.00. 2.5 Amendment Authority. This Amendment No. 03 is authorized pursuant to Section 3.3 Changes of the Agreement. 3. Terms. 3.1 Amendment. Section 3.1 Compensation and Payment of the Agreement is hereby amended in its entirety to read as follows: “3.1 Compensation and Payment. Contractor shall be compensated and reimbursed for the services rendered under this Agreement in accordance with the schedule of fees set forth in Exhibit “A”. The total amount of Compensation shall not exceed $540,000.00. 3.2 Amendment. Section 4.4 Term of the Agreement is hereby amended in its entirety to read as follows: Docusign Envelope ID: 337A407F-FAC8-416E-8C95-7C57FBD21523 55575.18100\42913029.1 Page 2 of 3 (BB&K 2024) “4.4 Terms. Unless earlier terminated in accordance with Section 4.5 of this Agreement, the Agreement shall continue in full force and effect, commencing on June 15, 2022, and June 14, 2026, unless extended by mutual written consent of the Parties.” 3.3 Continuing Effect of Agreement. Except as amended by this Amendment No. 03, all other provisions of the Agreement remain in full force and effect and shall govern the actions of the parties under this Amendment No. 03. From and after the date of this Amendment No. 03, whenever the term “Agreement” or “Contract” appears in the Agreement, it shall mean the Agreement as amended by this Amendment No. 03. 3.4 Adequate Consideration. The Parties hereto irrevocably stipulate and agree that they have each received adequate and independent consideration for the performance of the obligations they have undertaken pursuant to this Amendment No. 03. 3.5 Severability. If any portion of this Amendment No. 03 is declared invalid, illegal, or otherwise unenforceable by a court of competent jurisdiction, the remaining provisions shall continue in full force and effect. 3.6 Counterparts. This Amendment No. 03 may be executed in duplicate originals, each of which is deemed to be an original, but when taken together shall constitute but one and the same instrument. [SIGNATURES ON FOLLOWING PAGE] Docusign Envelope ID: 337A407F-FAC8-416E-8C95-7C57FBD21523 55575.18100\42913029.1 Page 3 of 3 (BB&K 2024) SIGNATURE PAGE FOR AMENDMENT NO. 03 TO THE SYSTEMWIDE FLOORING AND INSTALLATION SERVICES (A9145) BETWEEN THE CITY PALM SPRINGS AND MOHAWK COMMERCIAL, INC. IN WITNESS WHEREOF, the Parties have executed this Agreement as of the dates stated below. CONTRACTOR: By: ____________________________ By: ______________________________ Signature Signature (2nd signature required for Corporations) Date: Date: CITY OF PALM SPRINGS: APPROVED BY CITY COUNCIL: Date: _______ Item No. APPROVED AS TO FORM: ATTEST: By: ___________________________ By: _______________________________ City Attorney City Clerk APPROVED: By: _______________________________ Date: City Manager – up to $150,000 Deputy/Assistant City Manager – up to $50,000 Director – up to $25,000 Manager – up to $5,000 Docusign Envelope ID: 337A407F-FAC8-416E-8C95-7C57FBD21523 6/10/2025 6/10/2025 6/10/2025 CONTRACT ABSTRACT Contract/Amendment Name of Contract: Company Name: Company Contact: Email: Summary of Services: Contract Price: Contract Term: Public Integrity/ Business Disclosure Forms: Contract Administration Lead Department: Contract Administrator/ Ext: Contract Approvals Council/City Manager Approval Date: Agreement Number: Amendment Number: Contract Compliance Exhibits: Insurance: Routed By: Bonds: Business License: Sole Source Co-Op CoOp Agmt #: Sole Source Documents: CoOp Name: CoOp Pricing: By: Submitted on: Contract Abstract Form Rev 8.16.23 Authorized Signers: Name, Email (Corporations require 2 signatures) Systemwide Flooring and Installation Services Mohawk Commercial, Inc. Derek Carnes Derek Carnes <derek_carnes@mohawkind.com> Systemwide flooring and installation services $460,000 (including this A#2 for $160,000) June 15, 2022, through June 14, 2025 On file Public Works/Facilities David McAbee/Daniel Martinez 12/5/2022 / 03/14/2024 - Amendment No. 2 A9145 2 Yes Yes Yes Department N/A No 2020002149 Omnia Yes 03/28/2024 Tabitha Richards Docusign Envelope ID: 180AE912-59DB-41DE-BFEC-2895A52A1C33 AMENDMENT NO. 2 TO CONTRACT SERVICES AGREEMENT NO. A9145 SYSTEMWIDE FLOORING AND INSTALLATION SERVICES This Amendment No. 2 to the Contract Services Agreement (A9145), (“Amendment No. 2”), is made and entered into this 18th day of March, 2024, by and between the City of Palm Springs, a California charter city and municipal corporation, hereinafter designated as the City, and Mohawk Commercial, Inc., a Delaware corporation, hereinafter designated as the Contractor. City and Contractor are individually referred to as “Party” and are collectively referred to as the “Parties”. RECITALS A. City has determined that there is a need for a licensed and qualified flooring contractor, for the purchase and installation of flooring. B. Contractor is under a cooperative contract through Omnia Partners Contract 2020002149 to provide systemwide flooring to public entities including the City under the terms of Agreement A9145. C. On June 15, 2022, Parties entered into a Contract Services Agreement (A9145) for systemwide flooring and installation services, for a total contract amount of $75,000. D. On December 5, 2022, City Council approved Amendment No. 1 to extend the term through June 14, 2025, and add $225,000, for a revised contract amount of $300,000. E. City desires to modify the contract amount to add $160,000, for a total revised contract amount not to exceed $460,000. F. Contractor desires to perform said services on the terms and conditions set forth in this Amendment. In consideration of these promises and mutual obligations, covenants, and conditions, the Parties agree as follows: AGREEMENT SECTION 1. The true and correct recitals above are incorporated by this reference herein as the basis for this Third Amendment. Docusign Envelope ID: 180AE912-59DB-41DE-BFEC-2895A52A1C33 SECTION 2. 3.1. Compensation and Payment. is hereby replaced in its entirety as follows: “3.1. Compensation and Payment. Contractor shall be compensated and reimbursed for the services rendered under this Agreement in accordance with the schedule of fees set forth in Exhibit “A”. The total amount of Compensation shall not exceed $460,000. SECTION 3. Full Force and Effect. All terms, conditions, and provisions of the Contract Services Agreement A9145, unless specifically modified herein, shall continue in full force and effect. In the event of any conflict or inconsistency between the provisions of this Amendment No. 2 and any provisions of the Contract Services Agreement A9145, the provisions of this Amendment No. 2 shall in all respects govern and control. SECTION 4. The persons executing this Amendment No. 2 on behalf of the Parties hereto warrant that (I) such party is duly organized and existing, (ii) they are duly authorized to execute and deliver this Amendment No. 2 on behalf of said party, (iii) by so executing this Amendment No. 2, such party is formally bound to the provisions of this Amendment No. 2, and (iv) the entering into this Amendment No. 2 does not violate any provision of any other agreement to which said Party is bound. Except as specifically amended by this Amendment No. 2, all terms and provisions of Agreement No. A9145 remain in full force and effect. [SIGNATURES ON FOLLOWING PAGE] Docusign Envelope ID: 180AE912-59DB-41DE-BFEC-2895A52A1C33 SIGNATURE PAGE TO AMENDMENT NO. 2 (A9145) BY AND BETWEEN THE CITY OF PALM SPRINGS AND MOHAWK COMMERCIAL, INC. IN WITNESS WHEREOF, the Parties have executed this Agreement as of the dates stated below. CONTRACTOR: By:___________________________ By:____________________________________ Signature Signature (2nd signature required for Corporations) Date: Date: CITY OF PALM SPRINGS: APPROVED BY CITY COUNCIL: Date: _______ Item No. APPROVED AS TO FORM: ATTEST: By: ___________________________ By: City Attorney City Clerk APPROVED: By: _______________________________ Date: City Manager – over $50,000 Deputy/Assistant City Manager – up to $50,000 Director – up to $25,000 Manager – up to $5,000 Docusign Envelope ID: 180AE912-59DB-41DE-BFEC-2895A52A1C33 8/6/2024 8/6/2024 March 14, 2024 1.J. 8/6/2024 Submitted on: 12/08/2022 By: Tabitha Richards CONTRACT ABSTRACT 1 Original: Amendment No. 1; COI Contract Company Name: Company Contact: Summary of Services: Contract Total: Funding Source: Contract Term: Mohawk Commercial, Inc. Noelle Minute, Account Executive Systemwide Flooring & Installation Svcs – OMNIA Partners 2020002149 $300,000 (including $225,000 by this Amendment No. 1) 5206570-40105 June 15, 2022, continuing through June 14, 2025 (including two-year extension by this Amendment No. 1) Contract Administration Lead Department: Contract Administrator: Department of Maintenance and Facilities David McAbee/Heather MacPherson Contract Approval City Manager Approval: Amendment No. 1: Agreement Number: June 16, 2021 December 5, 2022, Item 1.D. A9145 Contract Compliance Exhibits: Signatures: Insurance: Bonds: Attached Attached Attached N/A Prepared by: Tabitha Richards DocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 AMENDMENT #1 TO CONTRACT SERVICES AGREEMENT NO. A9145 FOR SYSTEMWIDE FLOORING AND INSTALLATION SERVICES OMNIA PARTNERS CONTRACT 2020002149 This Amendment No. 1 to the Contract Services Agreement (A9145), (“Amendment No. 1”), is made and entered into this _____ day of _____________, 2022, by and between the City of Palm Springs, a California charter city and municipal corporation, hereinafter designated as the City, and Mohawk Commercial, Inc., a Delaware corporation, hereinafter designated as the Contractor. City and Contractor are individually referred to as “Party” and are collectively referred to as the “Parties”. RECITALS A. On June 15, 2022, the City Manager approved A9145, made and entered into in reference to the competitively solicited Omnia Partners Contract No. 2020002149 with Contractor (“Cooperative Agreement”). B. City desire to extend the Term of Contract Services Agreement No. 9145 (A9145) through June 14, 2025, and amend A9145 to add $225,000, for maximum contract amount not to exceed $300,000. C. Contractor desires to perform said services on the terms and conditions set forth in this Amendment. In consideration of these promises and mutual obligations, covenants, and conditions, the Parties agree as follows: AGREEMENT SECTION 1. The true and correct recitals above are incorporated by this reference herein as the basis for this Third Amendment. SECTION 2. 3.1 Compensation and Payment. Is hereby replaced in its entirety as follows: “3.1 Compensation and Payment. Contractor shall be compensated and reimbursed for the services rendered under this Agreement in accordance with the schedule of fees set forth in Exhibit “A”. The total amount of Compensation shall not exceed $300,000.” SECTION 3. 4.4 Term. Is hereby replaced in its entirety as follows: “4.4 Term. Unless earlier terminated in accordance with Section 4.5 of this Agreement, this Agreement shall continue in full force and effect, commencing on June 15, 2022, and DocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 December8th continuing through June 14, 2025, unless extended by mutual written consent of the Parties.” SECTION 4. Full Force and Effect. All terms, conditions, and provisions of the Contract Services Agreement A9145, unless specifically modified herein, shall continue in full force and effect. In the event of any conflict or inconsistency between the provisions of this Amendment No. 1 and any provisions of the Contract Services Agreement A9145, the provisions of this Amendment No. 1 shall in all respects govern and control. SECTION 5. The persons executing this Amendment No. 1 on behalf of the Parties hereto warrant that (I) such party is duly organized and existing, (ii) they are duly authorized to execute and deliver this Amendment No. 1 on behalf of said party, (iii) by so executing this Amendment No. 1, such party is formally bound to the provisions of this Amendment No. 1, and (iv) the entering into this Amendment No. 1 does not violate any provision of any other agreement to which said Party is bound. Except as specifically amended by this Amendment No. 1, all terms and provisions of Agreement No. A9145 remain in full force and effect. [SIGNATURES ON FOLLOWING PAGE] DocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 SIGNATURE PAGE TO AMENDMENT NO. 1 (A9145) BY AND BETWEEN THE CITY OF PALM SPRINGS AND MOHAWK COMMERCIAL, INC. IN WITNESS WHEREOF, the Parties have executed this Agreement as of the dates stated below. CONTRACTOR: By:___________________________ By:____________________________________ Signature Signature (2nd signature required for Corporations) Date: Date: CITY OF PALM SPRINGS: APPROVED BY CITY COUNCIL: Date: December 5, 2022__ Item No. 1.D. APPROVED AS TO FORM: ATTEST: By: ___________________________ By: City Attorney City Clerk APPROVED: By: _______________________________ Date: City Manager – over $50,000 Deputy/Assistant City Manager – up to $50,000 Director – up to $25,000 Manager – up to $5,000 12/7/2022 DocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 12/8/2022 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. INSURER(S) AFFORDING COVERAGE INSURER F : INSURER E : INSURER D : INSURER C : INSURER B : INSURER A : NAIC # NAME:CONTACT (A/C, No):FAX E-MAILADDRESS: PRODUCER (A/C, No, Ext):PHONE INSURED REVISION NUMBER:CERTIFICATE NUMBER:COVERAGES IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. OTHER: (Per accident) (Ea accident) $ $ N / A SUBR WVD ADDL INSD THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. $ $ $ $PROPERTY DAMAGE BODILY INJURY (Per accident) BODILY INJURY (Per person) COMBINED SINGLE LIMIT AUTOS ONLY AUTOSAUTOS ONLY NON-OWNED SCHEDULEDOWNED ANY AUTO AUTOMOBILE LIABILITY Y / N WORKERS COMPENSATION AND EMPLOYERS' LIABILITY OFFICER/MEMBER EXCLUDED? (Mandatory in NH) DESCRIPTION OF OPERATIONS below If yes, describe under ANY PROPRIETOR/PARTNER/EXECUTIVE $ $ $ E.L. DISEASE - POLICY LIMIT E.L. DISEASE - EA EMPLOYEE E.L. EACH ACCIDENT EROTH-STATUTEPER LIMITS(MM/DD/YYYY)POLICY EXP(MM/DD/YYYY)POLICY EFFPOLICY NUMBERTYPE OF INSURANCELTRINSR DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) EXCESS LIAB UMBRELLA LIAB $EACH OCCURRENCE $AGGREGATE $ OCCUR CLAIMS-MADE DED RETENTION $ $PRODUCTS - COMP/OP AGG $GENERAL AGGREGATE $PERSONAL & ADV INJURY $MED EXP (Any one person) $EACH OCCURRENCE DAMAGE TO RENTED $PREMISES (Ea occurrence) COMMERCIAL GENERAL LIABILITY CLAIMS-MADE OCCUR GEN'L AGGREGATE LIMIT APPLIES PER: POLICY PRO-JECT LOC CERTIFICATE OF LIABILITY INSURANCE DATE (MM/DD/YYYY) CANCELLATION AUTHORIZED REPRESENTATIVE ACORD 25 (2016/03) © 1988-2016 ACORD CORPORATION. All rights reserved. CERTIFICATE HOLDER The ACORD name and logo are registered marks of ACORD HIRED AUTOS ONLY D self-insured retention per policy 1,000,000 10/01/2023 EB2-651-004272-042 WA7-65D-004272-012 (MA) ATL-005437856-01 1,000,000 5,000,000 WC7-651004272-022 (WI MN) X 23035 5,000,000 ATLANTA, GA 30326 N X10/01/2022 0 10/01/2023 26247 10/01/2023 AS2-651-004272-032 A terms and conditions. 2,000,000 2,000,000 42404 Liberty Mutual Fire Insurance Company 1,000,000 X X insurance is primary and non-contributory. 09/22/2022 10/01/2022 10/01/2022 RE: Contract No. 2020002149 The City of Palm Springs, its officials, employees, and agents are included as Additional Insured where required by written contract. Waiver of subrogation is applicable where required by written contract and subject X 10/01/2022 3200 E. Tahquitz Canyon Way Palm Springs, CA 92262 City of Palm Springs American Guarantee & Liability Ins Co to policy terms and conditions. Should any of the above described policies be cancelled before the expiration date thereof, 30 day notice of may be delivered to certificate holders in accordance with the policy. This B C Liberty Insurance Corporation CN101225804--GAWU-22-23 evidenced above is subject to a 5,000 10/01/2023 5,000,000 AUC-9139812-16 C 2,000,000 33600 1,000,000 1,000,000 WA5-65D-004272-272 (AOS) TWO ALLIANCE CENTER MARSH USA, INC. X 3560 LENOX ROAD, SUITE 2400 160 S. Industrial Blvd Mohawk Industries, Inc. Calhoun, GA 30701 The Excess General Liability policy X 10/01/2022 Attention: City Manager/ City Clerk X X X 10/01/2022 X X B . X 10/01/2023 10/01/2023 Liberty Mutual Insurance Corp. X DocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 CITY COUNCIL STAFF REPORT DATE: DECEMBER 5, 2022 CONSENT CALENDAR SUBJECT: APPROVE AMENDMENT NO. 1 TO AGREEMENT NO. A9145 WITH MOHAWK COMMERCIAL, INC., FOR SYSTEMWIDE FLOORING AND INSTALLATION SERVICES FROM: Teresa Gallavan, Interim City Manager BY: Department of Maintenance and Facilities SUMMARY: This action will approve Amendment No. 1 to Agreement A9145 with Mohawk Commercial, Inc., in the amount of $225,000 for a revised contract amount not to exceed $300,000 for systemwide flooring and installation services and will extend the agreement term through June 14, 2025. RECOMMENDATION: 1. Approve Amendment No. 1 to Agreement A9145 (Attachment A) with Mohawk Commercial, Inc., to provide systemwide flooring and installation services in an additional amount of $225,000 for a total revised contract amount not to exceed $300,000 and extend the term through June 14, 2025. 2. Authorize the Interim City Manager or designee to execute all necessary documents. BUSINESS PRINCIPAL DISCLOSURE: The Public Integrity Disclosure Form for Mohawk Commercial is included as Attachment B. BACKGROUND: The City required the services of a systemwide flooring and installation contractor for flooring services. By utilizing Palm Springs Municipal Code Section 7.09.010, “Cooperative Purchasing Programs”, the City was allowed to obtain flooring and installation services through Mohawk Commercial, Inc. (Mohawk), under Omnia Partners Contract No. 2020002149. Item 1D - Page 1 DocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 City Council Staff Report December 5, 2022 -- Page 2 Approve Amendment with Mohawk Commercial, Inc. Therefore, the City signed a Contract Services Agreement with Mohawk on June 15, 2022, in an amount not to exceed $75,000, through June 14, 2023, to meet the Facilities and Maintenance Department’s immediate needs. STAFF ANALYSIS: Staff is requesting approval of Amendment No. 1 in the amount of $225,000 for a revised contract amount not to exceed $300,000, and extension of the agreement term through June 14, 2025, for systemwide flooring and installation services. Facilities Maintenance is currently working on three deferred maintenance projects that combined would expend approximately $100,000 during Fiscal Year 2022-23. • Finance Department Carpet Replacement $30,000 • Skate Park Carpet Replacement $20,000 • Animal Shelter Flooring Replacement $50,000 Therefore, increasing the contract to a not-to-exceed amount of $300,00 and increasing the term of the contract through June 14, 2025, will allow for current and future project flooring needs be met. ENVIRONMENTAL ASSESSMENT: The requested City Council action is not a “Project” as defined by the California Environmental Quality Act (CEQA). Pursuant to Section 15378(a), a “Project” means the whole of an action, which has a potential for resulting in either a direct physical change in the environment, or a reasonably foreseeable indirect physical change in the environment. The requested action is to approve contracts for the above-mentioned services, and is exempt from CEQA pursuant to Section 15378(b), in that a “Project” does not include: (5) Organizational or administrative activities of governments that will not result in direct or indirect physical changes in the environment. ALIGNMENT WITH STRATEGIC PLANNING: Approval of this action supports City Council priority 3A, Community Infrastructure – Improve City Facilities. FISCAL IMPACT: Sufficient funds are budgeted and available in the current Fiscal Year 2022-23 Facilities Maintenance Accounts 5206570-40105 and 5206570-50119. Item 1D - Page 2 DocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 City Council Staff Report December 5, 2022 -- Page 3 Approve Amendment with Mohawk Commercial, Inc. REVIEWED BY: Department Director: David McAbee Procurement Manager: Kim Baker Interim City Manager: Teresa Gallavan ATTACHMENTS: A. Amendment No. 1 B. Public Integrity Disclosure Item 1D - Page 3 DocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 ATTACHMENT A Item 1D - Page 4 DocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 AMENDMENT #1 TO CONTRACT SERVICES AGREEMENT NO. A9145 FOR SYSTEMWIDE FLOORING AND INSTALLATION SERVICES OMNIA PARTNERS CONTRACT 2020002149 This Amendment No. 1 to the Contract Services Agreement (A9145), (“Amendment No. 1”), is made and entered into this _____ day of _____________, 2022, by and between the City of Palm Springs, a California charter city and municipal corporation, hereinafter designated as the City, and Mohawk Commercial, Inc., a Delaware corporation, hereinafter designated as the Contractor. City and Contractor are individually referred to as “Party” and are collectively referred to as the “Parties”. RECITALS A. On June 15, 2022, the City Manager approved A9145, made and entered into in reference to the competitively solicited Omnia Partners Contract No. 2020002149 with Contractor (“Cooperative Agreement”). B. City desire to extend the Term of Contract Services Agreement No. 9145 (A9145) through June 14, 2025, and amend A9145 to add $225,000, for maximum contract amount not to exceed $300,000. C. Contractor desires to perform said services on the terms and conditions set forth in this Amendment. In consideration of these promises and mutual obligations, covenants, and conditions, the Parties agree as follows: AGREEMENT SECTION 1. The true and correct recitals above are incorporated by this reference herein as the basis for this Third Amendment. SECTION 2. 3.1 Compensation and Payment. Is hereby replaced in its entirety as follows: “3.1 Compensation and Payment. Contractor shall be compensated and reimbursed for the services rendered under this Agreement in accordance with the schedule of fees set forth in Exhibit “A”. The total amount of Compensation shall not exceed $300,000.” SECTION 3. 4.4 Term. Is hereby replaced in its entirety as follows: “4.4 Term. Unless earlier terminated in accordance with Section 4.5 of this Agreement, this Agreement shall continue in full force and effect, commencing on June 15, 2022, and Item 1D - Page 5 DocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 continuing through June 14, 2025, unless extended by mutual written consent of the Parties.” SECTION 4. Full Force and Effect. All terms, conditions, and provisions of the Contract Services Agreement A9145, unless specifically modified herein, shall continue in full force and effect. In the event of any conflict or inconsistency between the provisions of this Amendment No. 1 and any provisions of the Contract Services Agreement A9145, the provisions of this Amendment No. 1 shall in all respects govern and control. SECTION 5. The persons executing this Amendment No. 1 on behalf of the Parties hereto warrant that (I) such party is duly organized and existing, (ii) they are duly authorized to execute and deliver this Amendment No. 1 on behalf of said party, (iii) by so executing this Amendment No. 1, such party is formally bound to the provisions of this Amendment No. 1, and (iv) the entering into this Amendment No. 1 does not violate any provision of any other agreement to which said Party is bound. Except as specifically amended by this Amendment No. 1, all terms and provisions of Agreement No. A9145 remain in full force and effect. [SIGNATURES ON FOLLOWING PAGE] Item 1D - Page 6 DocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 SIGNATURE PAGE TO AMENDMENT NO. 1 (A9145) BY AND BETWEEN THE CITY OF PALM SPRINGS AND MOHAWK COMMERCIAL, INC. IN WITNESS WHEREOF, the Parties have executed this Agreement as of the dates stated below. CONTRACTOR: By:___________________________ By:____________________________________ Signature Signature (2nd signature required for Corporations) Date: Date: CITY OF PALM SPRINGS: APPROVED BY CITY COUNCIL: Date: _______ Item No. APPROVED AS TO FORM: ATTEST: By: ___________________________ By: City Attorney City Clerk APPROVED: By: _______________________________ Date: City Manager – over $50,000 Deputy/Assistant City Manager – up to $50,000 Director – up to $25,000 Manager – up to $5,000 Item 1D - Page 7 DocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 ATTACHMENT B Item 1D - Page 8 DocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 CITY OF PALM SPRINGS – PUBLIC INTEGRITY DISCLOSURE APPLICANT DISCLOSURE FORM Page 1 of 2 (Revised 09 13 18) PUBLIC INTEGRITY DISCLOSURE APPLICANT DISCLOSURE FORM 1.Name of Entity 2.Address of Entity (Principle Place of Business) 3.Local or California Address (if different than #2) 4.State where Entity is Registered with Secretary of State If other than California, is the Entity also registered in California? Yes No 5.Type of Entity Corporation Limited Liability Company Partnership Trust Other (please specify) 6.Officers, Directors, Members, Managers, Trustees, Other Fiduciaries (please specify) Note: If any response is not a natural person, please identify all officers, directors, members, managers and other fiduciaries for the member, manager, trust or other entity _________________________________________________ Officer Director Member Manager [name] General Partner Limited Partner Other ____________________________________ _________________________________________________ Officer Director Member Manager [name] General Partner Limited Partner Other ____________________________________ _________________________________________________ Officer Director Member Manager [name] General Partner Limited Partner Other ____________________________________ Mohawk Commercial Inc. 160 S. Industrial blvd. Calhoun, GA 30701 X Georgia X Jeffrey S. Lorberbaum X Aladdin Partners, L.P.X Item 1D - Page 9 DocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 CITY OF PALM SPRINGS – PUBLIC INTEGRITY DISCLOSURE APPLICANT DISCLOSURE FORM Page 2 of 2 (Revised 09 13 18) 7. Owners/Investors with a 5% beneficial interest in the Applicant Entity or a related entity EXAMPLE JANE DOE [name of owner/investor] 50%, ABC COMPANY, Inc. [percentage of beneficial interest in entity and name of entity] A. [name of owner/investor] [percentage of beneficial interest in entity and name of entity] B. [name of owner/investor] [percentage of beneficial interest in entity and name of entity] C. [name of owner/investor] [percentage of beneficial interest in entity and name of entity] D. [name of owner/investor] [percentage of beneficial interest in entity and name of entity] E. [name of owner/investor] [percentage of beneficial interest in entity and name of entity] I DECLARE UNDER PENALTY OF PERJURY UNDER THE LAWS OF THE STATE OF CALIFORNIA THAT THE FOREGOING IS TRUE AND CORRECT. Signature of Disclosing Party, Printed Name, Title Date Sergio Blanco, Contract Compliance 11/17/2022 Jeffrey S. Lorberbaum Aladdin Partners, L.P. 16% 13% FMR, LLC 9% The Vanguard Group 9% BlackRock, Inc 7% Item 1D - Page 10 __ L___I DocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 CONTRACT ABSTRACT 2 Originals: Agreement; 1 Original: Performance & Payment Bond and Insurance Contract Company Name: Company Contact: Summary of Services: Contract Price: Funding Source: Contract Term: Mohawk Commercial, Inc. Noelle Minite, Account Executive Systemwide Flooring & Installation Svcs – OMNIA Partners 2020002149 $75,000 Facilities: 5206570-40105 June 15, 2022 through June 30, 2023 Contract Administration Lead Department: Contract Administrator: Facilities Maintenance Daniel Martinez Contract Approvals Council Approval: Resolution Number: Agreement Number: N/A N/A A9145 Contract Compliance Exhibits: Signatures: Insurance: Bonds: Yes Yes Yes N/A Contract Prepared By: Procurement and Contracting Submitted on: June 8, 2022 By: Brian Sotak-Rossman DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 55575.00001\40098778.2 Revised 2.9.22 Page 1 of 17 CONTRACT SERVICES AGREEMENT A9145 SYSTEMWIDE FLOORING AND INSTALLATION SERVICES OMNIA PARTNERS CONTRACT 2020002149 THIS AGREEMENT FOR CONTRACT SERVICES (“Agreement”) is made and entered into on June 15, 2022, by and between the City of Palm Springs, a California charter city and municipal corporation (“City”), and Mohawk Commercial, Inc., a Delaware corporation (“Contractor”). City and Contractor are individually referred to as “Party” and are collectively referred to as the “Parties”. RECITALS A. City requires the services of a licensed and qualified flooring contractor, for the purchase and installation of flooring, (“Project”). B. Contractor is under a cooperative contract through Omnia Partners Contract 2020002149 to provide systemwide flooring to public entities including the City under the terms of this Agreement. C. Based on its experience, education, training, and reputation, Contractor is qualified and desires to provide the necessary services to City for the Project. D. City desires to retain the services of Contractor for the Project. NOW, THEREFORE, in consideration of the promises and mutual obligations, covenants, and conditions contained herein, and other valuable consideration, the receipt and sufficiency of which are hereby acknowledged, the Parties agree as follows: AGREEMENT 1. CONTRACTOR SERVICES 1.1 Scope of Services. In compliance with all terms and conditions of this Agreement, Contractor shall provide services to City as described in the Scope of Services/Work attached to this Agreement as Exhibit “A” and incorporated herein by reference (the “Services” or “Work”). Exhibit "A" includes the agreed upon schedule of fees. Contractor warrants that the Services shall be performed in a competent, , and satisfactory manner consistent with the level of care and skill ordinarily exercised by experienced, flooring installers currently practicing under similar conditions in a similar geographic area. In the event of any inconsistency between the terms contained in the Scope of Services/Work and the terms set forth in this Agreement, the terms set forth in this Agreement shall govern. 1.2 Compliance with Law. Contractor shall comply with all applicable federal, state, and local laws, statutes and ordinances and all lawful orders, rules, and regulations when performing the Services. Contractor shall be liable for all violations of such laws and regulations in connection with the Services and this Agreement. DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 55575.00001\40098778.2 Revised 2.9.22 Page 2 of 17 1.3 Licenses and Permits. Contractor shall obtain at its sole cost and expense such licenses, permits, and approvals as may be required by law for the performance of the Services required by this Agreement. 1.4 Familiarity with Work. By executing this Agreement, Contractor warrants that it has carefully considered how the Work should be performed and fully understands the facilities, difficulties, and restrictions attending performance of the Work under this Agreement. 2. TIME FOR COMPLETION The time for completion of the Services to be performed by Contractor is an essential condition of this Agreement. Contractor shall prosecute regularly and diligently the work of this Agreement. Neither Party shall be accountable for delays in performance caused by any condition beyond the reasonable control and without the fault or negligence of the non- performing Party. Delays shall not entitle Contractor to any additional compensation regardless of the Party responsible for the delay. 3. COMPENSATION OF CONTRACTOR 3.1 Compensation of Contractor. Contractor shall be compensated and reimbursed for the services rendered under this Agreement in accordance with the schedule of fees set forth in Exhibit “A”. The total amount of Compensation shall not exceed $75,000. 3.2 Method of Payment. In any month in which Contractor wishes to receive payment, Contractor shall submit to City an invoice for Services rendered prior to the date of the invoice, no later than the first working day of such month, in the form approved by City’s finance director. Goods ordered shall be invoiced by Contractor when shipped. Payments shall be based on the rates set forth in Exhibit “A”. City shall pay Contractor for all expenses stated in the invoice that are approved by City and consistent with this Agreement, within thirty (30) days of receipt of Contractor’s invoice. 3.3 Changes. In the event any change or changes in the Services is requested by City, Parties shall execute a written amendment to this Agreement, specifying all proposed amendments, including, but not limited to, any additional fees. An amendment may be entered into: A. To provide for revisions or modifications to documents, work product, or Work, when required by the enactment or revision of any subsequent law; or B. To provide for additional services not included in this Agreement or not customarily furnished in accordance with generally accepted practice in Contractor’s profession. 3.4 Appropriations. This Agreement is subject to, and contingent upon, funds being appropriated by the City Council of City for each fiscal year. If such appropriations are not made, this Agreement shall automatically terminate without penalty to City. DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 55575.00001\40098778.2 Revised 2.9.22 Page 3 of 17 4. PERFORMANCE SCHEDULE 4.1 Time of Essence. Time is of the essence in the performance of this Agreement. 4.2 Schedule of Performance. All Services rendered under this Agreement shall be performed under the agreed upon schedule of rates set forth in Exhibit “A.” Any time period extension must be approved in writing by the Contract Officer. 4.3 Force Majeure. The time for performance of Services to be rendered under this Agreement may be extended because of any delays due to a Force Majeure Event if Contractor notifies the Contract Officer within ten (10) days of the commencement of the Force Majeure Event. A Force Majeure Event shall mean an event that materially affects the Contractor’s performance and is one or more of the following: (1) Acts of God or other natural disasters occurring at the project site; (2) terrorism or other acts of a public enemy; (3) orders of governmental authorities (including, without limitation, unreasonable and unforeseeable delay in the issuance of permits or approvals by governmental authorities that are required for the Work); and (4) pandemics, epidemics or quarantine restrictions. For purposes of this section, “orders of governmental authorities,” includes ordinances, emergency proclamations and orders, rules to protect the public health, welfare and safety, and other actions of the City in its capacity as a municipal authority. After Contractor notification, the Contract Officer shall investigate the facts and the extent of any necessary delay and extend the time for performing the Services for the period of the enforced delay when and if, in the Contract Officer’s judgment, such delay is justified. The Contract Officer’s determination shall be final and conclusive upon the Parties to this Agreement. The Contractor will not receive an adjustment to the contract price or any other compensation. Notwithstanding the foregoing, the City may still terminate this Agreement in accordance with the termination provisions of this Agreement. 4.4 Term. Unless earlier terminated in accordance with Section 4.5 of this Agreement, this Agreement shall continue in full force and effect, commencing on June 15, 2022, and ending on the expiration of Omnia Partners Contract 2020002149. 4.5 Termination Prior to Expiration of Term. City may terminate this Agreement at any time, with or without cause, upon thirty (30) days written notice to Contractor. Where termination is due to the fault of Contractor and constitutes an immediate danger to health, safety, and general welfare, the period of notice shall be such shorter time as may be determined by the City. Upon receipt of the notice of termination, Contractor shall immediately cease all Services except such as may be specifically approved by the Contract Officer. Contractor shall be entitled to compensation for all Services rendered prior to receipt of the notice of termination and for any Services authorized by the Contract Officer after such notice. City shall not be liable for any costs other than the charges or portions thereof which are specified herein. Contractor shall not be entitled to payment for unperformed Services and shall not be entitled to damages or compensation for termination of Work. If the termination is for cause, the City shall have the right to take whatever steps it deems necessary to correct Contractor's deficiencies and charge the cost thereof to Contractor, who shall be liable for the full cost of the City's corrective action. Contractor may not terminate this Agreement except for cause, upon thirty (30) days written notice to City. DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 55575.00001\40098778.2 Revised 2.9.22 Page 4 of 17 5. COORDINATION OF WORK 5.1 Representative of Contractor. The following principal of Contractor is designated as being the principal and representative of Contractor authorized to act and make all decisions in its behalf with respect to the specified Services: Noelle Minite (name), Account Executive (title). It is expressly understood that the experience, knowledge, education, capability, and reputation of the foregoing principal is a substantial inducement for City to enter into this Agreement. Therefore, the foregoing principal shall be responsible during the term of this Agreement for directing all activities of Contractor and devoting sufficient time to personally supervise the Services under this Agreement. 5.2 Contract Officer. The Contract Officer shall be the City Manager or his/her designee ("Contract Officer"). Contractor shall be responsible for keeping the Contract Officer fully informed of the progress of the performance of the Services. Contractor shall refer any decisions that must be made by City to the Contract Officer. Unless otherwise specified, any approval of City shall mean the approval of the Contract Officer. 5.3 Prohibition Against Subcontracting or Assignment. The experience, knowledge, education, capability, and reputation of Contractor, its principals, and employees, were a substantial inducement for City to enter into this Agreement. In addition, neither this Agreement nor any interest may be assigned or transferred, voluntarily or by operation of law, without the prior written approval of City, except to an affiliate of Contractor. Subcontracts, if any, shall contain a provision making them subject to all provisions stipulated in this Agreement including without limitation the insurance and indemnification requirements. If Contractor is permitted to subcontract any part of this Agreement by City, Contractor shall be responsible to City for the acts and omissions of its subcontractor(s) in the same manner as it is for persons directly employed. Nothing contained in this Agreement shall create any contractual relationships between any subcontractor and City. 5.4 Independent Contractor. Neither City nor any of its employees shall have any control over the manner, mode, or means by which Contractor, its agents, or employees, perform the Services required, except as otherwise specified. Contractor shall perform all required Services as an independent contractor of City and shall not be an employee of City and shall remain at all times as to City a wholly independent contractor with only such obligations as are consistent with that role; however, City shall have the right to review Contractor’s work product, result, and advice. Contractor shall not at any time or in any manner represent that it or any of its agents or employees are agents or employees of City. Contractor shall pay all wages, salaries, and other amounts due personnel in connection with their performance under this Agreement and as required by law. Contractor shall be responsible for all reports and obligations respecting such personnel, including, but not limited to: social security taxes, income tax withholding, unemployment insurance, and workers’ compensation insurance. Contractor shall not have any authority to bind City in any manner. 5.5 Personnel. Contractor agrees to assign the following individuals to perform the services in this Agreement. Contractor shall not alter the assignment of the following personnel without providing written notice to the Contract Officer. Acting through the City Manager, the DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 55575.00001\40098778.2 Revised 2.9.22 Page 5 of 17 City shall have the unrestricted right to order the removal of any personnel assigned by Contractor by providing written notice to Contractor. Name: Title: Noelle Minite Account Executive 5.6 California Labor Code Requirements. A. Contractor is aware of the requirements of California Labor Code Sections 1720 et seq. and 1770 et seq., which require the payment of prevailing wage rates and the performance of other requirements on certain “public works” and “maintenance” projects (“Prevailing Wage Laws”). If the Services are being performed as part of an applicable “public works” or “maintenance” project, as defined by the Prevailing Wage Laws, and if the total compensation is $15,000 or more for maintenance or $25,000 or more for construction, alteration, demolition, installation, or repair, Contractor agrees to fully comply with such Prevailing Wage Laws. Contractor shall defend, indemnify, and hold the City, its officials, officers, employees, and agents free and harmless from any claims, liabilities, costs, penalties, or interest arising out of any failure or alleged failure to comply with the Prevailing Wage Laws. It shall be mandatory upon the Contractor and all subcontractors to comply with all California Labor Code provisions, which include but are not limited to prevailing wages (Labor Code Sections 1771, 1774 and 1775), employment of apprentices (Labor Code Section 1777.5), certified payroll records (Labor Code Sections 1771.4 and 1776), hours of labor (Labor Code Sections 1813 and 1815) and debarment of contractors and subcontractors (Labor Code Section 1777.1). B. If the Services are being performed as part of an applicable “public works” or “maintenance” project and if the total compensation is $15,000 or more for maintenance or $25,000 or more for construction, alteration, demolition, installation, or repair, then pu rsuant to Labor Code Sections 1725.5 and 1771.1, the Contractor and all subcontractors performing such Services must be registered with the Department of Industrial Relations. Contractor shall maintain registration for the duration of the Project and require the same of any subcontractors, as applicable. This Agreement may also be subject to compliance monitoring and enforcement by the Department of Industrial Relations. It shall be Contractor’s sole responsibility to comply with all applicable registration and labor compliance requirements. 6. INSURANCE Contractor shall procure and maintain, at its sole cost and expense, policies of insurance as set forth in the attached Exhibit "B", incorporated herein by reference. 7. INDEMNIFICATION. 7.1 Indemnification. To the fullest extent permitted by law, Contractor shall defend (at Contractor’s sole cost and expense), indemnify, protect, and hold harmless City, its elected officials, officers, employees, agents, and volunteers (collectively the “Indemnified Parties”), from and against any and all third party liabilities, actions, suits, claims, demands, losses, costs, judgments, arbitration awards, settlements, damages, demands, orders, penalties, and expenses including legal costs and attorney fees (collectively “Claims”), including but not DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 55575.00001\40098778.2 Revised 2.9.22 Page 6 of 17 limited to Claims arising from injuries to or death of persons (Contractor’s employees included), for damage to property, including property owned by City, for any violation of any federal, state, or local law or ordinance or in any manner arising out of, pertaining to, or incident to any acts, errors or omissions, or willful misconduct committed by Contractor, its officers, employees, representatives, and agents, that arise out of or relate to Contractor’s performance of Services or this Agreement. This indemnification clause excludes Claims arising from the sole negligence or willful misconduct of the Indemnified Parties. Under no circumstances shall the insurance requirements and limits set forth in this Agreement be construed to limit Contractor’s indemnification obligation or other liability under this Agreement. Contractor’s indemnification obligation shall survive the expiration or earlier termination of this Agreement until all actions against the Indemnified Parties for such matters indemnified are fully and finally barred by the applicable statute of limitations or, if an action is timely filed, until such action is final. 7.2 Design Professional Services Indemnification and Reimbursement. If Contractor’s obligation to defend, indemnify, and/or hold harmless arises out of Contractor’s performance as a “design professional” (as that term is defined under Civil Code section 2782.8), then, and only to the extent required by Civil Code section 2782.8, which is fully incorporated herein, Contractor’s indemnification obligation shall be limited to the extent which the Claims arise out of, pertain to, or relate to the negligence, recklessness, or willful misconduct of the Contractor in the performance of the Services or this Agreement, and, upon Contractor obtaining a final adjudication by a court of competent jurisdiction, Contractor’s liability for such claim, including the cost to defend, shall not exceed the Contractor’s proportionate percentage of fault. 8. RECORDS AND REPORTS 8.1 Reports. Contractor shall periodically prepare and submit to the Contract Officer reports concerning the performance of the Services required by this Agreement, or as the Contract Officer shall require. 8.2 Records. Contractor shall keep complete, accurate, and detailed accounts of all time, costs, expenses, and expenditures pertaining in any way to this Agreement. Contractor shall keep such books and records as shall be necessary to properly perform the Services required by this Agreement and enable the Contract Officer to evaluate the performance of such Services. The Contract Officer shall have full and free access to such books and records at all reasonable times, including the right to inspect, copy, audit on not more than an annual basis, and make records and transcripts from such records. 8.3 Ownership of Documents. All drawings, specifications, reports, records, documents, and other materials prepared by Contractor in the performance of this Agreement shall be the property of Contractor. City shall have an unrestricted right to use the concepts embodied in such documents. 8.4 Release of Documents. All drawings, specifications, reports, records, documents, and other materials prepared by Contractor in the performance of Services under this Agreement shall not be released publicly without the prior written approval of the Contract Officer. DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 55575.00001\40098778.2 Revised 2.9.22 Page 7 of 17 8.5 Audit and Inspection of Records. After receipt of reasonable notice and during the regular business hours of City, Contractor shall provide City, or other agents of City, such access to Contractor’s books, records, payroll documents, and facilities as City deems necessary to examine, copy, audit, and inspect all accounting books, records, work data, documents, and activities directly related to Contractor’s performance under this Agreement on no more than an annual basis. Contractor shall maintain such books, records, data, and documents in accordance with generally accepted accounting principles and shall clearly identify and make such items readily accessible to such parties during the term of this Agreement and for a period of three (3) years from the date of final payment by City hereunder. 9. ENFORCEMENT OF AGREEMENT 9.1 California Law. This Agreement shall be construed and interpreted both as to validity and to performance of the parties in accordance with the laws of the State of California. Legal actions concerning any dispute, claim, or matter arising out of or in relation to this Agreement shall be instituted in the Superior Court of the County of Riverside, State of California, or any other appropriate court in such county, and Contractor covenants and agrees to submit to the personal jurisdiction of such court in the event of such action. 9.2 Interpretation. This Agreement shall be construed as a whole according to its fair language and common meaning to achieve the objectives and purposes of the Parties. The terms of this Agreement are contractual and the result of negotiation between the Parties. Accordingly, any rule of construction of contracts (including, without limitation, California Civil Code Section 1654) that ambiguities are to be construed against the drafting party, shall not be employed in the interpretation of this Agreement. The caption headings of the various sections and paragraphs of this Agreement are for convenience and identification purposes only and shall not be deemed to limit, expand, or define the contents of the respective sections or paragraphs. 9.3 Waiver. No delay or omission in the exercise of any right or remedy of a non- defaulting Party on any default shall impair such right or remedy or be construed as a waiver. No consent or approval of City shall be deemed to waive or render unnecessary City’s consent to or approval of any subsequent act of Contractor. Any waiver by either Party of any default must be in writing. No such waiver shall be a waiver of any other default concerning the same or any other provision of this Agreement. 9.4 Rights and Remedies are Cumulative. Except with respect to rights and remedies expressly declared to be exclusive in this Agreement, the rights and remedies of the parties are cumulative. The exercise by either Party of one or more of such rights or remedies shall not preclude the exercise by it, at the same or different times, of any other rights or remedies for the same default or any other default by the other Party. 9.5 Legal Action. In addition to any other rights or remedies, either Party may take legal action, in law or in equity, to cure, correct, or remedy any default, to recover damages for any default, to compel specific performance of this Agreement, to obtain injunctive relief, a declaratory judgment, or any other remedy consistent with the purposes of this Agreement. DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 55575.00001\40098778.2 Revised 2.9.22 Page 8 of 17 9.6 Attorney Fees. In the event any dispute between the Parties with respect to this Agreement results in litigation or any non-judicial proceeding, the prevailing Party shall be entitled, in addition to such other relief as may be granted, to recover from the non-prevailing Party all reasonable costs and expenses. These include but are not limited to reasonable attorney fees, expert contractor fees, court costs and all fees, costs, and expenses incurred in any appeal or in collection of any judgment entered in such proceeding. 10. CITY OFFICERS AND EMPLOYEES: NON-DISCRIMINATION 10.1 Non-Liability of City Officers and Employees. No officer or employee of City shall be personally liable to the Contractor, or any successor-in-interest, in the event of any default or breach by City or for any amount which may become due to the Contractor or its successor, or for breach of any obligation of the terms of this Agreement. 10.2 Conflict of Interest. Contractor acknowledges that no officer or employee of the City has or shall have any direct or indirect financial interest in this Agreement, nor shall Contractor enter into any agreement of any kind with any such officer or employee during the term of this Agreement and for one (1) year thereafter. Contractor warrants that Contractor has not paid or given, and will not pay or give, any third party any money or other consideration in exchange for obtaining this Agreement. 10.3 Covenant Against Discrimination. In connection with its performance under this Agreement, Contractor shall not discriminate against any employee or applicant for employment because of actual or perceived race, religion, color, sex, age, marital status, ancestry, national origin (i.e., place of origin, immigration status, cultural or linguistic characteristics, or ethnicity), sexual orientation, gender identity, gender expression, physical or mental disability, or medical condition (each a “prohibited basis”). Contractor shall ensure that applicants are employed, and that employees are treated during their employment, without regard to any prohibited basis. As a condition precedent to City’s lawful capacity to enter this Agreement, and in executing this Agreement, Contractor certifies that its actions and omissions hereunder shall not incorporate any discrimination arising from or related to any prohibited basis in any Contractor activity, including but not limited to the following: employment, upgrading, demotion or transfer; recruitment or recruitment advertising; layoff or termination; rates of pay or other forms of compensation; and selection for training, including apprenticeship; and further, that Contractor is in full compliance with the provisions of Palm Springs Municipal Code Section 7.09.040, including without limitation the provision of benefits, relating to non- discrimination in city contracting. 11. MISCELLANEOUS PROVISIONS 11.1 Notice. Any notice, demand, request, consent, approval, or communication that either Party desires, or is required to give to the other Party or any other person shall be in writing and either served personally or sent by pre-paid, first-class mail or overnight delivery service to the address set forth below. Notice shall be deemed communicated seventy-two (72) hours from the time of mailing if mailed as provided in this Section. Either Party may change its address by notifying the other Party of the change of address in writing. DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 55575.00001\40098778.2 Revised 2.9.22 Page 9 of 17 To City: City of Palm Springs Attention: City Manager/ City Clerk 3200 E. Tahquitz Canyon Way Palm Springs, California 92262 To Contractor: Mohawk Commercial, Inc. 160 S. Industrial Blvd. Calhoun, GA 30701 Attn: General Counsel With a copy to: Contract and Compliance Attention: Noelle Minite 11.2 Integrated Agreement. This Agreement constitutes the entire understanding between the Parties and supersedes and cancels all prior negotiations, arrangements, agreements, representations, and understandings, if any, made by or among the Parties with respect to the subject matter in this Agreement. 11.3 Amendment. No amendments or other modifications of this Agreement shall be binding unless through written agreement signed by all Parties. 11.4 Severability. Whenever possible, each provision of this Agreement shall be interpreted in such a manner as to be effective and valid under applicable law. In the event that any one or more of the phrases, sentences, clauses, paragraphs, or sections contained in this Agreement shall be declared invalid or unenforceable by valid judgment or decree of a court of competent jurisdiction, such invalidity or unenforceability shall not affect any of the remaining phrases, sentences, clauses, paragraphs, or sections of this Agreement, which shall be interpreted to carry out the intent of the Parties. 11.5 Successors in Interest. This Agreement shall be binding upon and inure to the benefit of the Parties’ successors and assignees. 11.6 Third Party Beneficiary. Except as may be expressly provided for in this Agreement, nothing contained in this Agreement is intended to confer, nor shall this Agreement be construed as conferring, any rights, including, without limitation, any rights as a third-party beneficiary or otherwise, upon any entity or person not a party to this Agreement. 11.7 Recitals. The above-referenced Recitals are hereby incorporated into the Agreement as though fully set forth in this Agreement and each Party acknowledges and agrees that such Party is bound, for purposes of this Agreement, by the same. 11.8 Authority. The persons executing this Agreement on behalf of the Parties warrant that they are duly authorized to execute this Agreement on behalf of Parties and that by so executing this Agreement the Parties are formally bound to the provisions of this Agreement. 11.9 Counterparts. This Agreement may be signed in counterparts, each of which shall constitute an original. DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 55575.00001\40098778.2 Revised 2.9.22 Page 10 of 17 [SIGNATURES ON NEXT PAGE] DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 55575.00001\40098778.2 Revised 2.9.22 Page 11 of 17 SIGNATURE PAGE TO AGREEMENT BY AND BETWEEN THE CITY OF PALM SPRINGS AND MOHAWK COMMERCIAL, INC. IN WITNESS WHEREOF, the Parties have executed this Agreement as of the dates stated below. CONTRACTOR: By: _______________________________________ By: _________________________________________ Signature Signature (2nd signature required for Corporations) Date: Date: CITY OF PALM SPRINGS: APPROVED BY CITY COUNCIL: Date: N/A Item No. N/A APPROVED AS TO FORM: ATTEST: By: ___________________________ By: _______________________________ Jeffrey S. Ballinger, Monique Lomeli, City Attorney City Clerk APPROVED: By: _______________________________ Date: City Manager – over $50,000 Deputy/Assistant City Manager – up to $50,000 Director – up to $25,000 Manager – up to $5,000 DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17C 6/16/2022 6/16/2022 6/16/2022 DocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 55575.00001\40098778.2 Revised 2.9.22 Page 12 of 17 EXHIBIT “A” CONTRACTOR’S SCOPE OF SERVICES/WORK Including, Schedule of Fees And Schedule of Performance DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 55575.00001\40098778.2 Revised 2.9.22 Page 13 of 17 The scope of the services will be as outlined in the Omnia Partners Contract 2020002149. Services include systemwide flooring and installation services. Prices are a not-to-exceed as outlined on the following pages for the current year. DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 Contract: Omnia Partners Freight Terms: FOB Destination Prepaid & AddContract Expiration: 4/14/2025Product PlatformStyle NameStyle #BackingSizeUOMCollectionFiber BrandDye MethodUC Approved Materials of ConcernPROP 65 EPDList Price 2022 Price BroadloomA Different AngleKC234Woven (W)12' WideSYModern DobbyDuracolor® Tricor Premium NylonSolution DyedYesNONENOYES79.76$ 76.11$ BroadloomAccompany / QSBC534Weldlok12' WideSY DomicileColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES48.97$ 40.41$ BroadloomAgnomen / QSBC552Weldlok12' WideSY DomicileColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES48.97$ 40.41$ BroadloomAlexian / QSBC540Weldlok12' WideSY DomicileColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES48.97$ 40.41$ BroadloomAllegoristBC512Weldlok12' WideSY Yarn Spinner/Mohawk Today- 50 SY ColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES53.05$ 50.62$ BroadloomAlnwick Castle SLC50Weldlok12' WideSY ResidenceEverstrand® SDSolution DyedYesAlumina Trihydrate (FR) NONO10.78$ 10.28$ BroadloomAmend Art / QSBC531Weldlok12' WideSY Social OrderColorstrandSolution DyedUC ApprovedAlumina Trihydrate (FR) NOYES27.76$ 24.79$ BroadloomAncillary / QSBC532Weldlok12' WideSY DomicileColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES48.97$ 40.41$ BroadloomAnecdotistBC514Weldlok12' WideSY Yarn Spinner/Mohawk Today- 50 SY ColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES53.05$ 50.62$ BroadloomAntipole / QSBC545Weldlok12' WideSY DomicileColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES48.97$ 40.41$ BroadloomApplied ArtKC217Woven (W)12' WideSY Industrial DesignDuracolor® Tricor Premium NylonSolution DyedYesNONENOYES55.62$ 53.08$ BroadloomApplied ScienceKC218Woven (W)12' WideSY Industrial DesignColorstrandSolution DyedYesNONENOYES62.97$ 60.09$ BroadloomArtist II / QSBC380Weldlok12' WideSY Pure Genius IIColorstrandSolution Dyed/Yarn DyedAlumina Trihydrate (FR) NOYES16.99$ 16.21$ BroadloomAuteurBC513Weldlok12' WideSY Yarn Spinner/Mohawk Today- 50 SY ColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES53.05$ 50.62$ BroadloomBalance Refresh / QSBC549Weldlok12' WideSY DomicileColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES48.97$ 40.41$ BroadloomBalanced WeaveKC275Woven (W)12' WideSY SunweaveDuracolor® Tricor Premium NylonSolution DyedYesNONENOYES66.12$ 63.10$ BroadloomBase Camp / QSBC332Weldlok12' WideSY ExplorationsColorstrandSolution DyedUC ApprovedAlumina Trihydrate (FR) NOYES16.47$ 15.72$ BroadloomBroken Checks / QSBC403Unibond Plus12' WideSY IntertwinedColorstrandSolution DyedUC ApprovedAlumina Trihydrate (FR) NOYES30.04$ 29.33$ BroadloomCelestial Being / QSBC541Weldlok12' WideSY DomicileColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES48.97$ 40.41$ BroadloomCEO II / QSBC382Weldlok12' WideSY Pure Genius IIColorstrandSolution Dyed/Yarn DyedAlumina Trihydrate (FR) NOYES16.05$ 15.31$ BroadloomClearly ClassicKC221Woven (W)12' WideSY Simply TailoredColorstrandSolution DyedYesNONENOYES70.31$ 67.10$ BroadloomColor Study 30 / QSBC574Weldlok12' WideSY Color StudyColorstrandPiece DyedAlumina Trihydrate (FR) NOYES21.40$ 20.43$ BroadloomColor Study 36BC575Weldlok12' WideSY Color StudyColorstrandPiece DyedAlumina Trihydrate (FR) NOYES26.76$ 25.54$ BroadloomColor Study 42BC576Weldlok12' WideSY Color StudyColorstrandPiece DyedAlumina Trihydrate (FR) NOYES34.68$ 33.09$ BroadloomComeback / QSBC546Weldlok12' WideSY DomicileColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES48.97$ 40.41$ BroadloomConnetic / QS/ Max ServiceBC426Unibond Plus12' WideSY ConneticColorstrandSolution DyedUC ApprovedAlumina Trihydrate (FR) NOYES16.18$ 15.43$ BroadloomConsul / QSBC539Weldlok12' WideSY DomicileColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES48.97$ 40.41$ BroadloomContra / QSBC555Weldlok12' WideSY DomicileColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES48.97$ 40.41$ BroadloomConvenioBC506Weldlok12' WideSY Yarn Spinner/Mohawk Today- 50 SY ColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES53.05$ 50.62$ BroadloomConveyor / QSBC538Weldlok12' WideSY DomicileColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES48.97$ 40.41$ BroadloomCountless VariationsBC570Weldlok12' WideSYOpen Narrative/Mohawk Today- 50 SYColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES53.05$ 50.62$ Broadloom Country Mile / QS BC550 Weldlok 12' WideSY Domicile Colorstrand Precision Dyed InjectionAlumina Trihydrate (FR) NOYES48.97$ 40.41$ BroadloomCrestmont AveSLC39Weldlok12' WideSY100% Mohawk EverStrand BCF P.E.T.Piece DyedAlumina Trihydrate (FR) NONO23.33$ 20.19$ BroadloomCroft ManorSLC51Weldlok12' WideSY ResidenceEverstrand® SDSolution DyedYesAlumina Trihydrate (FR) NONO17.08$ 16.31$ BroadloomCross Knit / QSBC375Unibond Plus12' WideSY Fiber ArtColorstrandSolution DyedUC ApprovedAlumina Trihydrate (FR) NOYES18.52$ 17.67$ BroadloomDenouementBC564Weldlok12' WideSY Open Narrative/Mohawk Today- 50 SY ColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES53.05$ 50.62$ BroadloomDoctor II / QS / Max ServiceBC381Weldlok12' WideSY Pure Genius IIColorstrandSolution Dyed/Yarn DyedAlumina Trihydrate (FR) NOYES14.92$ 14.24$ BroadloomDrifting Current BC578Weldlok12' WideSY Urban Shores ColorstrandSolution DyedYesAlumina Trihydrate (FR) NOYES46.78$ 44.64$ BroadloomDriven / QS / Max ServiceBC427Unibond Plus12' WideSY Mass InfluenceColorstrandSolution Dyed/Yarn DyedAlumina Trihydrate (FR) NOYES16.18$ 15.43$ BroadloomElocutionistBC509Weldlok12' WideSY Yarn Spinner/Mohawk Today- 50 SY ColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES53.05$ 50.62$ BroadloomEmpyrean / QSBC544Weldlok12' WideSY DomicileColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES48.97$ 40.41$ BroadloomEnd Result / QSBC288Weldlok12' WideSY Of The MomentColorstrandSolution DyedUC ApprovedAlumina Trihydrate (FR) NOYES13.78$ 13.15$ BroadloomEssential Elements / QS / Max ServiceBC441Weldlok12' WideSY RemasteredColorstrandSolution DyedUC ApprovedAlumina Trihydrate (FR) NOYES14.92$ 14.24$ BroadloomExistenceKC229Unibond Plus12' WideSY Telling SpacesColorstrandSolution DyedUC ApprovedAlumina Trihydrate (FR) NOYES38.76$ 36.99$ BroadloomFaculty RemixGL154Unibond Plus12' WideSY Faculty RemixDuracolorSolution Dyed/Yarn DyedAlumina Trihydrate (FR) NOYES35.08$ 32.16$ BroadloomFiction Film BC565Weldlok12' WideSY Open Narrative/Mohawk Today- 50 SY ColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES53.05$ 50.62$ BroadloomFloating FormsBC579Weldlok12' WideSY Urban Shores ColorstrandSolution DyedYesAlumina Trihydrate (FR) NOYES46.78$ 44.64$ BroadloomFlow of LifeBC567Weldlok12' WideSY Open Narrative/Mohawk Today- 50 SY ColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES53.05$ 50.62$ BroadloomFragmented Narrative BC566Weldlok12' WideSY Open Narrative/Mohawk Today- 50 SY ColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES53.05$ 50.62$ BroadloomGathered Style / QSBC404Unibond Plus12' WideSY IntertwinedColorstrandSolution DyedUC ApprovedAlumina Trihydrate (FR) NOYES30.04$ 29.33$ BroadloomGet Started / QS / Max ServiceBC406Weldlok12' WideSY Get StartedPETSolution DyedUC ApprovedAlumina Trihydrate (FR) NONO12.04$ 11.33$ BroadloomGlobal AttractionKC222Woven (W)12' WideSYColorstrandSolution Dyed / Yarn DyedNONENOYES75.56$ 72.11$ BroadloomGood WillBC528Weldlok12' WideSY Social OrderColorstrandSolution DyedUC ApprovedAlumina Trihydrate (FR) NOYES27.76$ 24.79$ BroadloomGoonj Revival / QS 4 weekMH361Weldlok12' WideSY Definity (rolls/cuts/rugs)ColorstrandSolution DyedUC ApprovedAlumina Trihydrate (FR) NOYES88.18$ 71.92$ BroadloomGraphic Touch / QS / Max ServiceBC452Weldlok12' WideSY High ConceptsPETSolution DyedUC ApprovedAlumina Trihydrate (FR) NONO12.04$ 11.49$ BroadloomHeterdigeticBC561Weldlok12' WideSY Open Narrative/Mohawk Today- 50 SY ColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES53.05$ 50.62$ BroadloomHue-OlogyBC573Weldlok12' WideSY HueologyColorstrandPiece DyedAlumina Trihydrate (FR) NOYES27.34$ 26.09$ BroadloomHumbleKC227Unibond Plus12' WideSY Telling SpacesColorstrandSolution DyedUC ApprovedAlumina Trihydrate (FR) NOYES41.92$ 40.00$ BroadloomInnate Spirit (Temp Stock Definity)BC581Weldlok12' WideSY Celebrating Heritage ColorstrandSolution DyedYesAlumina Trihydrate (FR) NOYES88.18$ 84.15$ BroadloomInterplay / QSGL415Unibond Plus12' WideSY Learn & LiveDuracolor TricorSolution DyedUC ApprovedAlumina Trihydrate (FR) NOYES27.34$ 22.70$ BroadloomInterplay Stripe / QSGL416Unibond Plus12' WideSY Learn & LiveDuracolor TricorSolution DyedUC ApprovedAlumina Trihydrate (FR) NOYES27.34$ 22.70$ BroadloomIvy HallSLC46Weldlok12' WideSY100% Mohawk EverStrand BCF P.E.T.PredyedAlumina Trihydrate (FR) NONO10.49$ 9.17$ BroadloomJocund / QSBC529Weldlok12' WideSY Social OrderColorstrandSolution DyedUC ApprovedAlumina Trihydrate (FR) NOYES27.76$ 24.79$ BroadloomLakir Revival / QS 4 weekMH362Weldlok12' WideSY Definity (rolls/cuts/rugs)ColorstrandSolution DyedUC ApprovedAlumina Trihydrate (FR) NOYES88.18$ 71.92$ BroadloomLaurel PathSLC34Weldlok12' WideSYColorstrand® SD NylonSolution DyedUC ApprovedAlumina Trihydrate (FR) NOYES26.96$ 24.79$ BroadloomLinear FictionBC571Weldlok12' WideSY Open Narrative/Mohawk Today- 50 SY ColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES53.05$ 50.62$ BroadloomListenerBC511Weldlok12' WideSY Yarn Spinner/Mohawk Today- 50 SY ColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES53.05$ 50.62$ BroadloomLiving QuartersSLC26Weldlok12' WideSY75% SmartStrand® Ultra™ BCF Triexta / 25% BCF P.E.T. Piece DyedAlumina Trihydrate (FR) NOYES16.15$ 15.60$ BroadloomLyrical DocumentaryBC559Weldlok12' WideSY Open Narrative/Mohawk Today- 50 SY ColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES53.05$ 50.62$ BroadloomMatte FinishGL421Unibond Plus12' WideSY Texural EffectsDuracolor TricorSolution DyedUC ApprovedAlumina Trihydrate (FR) NOYES31.63$ 29.22$ BroadloomMill AvenueSLC41Weldlok12' WideSY100% SmartStrand® Ultra™ BCF TriextaPiece DyedAlumina Trihydrate (FR) NOYES14.46$ 12.42$ BroadloomMindful - 20 (15 ft)BC411Weldlok12' WideSY MindfulPETSolution DyedUC ApprovedAlumina Trihydrate (FR) NONO10.78$ 9.17$ BroadloomMindful - 20 / QSBC395Weldlok12' WideSY MindfulPETSolution DyedYesAlumina Trihydrate (FR) NONO8.98$ 8.57$ BroadloomMindful - 26 (15 ft)BC412Weldlok12' WideSY MindfulPETSolution DyedUC ApprovedAlumina Trihydrate (FR) NONO13.12$ 11.00$ BroadloomMindful - 26 / QS / Max ServiceBC396Weldlok12' WideSY MindfulPETSolution DyedYesAlumina Trihydrate (FR) NONO12.04$ 11.49$ BroadloomMindful - Base / QSBC397Weldlok12' WideSY MindfulPETSolution DyedYesAlumina Trihydrate (FR) NONO8.26$ 7.88$ BroadloomMirada Stitchlock / QSGL417Unibond Plus12' WideSY Learn & LiveDuracolor TricorSolution DyedUC ApprovedAlumina Trihydrate (FR) NOYES26.80$ 22.70$ BroadloomMoss ModerneGL420Unibond Plus12' WideSY Texural EffectsDuracolor TricorSolution DyedUC ApprovedAlumina Trihydrate (FR) NOYES31.63$ 30.27$ BroadloomMust Have / QS / Max ServiceBC287Weldlok12' WideSY Of The MomentColorstrandSolution DyedUC ApprovedAlumina Trihydrate (FR) NOYES14.92$ 14.24$ BroadloomNew Basics III 20 / QS / Max ServiceBC398Weldlok12' WideSY New BasicsColorstrandSolution DyedUC ApprovedAlumina Trihydrate (FR) NOYES14.92$ 14.17$ BroadloomNew Basics III 26 / QS / Max ServiceBC399Unibond Plus12' WideSY New BasicsColorstrandSolution DyedUC ApprovedAlumina Trihydrate (FR) NOYES16.18$ 16.07$ BroadloomNew Leaf / QSBC554Weldlok12' WideSY DomicileColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES48.97$ 40.42$ BroadloomOblique / QSBC536Weldlok12' WideSY DomicileColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES48.97$ 40.42$ BroadloomObservationalBC563Weldlok12' WideSY Open Narrative/Mohawk Today- 50 SY ColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES53.05$ 50.62$ BroadloomOutrider / QSBC543Weldlok12' WideSY DomicileColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES48.97$ 40.41$ BroadloomOverarchingBC569Weldlok12' WideSY Open Narrative/Mohawk Today- 50 SY ColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES53.05$ 50.62$ BroadloomPatterned PastKC276Woven (W)12' WideSY Pattern & SymmetryDuracolor® Tricor Premium NylonSolution DyedUC Approved NONE NOYES67.18$ 55.12$ BroadloomPocket SquareKC225Woven (W)12' WideSY Simply TailoredDuracolor® Tricor Premium NylonSolution DyedUC Approved NONE NOYES70.54$ 53.30$ BroadloomProforBC515Weldlok12' WideSY Yarn Spinner/Mohawk Today- 50 SY ColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES53.05$ 50.62$ BroadloomProtagonistBC510Weldlok12' WideSY Yarn Spinner/Mohawk Today- 50 SY ColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES53.05$ 50.62$ BroadloomPurview / QSBC553Weldlok12' WideSY DomicileColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES48.97$ 40.41$ BroadloomQuarterageSLC32Weldlok12' WideSY100% SmartStrand® Ultra™ BCF TriextaPiece DyedAlumina Trihydrate (FR) NOYES26.46$ 25.24$ BroadloomReal TimeBC568Weldlok12' WideSY Open Narrative/Mohawk Today- 50 SY ColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES53.05$ 50.62$ BroadloomRecover Act / QSBC547Weldlok12' WideSY DomicileColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES48.97$ 40.41$ BroadloomResistance / QS / Max ServiceBC428Unibond Plus12' WideSY Mass InfluenceColorstrandSolution Dyed/Yarn DyedAlumina Trihydrate (FR) NOYES16.18$ 15.43$ BroadloomRhetorcianBC507Weldlok12' WideSY Yarn Spinner/Mohawk Today- 50 SY ColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES53.05$ 50.62$ BroadloomRoundabout / QSBC556Weldlok12' WideSY DomicileColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES48.97$ 40.41$ BroadloomRustic PladKC277Woven (W)12' WideSY Pattern & SymmetryDuracolor® Tricor Premium NylonSolution DyedUC Approved NONE NOYES67.18$ 55.12$ BroadloomSchemaBC508Weldlok12' WideSY Yarn Spinner/Mohawk Today- 50 SY ColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES53.05$ 50.62$ BroadloomSecond Wind / QSBC557Weldlok12' WideSY DomicileColorstrandPrecision Dyed InjectionAlumina Trihydrate (FR) NOYES48.97$ 40.41$ Strategic Account Number: 16629For order placement: MohawkOne West - tammy_land@mohawkind.com | MohawkOne East - Contract Inquiries: contract_compliance@mohawkind.comDocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 Broadloom Sequence of Events BC562 Weldlok 12' WideSY Open Narrative/Mohawk Today- 50 SYColorstrand Precision Dyed InjectionAlumina Trihydrate (FR) NO YES53.05$ 50.62$ Broadloom Shadow Pass KC271 Woven (W) 12' WideSY Sunweave Duracolor® Tricor Premium Nylon Solution DyedUC Approved NONE NO YES66.12$ 55.12$ Broadloom Shape Up / QS BC558 Weldlok 12' WideSY Domicile Colorstrand Precision Dyed InjectionAlumina Trihydrate (FR) NO YES48.97$ 40.41$ Broadloom Sideward / QS BC537 Weldlok 12' WideSY Domicile Colorstrand Precision Dyed InjectionAlumina Trihydrate (FR) NO YES48.97$ 40.41$ Broadloom Sky Gap / QS BC551 Weldlok 12' WideSY Domicile Colorstrand Precision Dyed InjectionAlumina Trihydrate (FR) NO YES48.97$ 40.41$ Broadloom Smart Details / QS / Max Service BC451 Weldlok 12' WideSY High Concepts PET Solution DyedUC ApprovedAlumina Trihydrate (FR) NO NO12.04$ 11.49$ Broadloom Social Identity BC572 Weldlok 12' WideSY Open Narrative/Mohawk Today- 50 SYColorstrand Precision Dyed InjectionAlumina Trihydrate (FR) NO YES53.05$ 50.62$ Broadloom Social Perk / QS BC530 Weldlok 12' WideSY Social OrderColorstrand Solution DyedUC ApprovedAlumina Trihydrate (FR) NO YES31.48$ 24.79$ Broadloom Spheroid / QS BC535 Weldlok 12' WideSY Domicile Colorstrand Precision Dyed InjectionAlumina Trihydrate (FR) NO YES48.97$ 40.41$ Broadloom Start Right / QS / Max ServiceBC453 Weldlok 12' WideSY High Concepts PET Solution DyedUC ApprovedAlumina Trihydrate (FR) NO NO12.04$ 11.49$ Broadloom Storied Pieces BC580 Weldlok 12' WideSY Celebrating Heritage Colorstrand Solution DyedYesAlumina Trihydrate (FR) NO YES46.78$ 44.64$ Broadloom Subsidiary / QS BC533 Weldlok 12' WideSY Domicile Colorstrand Precision Dyed InjectionAlumina Trihydrate (FR) NO YES48.97$ 40.41$ Broadloom Suburbia SLC27 Weldlok 12' WideSY 100% Mohawk EverStrand BCF P.E.T. Piece DyedAlumina Trihydrate (FR) NO NO19.83$ 15.60$ Broadloom Surreal AdvertBC560 Weldlok 12' WideSY Open Narrative/Mohawk Today- 50 SYColorstrand Precision Dyed InjectionAlumina Trihydrate (FR) NO YES53.05$ 50.62$ Broadloom Trail Mix / QS / Max Service BC333 Weldlok 12' WideSY Explorations Colorstrand Solution DyedUC ApprovedAlumina Trihydrate (FR) NO YES14.92$ 14.24$ Broadloom Uncommon Thread KC233 Woven (W) 12' WideSY Modern DobbyDuracolor® Tricor Premium Nylon Solution DyedUC Approved NONE NO NO61.92$ 51.54$ Broadloom Vicar / QS BC542 Weldlok 12' WideSY Domicile Colorstrand Precision Dyed InjectionAlumina Trihydrate (FR) NO YES48.97$ 40.41$ Broadloom Waft / QS BC548 Weldlok 12' WideSY Domicile Colorstrand Precision Dyed InjectionAlumina Trihydrate (FR) NO YES48.97$ 40.41$ Broadloom Well Dressed KC226 Woven (W) 12' WideSY Simply Tailored Duracolor® Tricor Premium Nylon Solution DyedUC Approved NONE NO YES90.24$ 74.51$ Broadloom Whip Stitch / QS / Max Service BC376 Unibond Plus 12' WideSY Fiber ArtColorstrand Solution DyedUC ApprovedAlumina Trihydrate (FR) NO YES16.18$ 15.43$ Broadloom Wired Mesh / QS BC393 Unibond Plus 12' WideSY Metal CraftColorstrand Solution DyedUC ApprovedAlumina Trihydrate (FR) NO YES22.16$ 21.15$ Modular Carpet TileA Premonition II GT161 EcoFlex NXT (EP) 2424SY Sixth Sense II DuracolorSolution DyedUC Approved NONE NO YES65.32$ 63.18$ Modular Carpet TileAcademic View / QS / Max Service BT433 EcoFlex Matrix (UZ) 2424SYArt Exposure Colorstrand Solution DyedUC Approved NONE NO YES22.12$ 21.10$ Modular Carpet TileAccredited / QS GT431 EcoFlex NXT (EP) 1236SY Learn & Live Duracolor TricorSolution DyedUC Approved NONE NO YES38.88$ 33.98$ Modular Carpet TileAdaptable / QS BT432 EcoFlex Matrix (UZ) 2424SYArt Exposure EcoFlex Matrix Solution DyedUC Approved NONE NO YES29.68$ 29.23$ Modular Carpet TileAdopt a Plan GT466 EcoFlex NXT (EP) 2424SY Learn & Live - Taking Steps Duracolor TricorSolution DyedYes NONE NO YES34.83$ 33.24$ Modular Carpet TileAmplitude GT147 EcoFlex NXT (EP) 2424SY Power SurgeDuracolorSolution DyedUC Approved NONE NO YES56.48$ 54.06$ Modular Carpet TileAmused II GT313 EcoFlex NXT (EP) 2424SY State of Mind III DuracolorSolution DyedUC Approved NONE NO YES67.10$ 64.31$ Modular Carpet TileAngled Perception / QS BT496 EcoFlex Matrix (UZ) 1236SY Visual Edge EcoFlex Matrix Solution DyedUC Approved NONE NO YES29.50$ 26.66$ Modular Carpet TileAqua Rhythm GT455 EcoFlex NXT (EP) 1236SY Data Tide Duracolor TricorSolution DyedYes NONE NO YES43.00$ 41.04$ Modular Carpet TileArtist II / QS BT380 EcoFlex Matrix (UZ) 2424SY Pure Genius II EcoFlex Matrix Solution Dyed/Yarn DyedNONE NO YES32.92$ 32.73$ Modular Carpet TileBaccharis GT408 EcoFlex NXT (EP) 1236SY Healthy Environments Duracolor TricorSolution DyedUC Approved NONE NO YES45.54$ 43.53$ Modular Carpet TileBiome GT456 EcoFlex NXT (EP) 1236SY Data Tide Duracolor TricorSolution DyedYes NONE NO YES43.00$ 41.04$ Modular Carpet TileBlended Twist / QS BT413 EcoFlex Matrix (UZ) 2424SYArtisanal EcoFlex Matrix Solution DyedUC Approved NONE NO YES23.56$ 22.49$ Modular Carpet TileBrain PowerGT136 EcoFlex NXT (EP) 2424SY Mind Over MatterDuracolorSolution DyedUC Approved NONE NO YES42.64$ 40.70$ Modular Carpet TileCaliber / QS BT282 EcoFlex Matrix (UZ) 2424SY Bending Earth EcoFlex Matrix Solution DyedUC Approved NONE NO YES32.49$ 32.10$ Modular Carpet TileCentral Point / QS BT428 EcoFlex Matrix (UZ) 2424SYArt Intervention EcoFlex Matrix Solution DyedUC Approved NONE NO YES28.62$ 26.48$ Modular Carpet TileCEO II / QS BT382 EcoFlex Matrix (UZ) 2424SY Pure Genius II EcoFlex Matrix Solution Dyed/Yarn DyedNONE NO YES32.92$ 32.73$ Modular Carpet TileChillD GT424 EcoFlex NXT (EP) 1236SY Relaxing Floors Duracolor TricorSolution DyedUC Approved NONE NO YES57.33$ 52.98$ Modular Carpet TileChitalpa GT407 EcoFlex NXT (EP) 1236SY Healthy Environments Duracolor TricorSolution DyedUC Approved NONE NO YES45.54$ 43.53$ Modular Carpet TileClever Class / QS BT408 EcoFlex Matrix (UZ) 2424SY Mixology EcoFlex Matrix Solution DyedUC Approved NONE NO YES22.12$ 20.96$ Modular Carpet TileColor Balance GT405 EcoFlex NXT (EP) 1236SY Color Balance DuracolorSolution DyedUC Approved NONE NO YES44.89$ 42.90$ Modular Carpet TileColorBeatGT160 EcoFlex NXT (EP) 2424SY ColorbeatDuracolor TricorSolution DyedUC Approved NONE NO YES48.38$ 44.93$ Modular Carpet TileColorBeat PlankGT298 EcoFlex NXT (EP) 1236SY ColorbeatDuracolor TricorSolution DyedUC Approved NONE NO YES53.06$ 50.77$ Modular Carpet TileCoolly Noted / QS BT336 EcoFlex Matrix (UZ) 2424SY Mixology EcoFlex Matrix Solution DyedUC Approved NONE NO YES22.12$ 20.96$ Modular Carpet TileCrafted Expression GT459 EcoFlex NXT (EP) 1236SY Celebrated HeritageDuracolor TricorSolution DyedYes NONE NO YES53.55$ 51.11$ Modular Carpet TileCreative Spark / QS / Max ServiceBT426 EcoFlex Matrix (UZ) 2424SYArt Intervention Colorstrand Solution DyedUC Approved NONE NO YES22.12$ 21.10$ Modular Carpet TileDatum / QS BT284 EcoFlex Matrix (UZ) 2424SY Bending Earth EcoFlex Matrix Solution DyedUC Approved NONE NO YES32.49$ 32.10$ Modular Carpet TileDiffuse BT425 EcoFlex NXT (EP) 1236SY Variant Form EcoFlex NXT Solution DyedUC Approved NONE NO YES42.84$ 41.32$ Modular Carpet TileDigital Terrain Plank GT341 EcoFlex NXT (EP) 1236SY Expedition Duracolor TricorSolution DyedUC Approved NONE NO YES52.06$ 49.61$ Modular Carpet TileDisruptive Path / QS BT430 EcoFlex NXT (EP) 1236SYArt Style EcoFlex NXT Solution DyedUC Approved NONE NO YES41.11$ 40.12$ Modular Carpet TileDoctor II / QS BT381 EcoFlex Matrix (UZ) 2424SY Pure Genius II EcoFlex Matrix Solution Dyed/Yarn DyedNONE NO YES32.92$ 32.73$ Modular Carpet TileDraft Point / QS / Max ServiceBT427 EcoFlex Matrix (UZ) 2424SYArt Intervention Colorstrand Solution DyedUC Approved NONE NO YES22.12$ 21.10$ Modular Carpet TileDrifted Ground Plank / QSBT389 EcoFlex NXT (EP) 1236SY Iconic Earth Colorstrand Solution DyedYes NONE NO YES42.41$ 40.47$ Modular Carpet TileEcosphere / QS GT333 EcoFlex NXT (EP) 2424SY Expedition Duracolor TricorSolution DyedUC Approved NONE NO YES45.32$ 43.33$ Modular Carpet TileEnlivened / QS / Max Service BT455 EcoFlex Matrix (UZ) 2424SYArt Exposure Colorstrand Solution DyedUC Approved NONE NO YES22.12$ 21.10$ Modular Carpet TileEnthralled II GT314 EcoFlex NXT (EP) 2424SY State of Mind III DuracolorSolution DyedUC Approved NONE NO YES67.10$ 64.31$ Modular Carpet TileFaculty Remix GT154 EcoFlex NXT (EP) 2424SY Faculty Remix DuracolorSolution Dyed/Yarn DyedNONE NO YES50.72$ 48.53$ Modular Carpet TileFeather GT434 EcoFlex NXT (EP) 1236SY Owls Duracolor TricorSolution DyedUC Approved NONE NO YES57.33$ 53.28$ Modular Carpet TileField Of View Dark GT449 EcoFlex NXT (EP) 1236SY Optic Reset Duracolor TricorSolution DyedUC Approved NONE NO YES36.77$ 33.06$ Modular Carpet TileField Of View Light GT450 EcoFlex NXT (EP) 1236SY Optic Reset Duracolor TricorSolution DyedUC Approved NONE NO YES36.77$ 33.06$ Modular Carpet TileField Overlay Dark GT403 EcoFlex NXT (EP) 1236SY Lichen Duracolor TricorSolution DyedUC Approved NONE NO YES46.58$ 44.44$ Modular Carpet TileFiltering Form / QS BT583 EcoFlex Matrix (UZ) 2424SY Crossing CurrentColorstrand Solution DyedYes NONE NO YES29.39$ 28.05$ Modular Carpet TileFirst One Up II / QS BT443 EcoFlex NXT (EP) 2424SY First One Up II EcoFlex NXT Solution DyedUC Approved NONE NO YES33.30$ 31.78$ Modular Carpet TileFirstStep II / QS GT315 EcoFlex NXT (EP) 2424SY Tuff Stuff II DuracolorSolution DyedUC Approved NONE NO YES96.55$ 89.97$ Modular Carpet TileFlamestitch III GT168 EcoFlex NXT (EP) 2424SY Flamestitch DuracolorSolution DyedUC Approved NONE NO YES57.74$ 55.29$ Modular Carpet TileFlight GT435 EcoFlex NXT (EP) 1236SY Owls Duracolor TricorSolution DyedUC Approved NONE NO YES57.33$ 53.28$ Modular Carpet TileFlux Foundation / QS BT585 EcoFlex Matrix (UZ) 2424SY Shape & Flow Colorstrand Solution DyedYes NONE NO YES29.50$ 28.15$ Modular Carpet TileFlux Play / QS BT584 EcoFlex Matrix (UZ) 2424SY Shape & Flow Colorstrand Solution DyedYes NONE NO YES29.50$ 28.15$ Modular Carpet TileForward Vision GT135 EcoFlex NXT (EP) 2424SY Mind Over MatterDuracolorSolution DyedUC Approved NONE NO YES42.64$ 40.74$ Modular Carpet TileFractal GrounD GT425 EcoFlex NXT (EP) 1236SY Relaxing Floors Duracolor TricorSolution DyedUC Approved NONE NO YES57.33$ 52.98$ Modular Carpet TileFramed Structure / QS / Max ServiceBT436 EcoFlex Matrix (UZ) 2424SY Sketch Effect Colorstrand Solution DyedUC Approved NONE NO YES22.12$ 21.10$ Modular Carpet TileFramed Structure / QS EcoFlex AirBT436 EcoFlex Air (UW) 2424SY Sketch Effect Colorstrand Solution DyedUC Approved NONE NO YES32.65$ 24.26$ Modular Carpet TileGravitational Plank GT343 EcoFlex NXT (EP) 1236SY Expedition Duracolor TricorSolution DyedUC Approved NONE NO YES52.06$ 49.61$ Modular Carpet TileGround CoverGT402 EcoFlex NXT (EP) 1236SY Lichen Duracolor TricorSolution DyedUC Approved NONE NO YES63.20$ 60.44$ Modular Carpet TileHeadstrong / QSBT354 EcoFlex Matrix (UZ) 2424SY RenegadeEcoFlex Matrix Solution DyedUC Approved NONE NO YES30.62$ 29.22$ Modular Carpet TileHem GT178 EcoFlex NXT (EP) 2424SY Denim DuracolorSolution DyedUC Approved NONE NO YES39.24$ 37.44$ Modular Carpet TileHem PlankGT295 EcoFlex NXT (EP) 1236SY Denim DuracolorSolution DyedUC Approved NONE NO YES43.11$ 41.41$ Modular Carpet TileHidden Dimension / QS BT497 EcoFlex Matrix (UZ) 1236SY Visual Edge Ecoflex Matrix Solution DyedUC Approved NONE NO YES29.50$ 28.38$ Modular Carpet TileHorsepower II GT170 EcoFlex NXT (EP) 2424SY Motorsport II DuracolorSolution DyedUC Approved NONE NO YES60.08$ 57.55$ Modular Carpet TileHustle & Bustle GT307 EcoFlex NXT (EP) 2424SY On The Scene Duracolor TricorSolution DyedUC Approved NONE NO YES40.66$ 38.80$ Modular Carpet TileHydrosphere / QSGT332 EcoFlex NXT (EP) 2424SY Expedition Duracolor TricorSolution DyedUC Approved NONE NO YES45.32$ 43.33$ Modular Carpet TileHyper Earth PlankBT405 EcoFlex NXT (EP) 1236SY Hyper Earth EcoFlex NXT Solution DyedUC Approved NONE NO YES44.30$ 42.85$ Modular Carpet TileIn The Loop / QS BT309 EcoFlex Matrix (UZ) 2424SY Beyond Expectations EcoFlex Matrix Solution DyedUC Approved NONE NO YES33.10$ 31.59$ Modular Carpet TileInfinite Impact / QS / Max Service BT499 EcoFlex Matrix (UZ) 1236SY Infinite ImpactEnvirostrand Solution DyedUC Approved NONE NO NO18.88$ 16.51$ Modular Carpet TileInseam Plank GT297 EcoFlex NXT (EP) 1236SY Denim DuracolorSolution DyedUC Approved NONE NO YES43.11$ 41.14$ Modular Carpet TileInsurgentBT367 EcoFlex Matrix (UZ) 2424SY RenegadeEcoFlex Matrix Solution DyedUC Approved NONE NO YES38.07$ 36.68$ Modular Carpet TileIntegrateBT423 EcoFlex NXT (EP) 2424SY Variant Form EcoFlex NXT Solution DyedUC Approved NONE NO YES39.76$ 38.43$ Modular Carpet TileInterthread / QSBT449 EcoFlex Matrix (UZ) 2424SY DexterityEcoFlex Matrix Solution DyedUC Approved NONE NO YES18.88$ 17.57$ Modular Carpet TileInto ItGT319 EcoFlex NXT (EP) 2424SY Get SmArtDuracolor TricorSolution DyedUC Approved NONE NO YES41.20$ 38.74$ Modular Carpet TileIt's a Sign II GT162 EcoFlex NXT (EP) 2424SY Sixth Sense II DuracolorSolution DyedUC Approved NONE NO YES65.32$ 63.18$ Modular Carpet TileJean GT177 EcoFlex NXT (EP) 2424SY Denim DuracolorSolution DyedUC Approved NONE NO YES39.24$ 37.44$ Modular Carpet TileKinesthetic Plank GT317 EcoFlex NXT (EP) 1236SY Get SmArtDuracolor TricorSolution DyedUC Approved NONE NO YES44.80$ 42.53$ Modular Carpet TileKnow-HowGT137 EcoFlex NXT (EP) 2424SY Mind Over MatterDuracolorSolution DyedUC Approved NONE NO YES42.64$ 40.70$ Modular Carpet TileLate NightGT306 EcoFlex NXT (EP) 2424SY On The Scene Duracolor TricorSolution DyedUC Approved NONE NO YES40.66$ 38.80$ Modular Carpet TileLateral Surface / QSBT314 EcoFlex Matrix (UZ) 2424SY Bending Earth II EcoFlex Matrix Solution DyedUC Approved NONE NO YES32.49$ 32.10$ Modular Carpet TileLithosphere / QS GT334 EcoFlex NXT (EP) 2424SY Expedition Duracolor TricorSolution DyedUC Approved NONE NO YES45.32$ 43.33$ Modular Carpet TileMacro Bloom GT388 EcoFlex NXT (EP) 1236SY Lichen Duracolor TricorSolution DyedUC Approved NONE NO YES63.20$ 60.44$ Modular Carpet TileMaterial NarrativesGT458 EcoFlex NXT (EP) 1236SY Celebrated HeritageDuracolor TricorSolution DyedYes NONE NO YES53.55$ 51.11$ Modular Carpet TileMellowD GT426 EcoFlex NXT (EP) 1236SY Relaxing Floors Duracolor TricorSolution DyedUC Approved NONE NO YES57.33$ 52.98$ Modular Carpet TileMetallic Path / QS BT431 EcoFlex NXT (EP) 1236SYArt Style EcoFlex NXT Solution DyedUC Approved NONE NO YES41.11$ 40.12$ Modular Carpet TileMetalmorphic Plank / QS BT388 EcoFlex NXT (EP) 1236SY Iconic Earth Colorstrand Solution DyedYes NONE NO YES42.41$ 40.47$ Modular Carpet TileMicro Bloom GT397 EcoFlex NXT (EP) 1236SY Lichen Duracolor TricorSolution DyedUC Approved NONE NO YES63.20$ 60.44$ Modular Carpet TileMindful / QS / Max Service BT446 EcoFlex Matrix (UZ) 2424SY Mindful Envirostrand Solution DyedUC Approved NONE NO NO18.88$ 15.67$ Modular Carpet TileMindful Stripe / QS BT447 EcoFlex Matrix (UZ) 2424SY Mindful EcoFlex Matrix Solution DyedUC Approved NONE NO YES16.72$ 15.67$ Modular Carpet TileMotivated MovementGT465 EcoFlex NXT (EP) 2424SY Learn & Live - Taking Steps Duracolor TricorSolution DyedYes NONE NO YES34.83$ 33.24$ Modular Carpet TileMutineerBT366 EcoFlex Matrix (UZ) 2424SY RenegadeEcoFlex Matrix Solution DyedUC Approved NONE NO YES38.07$ 36.68$ DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 Modular Carpet TileNecessary Action GT467 EcoFlex NXT (EP) 2424SY Learn & Live - Taking Steps Duracolor TricorSolution DyedYes NONE NO YES34.83$ 33.24$ Modular Carpet TileNew Basics III / QS BT400 EcoFlex Matrix (UZ) 2424SY New Basics EcoFlex Matrix Solution DyedUC Approved NONE NO YES30.35$ 29.15$ Modular Carpet TileOff The Wall GT195 EcoFlex NXT (EP) 2424SY Street Thread DuracolorSolution DyedUC Approved NONE NO YES61.25$ 58.67$ Modular Carpet TilePDI-Beach Breaker PlankSY020 EcoFlex Air (UW) 1236SY PDI Tile ColorstrandNONE NO YES65.21$ 62.23$ Modular Carpet TilePDI-Beach Breaker SquareSY020 EcoFlex Air (UW) 2424SY PDI Tile ColorstrandNONE NO YES63.05$ 60.18$ Modular Carpet TilePDI-Second Wave PlankSY022 EcoFlex Air (UW) 1236SY PDI Tile ColorstrandNONE NO YES65.21$ 62.23$ Modular Carpet TilePDI-Second Wave SquareSY022 EcoFlex Air (UW) 2424SY PDI Tile ColorstrandNONE NO YES63.05$ 60.18$ Modular Carpet TilePDI-Shaka PlankSY019 EcoFlex Air (UW) 1236SY PDI Tile ColorstrandNONE NO YES54.41$ 51.93$ Modular Carpet TilePDI-Shaka SquareSY019 EcoFlex Air (UW) 2424SY PDI Tile ColorstrandNONE NO YES52.25$ 49.87$ Modular Carpet TilePDI-Special Base Plank (Ripple, Stria, NAEcoFlex Air (UW) 1236SY PDI Tile ColorstrandNONE NO YES67.37$ 64.30$ Modular Carpet TilePDI-Special Base Square (Ripple, Stria, NAEcoFlex Air (UW) 2424SY PDI Tile ColorstrandNONE NO YES65.21$ 62.23$ Modular Carpet TilePhotofinish II GT169 EcoFlex NXT (EP) 2424SY Motorsport II DuracolorSolution DyedUC Approved NONE NO YES60.08$ 57.55$ Modular Carpet TilePicture This / QS BT334 EcoFlex Matrix (UZ) 2424SY Mixology EcoFlex Matrix Solution DyedUC Approved NONE NO YES22.12$ 20.96$ Modular Carpet TilePop Icon GT194 EcoFlex NXT (EP) 2424SY Street Thread DuracolorSolution DyedUC Approved NONE NO YES61.25$ 58.67$ Modular Carpet TilePosture / QS BT407 EcoFlex Matrix (UZ) 2424SY Mixology EcoFlex Matrix Solution DyedUC Approved NONE NO YES22.12$ 20.96$ Modular Carpet TileProficient / QS GT432 EcoFlex NXT (EP) 1236SY Learn & Live Duracolor TricorSolution DyedUC Approved NONE NO YES38.88$ 33.98$ Modular Carpet TileReawakened PlankGT302 EcoFlex NXT (EP) 1236SY New VintageDuracolor TricorSolution DyedUC Approved NONE NO YES55.06$ 52.71$ Modular Carpet TileReckless / QS BT353 EcoFlex Matrix (UZ) 2424SY RenegadeEcoFlex Matrix Solution DyedUC Approved NONE NO YES30.62$ 29.22$ Modular Carpet TileReconstructBT424 EcoFlex NXT (EP) 2424SY Variant Form EcoFlex NXT Solution DyedUC Approved NONE NO YES39.76$ 38.43$ Modular Carpet TileRediscovered Plank GT303 EcoFlex NXT (EP) 1236SY New VintageDuracolor TricorSolution DyedUC Approved NONE NO YES55.06$ 52.71$ Modular Carpet TileRefined Pass / QS BT582 EcoFlex Matrix (UZ) 2424SY Crossing CurrentColorstrand Solution DyedYes NONE NO YES29.39$ 28.05$ Modular Carpet TileRenewed Path / QS / Max ServiceBT578 EcoFlex Matrix (UZ) 2424SY Renewed Path Envirostrand Solution DyedUC Approved NONE NO NO18.88$ 16.51$ Modular Carpet TileRestD GT427 EcoFlex NXT (EP) 1236SY Relaxing Floors Duracolor TricorSolution DyedUC Approved NONE NO YES57.33$ 52.98$ Modular Carpet TileRestore BT417 EcoFlex Matrix (UZ) 2424SY Uncharted EcoFlex Matrix Solution DyedUC Approved NONE NO YES42.70$ 41.42$ Modular Carpet TileRiot / QS BT355 EcoFlex Matrix (UZ) 2424SY RenegadeEcoFlex Matrix Solution DyedUC Approved NONE NO YES30.62$ 29.22$ Modular Carpet TileRise Up / QS GT420 EcoFlex NXT (EP) 2424SY Learn & Live Duracolor TricorSolution DyedUC Approved NONE NO YES34.83$ 31.22$ Modular Carpet TileRise Up / QS EcoFlex Air GT420 EcoFlex Air (UW) 2424SY Learn & Live Duracolor TricorSolution DyedUC Approved NONE NO YES41.04$ 31.22$ Modular Carpet TileRiver CodeGT454 EcoFlex NXT (EP) 1236SY Data Tide Duracolor TricorSolution DyedYes NONE NO YES43.00$ 41.04$ Modular Carpet TileSabbatical / QS GT433 EcoFlex NXT (EP) 1236SY Learn & Live Duracolor TricorSolution DyedUC Approved NONE NO YES38.88$ 33.98$ Modular Carpet TileSector / QS BT285 EcoFlex Matrix (UZ) 2424SY Bending Earth EcoFlex Matrix Solution DyedUC Approved NONE NO YES32.49$ 32.10$ Modular Carpet TileSeek Unique / QS BT335 EcoFlex Matrix (UZ) 2424SY Mixology EcoFlex Matrix Solution DyedUC Approved NONE NO YES22.12$ 20.96$ Modular Carpet TileSeismic Wave Plank GT342 EcoFlex NXT (EP) 1236SY Expedition Duracolor TricorSolution DyedUC Approved NONE NO YES52.06$ 49.61$ Modular Carpet TileSelvedge GT179 EcoFlex NXT (EP) 2424SY Denim DuracolorSolution DyedUC Approved NONE NO YES39.24$ 37.44$ Modular Carpet TileShaded Lines / QS BT437 EcoFlex Matrix (UZ) 2424SY Sketch Effect EcoFlex Matrix Solution DyedUC Approved NONE NO YES26.06$ 24.26$ Modular Carpet TileShaded Lines / QS EcoFlex Air BT437 EcoFlex Air (UW) 2424SY Sketch Effect EcoFlex Matrix Solution DyedUC Approved NONE NO YES32.65$ 24.26$ Modular Carpet TileShared Path / QS BT429 EcoFlex NXT (EP) 1236SYArt Style EcoFlex NXT Solution DyedUC Approved NONE NO YES41.11$ 40.12$ Modular Carpet TileShifted Focus GT448 EcoFlex NXT (EP) 1236SY Optic Reset Duracolor TricorSolution DyedUC Approved NONE NO YES36.77$ 33.07$ Modular Carpet TileSide Stripe / QS GT419 EcoFlex NXT (EP) 2424SY Learn & Live Duracolor TricorSolution DyedUC Approved NONE NO YES34.83$ 30.27$ Modular Carpet TileSide Stripe / QS EcoFlex Air GT419 EcoFlex Air (UW) 2424SY Learn & Live Duracolor TricorSolution DyedUC Approved NONE NO YES41.04$ 30.27$ Modular Carpet TileSolve II BT416 EcoFlex Matrix (UZ) 2424SY Uncharted EcoFlex Matrix Solution Dyed/Yarn DyedNONE NO YES42.70$ 41.42$ Modular Carpet TileStatement Fabric / QS / Max Service BT448 EcoFlex Matrix (UZ) 2424SY DexterityEnvirostrand Solution DyedUC Approved NONE NO NO18.88$ 17.57$ Modular Carpet TileStatement Stone / QSBT390 EcoFlex NXT (EP) 2424SY Iconic Earth Colorstrand Solution DyedYes NONE NO YES38.99$ 37.20$ Modular Carpet TileStep In Style II / QS GT312 EcoFlex NXT (EP) 2424SY Tuff Stuff II DuracolorSolution DyedUC Approved NONE NO YES90.11$ 86.47$ Modular Carpet TileStep Up II / QS GT311 EcoFlex NXT (EP) 2424SY Tuff Stuff II DuracolorSolution DyedUC Approved NONE NO YES100.30$ 98.87$ Modular Carpet TileStreetscapes GT308 EcoFlex NXT (EP) 2424SY On The Scene Duracolor TricorSolution DyedUC Approved NONE NO YES40.66$ 38.80$ Modular Carpet TileStructured Mesh GT380 EcoFlex NXT (EP) 2424SY Uncovered DuracolorSolution DyedUC Approved NONE NO YES46.42$ 43.15$ Modular Carpet TileSuper Fresh GT196 EcoFlex NXT (EP) 2424SY Street Thread DuracolorSolution DyedUC Approved NONE NO YES61.25$ 58.67$ Modular Carpet TileSwipe Right / QS GT418 EcoFlex NXT (EP) 2424SY Learn & Live Duracolor TricorSolution DyedUC Approved NONE NO YES34.83$ 30.27$ Modular Carpet TileSwipe Right / QS EcoFlex Air GT418 EcoFlex Air (UW) 2424SY Learn & Live Duracolor TricorSolution DyedUC Approved NONE NO YES41.04$ 30.27$ Modular Carpet TileTactile Infusion GT422 EcoFlex NXT (EP) 1236SY Textural Effects Duracolor TricorSolution DyedUC Approved NONE NO YES38.25$ 35.94$ Modular Carpet TileTaped OffGT197 EcoFlex NXT (EP) 2424SY Street Thread DuracolorSolution DyedUC Approved NONE NO YES58.39$ 55.92$ Modular Carpet TileThematic Thread GT423 EcoFlex NXT (EP) 1236SY Textural Effects Duracolor TricorSolution DyedUC Approved NONE NO YES38.25$ 35.94$ Modular Carpet TileThreaded Craft / QSBT414 EcoFlex Matrix (UZ) 2424SYArtisanal EcoFlex Matrix Solution DyedUC Approved NONE NO YES23.56$ 22.49$ Modular Carpet TileTonal Shift GT457 EcoFlex NXT (EP) 1236SY Celebrated HeritageDuracolor TricorSolution DyedYes NONE NO YES53.55$ 51.11$ Modular Carpet TileTranquil Beauty Plank GT309 EcoFlex NXT (EP) 1236SY Tranquil Beauty Duracolor TricorSolution DyedUC Approved NONE NO YES50.85$ 48.64$ Modular Carpet TileTransformative GT324 EcoFlex NXT (EP) 2424SY SerenityDuracolorSolution DyedUC Approved NONE NO YES57.40$ 54.95$ Modular Carpet TileUnexpected Texture GT377 EcoFlex NXT (EP) 2424SY Uncovered DuracolorSolution DyedUC Approved NONE NO YES46.42$ 45.03$ Modular Carpet TileUrban CanvasGT412 EcoFlex NXT (EP) 1236SY Nutopia Duracolor TricorSolution DyedUC Approved NONE NO YES49.91$ 47.74$ Modular Carpet TileUrban Field II GT446 EcoFlex NXT (EP) 1236SY Nutopia 2.0 Duracolor TricorSolution DyedUC Approved NONE NO YES59.29$ 55.12$ Modular Carpet TileUrban Fringe II GT445 EcoFlex NXT (EP) 1236SY Nutopia 2.0 Duracolor TricorSolution DyedUC Approved NONE NO YES59.29$ 55.12$ Modular Carpet TileUrban MobilityGT430 EcoFlex NXT (EP) 1236SY Smart CityDuracolor TricorSolution DyedUC Approved NONE NO YES59.29$ 55.12$ Modular Carpet TileUrban Model GT429 EcoFlex NXT (EP) 1236SY Smart CityDuracolor TricorSolution DyedUC Approved NONE NO YES59.29$ 55.12$ Modular Carpet TileUrban Passage II GT444 EcoFlex NXT (EP) 1236SY Nutopia 2.0 Duracolor TricorSolution DyedUC Approved NONE NO YES59.29$ 55.12$ Modular Carpet TileUrban TerrainGT413 EcoFlex Matrix (UZ) 1236SY Nutopia MatrixDuracolor TricorSolution DyedUC Approved NONE NO YES38.97$ 35.94$ Modular Carpet TileUrban TransitGT414 EcoFlex Matrix (UZ) 1236SY Nutopia MatrixDuracolor TricorSolution DyedUC Approved NONE NO YES38.97$ 35.94$ Modular Carpet TileVenturesome / QS BT356 EcoFlex Matrix (UZ) 2424SY RenegadeEcoFlex Matrix Solution DyedUC Approved NONE NO YES30.62$ 23.22$ Modular Carpet TileWavelength GT149 EcoFlex NXT (EP) 2424SY Power SurgeDuracolorSolution DyedUC Approved NONE NO YES54.14$ 51.81$ Modular Carpet TileWellbeing GT325 EcoFlex NXT (EP) 2424SY SerenityDuracolorSolution DyedUC Approved NONE NO YES57.40$ 54.95$ Modular Carpet TileWrite Direction PlankGT318 EcoFlex NXT (EP) 1236SY Get SmArtDuracolor TricorSolution DyedUC Approved NONE NO YES44.80$ 42.53$ Modular Carpet TileXeric GT406 EcoFlex NXT (EP) 1236SY Healthy Environments Duracolor TricorSolution DyedUC Approved NONE NO YES45.54$ 43.53$ Modular Carpet TileX-Factor / QS BT212 EcoFlex Matrix (UZ) 2424SY X FactorEcoFlex Matrix Solution DyedUC Approved NONE NO YES21.40$ 17.51$ Modular Carpet TileZip It Plank GT296 EcoFlex NXT (EP) 1236SY Denim DuracolorSolution DyedUC Approved NONE NO YES43.11$ 39.10$ LVTAntiek C0015 8" x 60"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO7.18$ 6.01$ LVTAntiek C0015 9" x 48"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO7.18$ 6.01$ LVT Better TogetherC0097 12" x 36"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES6.46$ 5.60$ LVT Better TogetherC0097 24" x 24"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES6.46$ 5.60$ LVT Better TogetherC0097 4" x 36"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES6.46$ 5.60$ LVT Better TogetherC0097 8" x 48"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES6.46$ 5.60$ LVT BolderC0010 36" x 36"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) YES NO6.64$ 6.17$ LVT CentratoC0104 7.5"x 51.8"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES4.30$ 3.68$ LVT Creative Terrain C0181 18" x 36"SF Creative TerrainPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES10.60$ 10.12$ LVT Edgeland C0085 6" x 48"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO2.68$ 2.36$ LVT Elan Valley C0189 6" x 48"SF Elan ValleyPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES2.32$ 2.21$ LVT Grainiac C0013 6" x 48"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO3.76$ 3.05$ LVT Grown UpC0075 9" x 59"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO8.26$ 7.27$ LVT Hemstitch CR710 9.25" x 59.25"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) YES NO8.44$ 8.14$ LVT Hit the MarkC0095 12" x 24"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO7.90$ 6.71$ LVT Hit the MarkC0095 18" x 36"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO7.90$ 6.71$ LVT Hit the MarkC0095 7.25" x 48"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO7.90$ 6.71$ LVT Large & Local ReforestationC0188 9" x 59"SF Large & LocalPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES5.56$ 5.31$ LVT Large & Local Rendered FlaxC0192 9" x 59"SF Large & LocalPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES5.56$ 5.31$ LVT Large & Local Rugged FoundationC0191 9" x 59"SF Large & LocalPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES5.56$ 5.31$ LVT Large & Local Wood C0128 9" x 59"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES5.56$ 4.80$ LVT Lineate C0089 9" x 59"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) YES NO6.64$ 6.17$ LVT Linked CR708 9.84" x 39.37"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) YES NO8.44$ 8.14$ LVT Living Local Chromascope C0159 12" x 24"SF Living LocalPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES4.48$ 4.27$ LVT Living Local Optic Hues C0178 12" x 24"SF Living LocalPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES4.48$ 4.27$ LVT Living Local Premium Woods C0194 7.72" x 51.97"SF Living LocalPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES4.48$ 4.27$ LVT Living Local Stoneworks C0179 12" x 24"SF Living LocalPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES4.48$ 4.27$ LVT Living Local Terrazzo C0180 12" x 24"SF Living LocalPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES4.48$ 4.27$ LVT Living Local Wood Glue Down C2039 6" x 48"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES4.48$ 3.68$ LVT Matuto Plus C0135 12" x 24"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO5.74$ 4.94$ LVT Metal C0059 18" x 36"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO8.26$ 7.27$ LVT Mixte Solid C0090 36" x 36"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) YES NO6.64$ 6.17$ LVT Mixte Stripe C0091 36" x 36"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) YES NO6.64$ 6.17$ LVT Molveno Stones C0109 11.75" x 35.75"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO7.00$ 5.72$ LVT Molveno Woods C0110 7.75" x 59.75"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO7.00$ 5.72$ DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 LVT Morikato Wood C0016 7" x 48"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO6.46$ 5.83$ LVT Neches Bend C0187 7.52"x 51.8"SF Dodford 12PVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES4.48$ 4.27$ LVT Second Home Wood C0141 7.5" x 48"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO6.64$ 5.50$ LVT Secoya C0009 9" x 59"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) YES NO6.46$ 6.17$ LVT Select Step II Stone CR704 18" x 36"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO2.14$ 2.04$ LVT Select Step II Wood CR703 7.25" x 48"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO NO2.14$ 2.04$ LVT Urban Native StoneC0084 12" x 24"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES3.04$ 2.56$ LVT Urban Native Wood C0083 8" x 48"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) NO YES3.04$ 2.56$ LVT Vivid Step Plank CR7056" x 48"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) YES NO2.68$ 2.10$ LVT Vivid Step Stone CR706 12" x 24"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) YES NO2.68$ 2.10$ LVT Weave CR709 18" x 36"SFPVC, Ortho-Phthalate Free, Flame Retardant (Halogenated Free) YES NO8.44$ 8.14$ Rubber Tile TRUE HammeredTRMB 17-13/16" x 17-SF TRUENONE *Antimicrobial free for production after 7/1/19NO NO16.31$ 15.57$ Rubber Tile TRUE HammeredTRMB 35-11/16" x 35-SF TRUENONE *Antimicrobial free for production after 7/1/19NO NO15.80$ 15.08$ Rubber SheetTRUE Medi-Flex Sheet 2mm TRS2B 5' x 50' nominal SFNONE *Antimicrobial free for production after 7/1/19NO NO9.72$ 7.99$ Rubber SheetTRUE Medi-Flex Sheet 3mmTRS3B 5' x 50' nominal SFNONE *Antimicrobial free for production after 7/1/19NO NO12.10$ 10.01$ Rubber Tile TRUE Medi-Flex Tile 2mm TRSTB 17-13/16" x 17-SFNONE *Antimicrobial free for production after 7/1/19NO NO12.83$ 10.84$ Rubber Tile TRUE Medi-Flex Tile 2mm TRSTB 35-11/16" x 35-SFNONE *Antimicrobial free for production after 7/1/19NO NO12.53$ 10.84$ Rubber Tile TRUE Medi-Flex Tile 3mm TRSIB 17-13/16" x 17-SFNONE *Antimicrobial free for production after 7/1/19NO NO15.53$ 13.48$ Rubber Tile TRUE Medi-Flex Tile 3mm TRSIB 35-11/16" x 35-SFNONE *Antimicrobial free for production after 7/1/19NO NO15.28$ 13.48$ Rubber Tile TRUE Round TRRB 35-1/2" x 35-1/2"SF TRUENONE *Antimicrobial free for production after 7/1/19NO NO15.28$ 14.58$ Rubber Tile TRUE Round TRRB 17-11/16" x 17-SF TRUENONE *Antimicrobial free for production after 7/1/19NO NO15.80$ 15.08$ Resilient Sheet GeomorphicC2044/C20456' & 12' WidthSY Healthy EnvironmentsPVC, Ortho-Phthalate Free NO YES41.38$ 37.40$ Resilient Sheet Juniperus C2042/C20436' & 12' WidthSY Healthy EnvironmentsPVC, Ortho-Phthalate Free NO YES41.38$ 36.68$ Resilient Sheet Klei Firma C2046/C20476' & 12' WidthSY Healthy EnvironmentsPVC, Ortho-Phthalate Free NO YES41.38$ 36.68$ Resilient Sheet Sisalana C2040/C2041 6' & 12' WidthSY Healthy EnvironmentsPVC, Ortho-Phthalate Free NO YES41.38$ 36.68$ Resilient Sheet Living Kind C2049 13'2" WidthSY Living KindPVC, Ortho-Phthalate Free NO YES19.78$ 16.59$ Resilient Sheet Calmness C2023 6' & 12' WidthSY SerenityPVC, Ortho-Phthalate Free NO YES41.38$ 36.68$ Resilient Sheet Ephemeral C2022 6' & 12' WidthSY SerenityPVC, Ortho-Phthalate Free NO YES41.38$ 36.68$ Resilient Sheet SensoryC2021 6' & 12' WidthSY SerenityPVC, Ortho-Phthalate Free NO YES41.38$ 36.68$ Resilient Sheet TherapeuticC2020 6' & 12' WidthSY SerenityPVC, Ortho-Phthalate Free NO YES41.38$ 36.68$ Resilient Sheet Medella C2048 6' 6" WidthSY Healthy EnvironmentsPVC, Ortho-Phthalate Free NO YES48.04$ 40.69$ Hardwood / LaminateVoxwood C0182 54.33" LengthSF RevWood ContractFormaldehyde NO NO5.74$ 5.48$ Adhesives Nubroadlok (LifeLoc) Moisture Proof Latex Seam LLSSB112.26$ Adhesives NuBroadlok Premium PlusB002044.90$ Adhesives NuBroadlok Premium PlusB002044.90$ Adhesives NuBroadlok VRT B003075.21$ Adhesives NuBroadlokB26119.08$ Adhesives NuBroadlokB267117.87$ Adhesives EnPress M004C112.26$ Adhesives FlexLok FLXTB101.03$ Adhesives OptiSeal M003B151.55$ Adhesives PrimeCoatXL23C44.90$ Adhesives M700 VA67C39.28$ Adhesives M700 VA67C140.33$ Adhesives M95.0 M95C50.51$ Adhesives M95.0 M95C157.17$ Adhesives MS160 MS160190.85$ Adhesives SurfaceSeal XL26C106.65$ Adhesives M99.0 M9956.12$ Adhesives M99.0 M99190.85$ AdhesivesAD 590AD590151.55$ AdhesivesAD 777AWP7772.96$ AdhesivesAD 777AWP77224.53$ Adhesives Zip Step TapeADZIP246.98$ Adhesives Infuze Seam SealerINFZC6.73$ Adhesives M45 M45C5.26$ Accessories - RubberAD888AD888-01318.84$ Accessories - RubberAD888AD888-025.60$ Accessories - RubberAD888AD888-0370.72$ Accessories - RubberDual Cartridge GunLOCDC136.96$ Accessories - RubberDurabond Package LOCPC154.92$ Accessories - RubberTRUE Weld Rod TRWB93.17$ Accessories - RubberVisual Strip - Black VITC-2283.07$ Accessories - RubberVisual Strip - Night Glow VITC-82150.43$ Accessories - RubberVisual Strip - Red VITC-52104.40$ Accessories - RubberVisual Strip - White VITC-18104.40$ Accessories - RubberVisual Strip - Yellow VITC-72104.40$ Accessories - RubberSquare Mix Nozzles (10 pack) LOCNC30.30$ Accessories - RubberChemical Weld Cartridge-LoctiteLOCHC34.79$ Accessories - Sheet Infuze Seam SealerINFZC6.73$ Accessories - Sheet Heterogeneous Sheet Vinyl Weld RodsWELDC40.41$ Accessories - Sheet Homogeneous Sheet Vinyl Weld RodsMWRC40.41$ Accessories - LVTAccuSound VU01C0.55$ Accessories - LVTActiveSound VU02C0.77$ Accessories - LVT Scratch Repair KitVA8C-157.25$ Accessories - LVT Scratch Repair KitVA8C-3147.06$ Accessories - HVT Homogeneous Vinyl Tile Weld Rods CTWR168.39$ Accessories - HVT Deep Scrub CleanerHVTDC0.01$ Accessories - HVT Deep Scrub Pad (maroon)HVTDP0.01$ Accessories - HVT Initial Surface CleanerHVTSC0.01$ Accessories - RevWood ContractInitial Surface Cleaner Pad (natural)HVTSP0.01$ #REF! Installation Kit LT4C28.06$ Accessories - RevWood ContractInstamatch Repair KitIM40.41$ Accessories - RevWood ContractUnifix Repair Tool UT127.98$ Accessories - Stair Tread Hammered, Tread OnlyRTM16.83$ Accessories - Stair Tread Hammered, With RiserOPM20.20$ Accessories - Stair Tread Hammered, With Riser & Visual StripOVM23.57$ Accessories - Stair Tread Hammered, With Visual StripRVM21.32$ Accessories - Stair Tread Round, Tread OnlyTRNB16.83$ Accessories - Stair Tread Round, With RiserTROB20.20$ Accessories - Stair Tread Round, With Riser & Visual Strip TRQB23.57$ Accessories - Stair Tread Round, With Visual Strip TRPB21.32$ Wall Base - RubberStraight Wall Base - 120' Rolls CRW010.89$ Wall Base - RubberStraight Wall Base - 96' Rolls CRW011.54$ Wall Base - RubberStraight Wall Base - 120' Rolls CRW020.89$ Wall Base - RubberStraight Wall Base - 96' Rolls CRW021.54$ Wall Base - RubberCoved Wall Base - 120' Rolls CRW030.89$ Wall Base - RubberCoved Wall Base - 96' Rolls CRW031.54$ Wall Base - RubberCovedWall Base - 120' Rolls CRW050.89$ Wall Base - RubberCoved Wall Base - 96' Rolls CRW051.54$ Wall Base - Vinyl Straight Wall Base - 120' Rolls CVW010.83$ Wall Base - Vinyl Straight Wall Base - 96' Rolls CVW011.40$ Wall Base - Vinyl Straight Wall Base - 120' Rolls CVW020.83$ Wall Base - Vinyl Straight Wall Base - 96' Rolls CVW021.40$ Wall Base - Vinyl Straight Wall Base - 120' Rolls CVW030.83$ Wall Base - Vinyl Straight Wall Base - 96' Rolls CVW031.40$ Wall Base - Vinyl Straight Wall Base - 120' Rolls CVW040.83$ DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 Wall Base - Vinyl Straight Wall Base - 96' Rolls CVW041.40$ Wall Base - Vinyl Straight Wall Base - 120' Rolls CVW050.76$ Accessories - Stair Tread Hammered Tread CRS0116.74$ Accessories - Stair Tread Hammered Tread CRS0116.74$ Accessories - Stair Tread Hammered Tread & Riser CRS0220.08$ Accessories - Stair Tread Hammered Tread & Riser CRS0220.08$ Accessories - Stair Tread Hammered Tread w/Vis Strip CRS0320.61$ Accessories - Stair Tread Hammered Tread w/Vis Strip CRS0320.61$ Accessories - Stair Tread Hammered Tread & Riser w/VisStripCRS0223.96$ Accessories - Stair Tread Hammered Tread & Riser w/VisStripCRS0323.96$ Accessories - Stair Tread Round Tread CRS0316.74$ Accessories - Stair Tread Round Tread CRS0416.74$ Accessories - Stair Tread Round Tread & Riser CRS0420.08$ Accessories - Stair Tread Round Tread & Riser CRS0520.08$ Accessories - Stair Tread Round Tread w/Vis Strip CRS0520.61$ Accessories - Stair Tread Round Tread w/Vis Strip CRS0620.61$ Accessories - Stair Tread Round Tread & Riser CRS0623.96$ Accessories - Stair Tread Round Tread w/Vis Strip CRS0723.96$ Accessories - Stair Tread Round Tread w/Vis Strip CRS075.83$ Accessories - Stair Tread Round Tread & Riser w/VisStripCRS088.89$ Accessories - Stair Tread Round Tread & Riser w/VisStripCRS081.85$ Accessories - Stair Tread Stringer / RiserCRS091.10$ Accessories - Stair Tread Smooth Landing Tile CRS102.03$ Accessories - RubberUniversal Transition - Finish material to finish CRA011.19$ Accessories - RubberUniversal Transition - Finish material to finish CRA021.73$ Accessories - RubberUniversal Transition - Finish material to finish CRA031.54$ Accessories - RubberT-Moulding Track Pinless Metal Track (12ft) CRA041.67$ Accessories - RubberAdaptors - Finish material to finish material 1/8" CRA051.81$ Accessories - RubberAdaptors - Finish material to finish material 1/8" Tile-CRA060.86$ Accessories - RubberReducers - Finish material to floor 1/8" Underslung CRA071.54$ Accessories - RubberReducers - Finish material to floor 1/4" Underslung CRA080.93$ Accessories - RubberReducers - Finish material to floor 1/8" Reducer CRA093.98$ Accessories - RubberReducers - Finish material to floor 1/4" Reducer CRA105.28$ Accessories - RubberStair Installation Cove Stick (Natural Color Only - CRA112.69$ Accessories - RubberStair Nose to Flooring 1/8" Stair Nosing (12ft)CRS112.86$ Accessories - RubberStair Nose to Flooring 1/4" Undercut Nosing (12ft)CRS122.89$ Wall Base - RubberArchitectural Base - Straight Cut 8' LengthsAWB012.63$ Wall Base - RubberArchitectural Base - Straight Cut 8' LengthsAWB012.82$ DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 SUPPLIER: UOM New York Region 1: Bronx, Queens, Kings, Richmond, Nassau, Suffolk, Putnam, Westchester & Orange Counties New York Region 2: Erie, Niagara, St. Lawrence, Franklin, Essex, Jefferson, Lewis, & Hamilton Counties New York Region 3: Remainder of State of New York Labor Description Labor Rate Labor Rate Labor Rate Non Union Rate Union Wage Rate Non Union Rate Union Wage Rate Non Union Rate Union Wage Rate Non Union Rate Union Wage Rate Non Union Rate Union Wage Rate Non Union Rate Union Wage Rate Monday - Friday Standard 8 Hour Shift - Hourly Labor Rate for Flooring Contract Labor Services Not Listed HR $168.03 $168.03 $124.48 $124.48 $168.03 $82.23 $111.02 $82.23 $111.02 $82.23 $111.02 $101.20 $136.64 Open Market Open Market Monday - Friday Overtime - Add SY $6.12 $6.12 $4.88 $4.88 $6.12 $3.81 $4.78 $3.81 $4.78 $3.81 $4.78 $4.83 $6.05 Open Market Open Market Saturday - Add SY $6.12 $6.12 $4.88 $4.88 $6.12 $3.81 $4.78 $3.81 $4.78 $3.81 $4.78 $4.83 $6.05 Open Market Open Market Sunday & Holiday - Add SY $9.17 $9.17 $7.34 $7.34 $9.17 $5.73 $7.16 $5.73 $7.16 $5.73 $7.16 $7.27 $9.07 Open Market Open Market Installation Broadloom (direct glue down)SY $14.84 $14.84 $10.99 $10.99 $14.84 $7.85 $10.61 $8.46 $11.42 $8.46 $11.42 $10.86 $14.65 Open Market Open Market Installation Broadloom (direct glue down w/ pattern)SY $15.65 $15.65 $11.59 $11.59 $15.65 $8.46 $11.42 $9.06 $12.23 $9.06 $12.23 $11.46 $15.46 Open Market Open Market Installation Carpet Tile SY $12.81 $12.81 $9.50 $9.50 $12.81 $6.71 $9.06 $7.34 $9.91 $7.34 $9.91 $9.01 $11.26 Open Market Open Market Removal of Double Stick Installation SY $13.19 $13.19 $9.77 $9.77 $13.19 $7.24 $9.79 $7.24 $9.79 $7.24 $9.79 $9.66 $13.05 Open Market Open Market Removal of Broadloom (direct glue down)SY $6.69 $6.69 $4.96 $4.96 $6.69 $3.62 $4.90 $3.62 $4.90 $3.62 $4.90 $4.84 $6.52 Open Market Open Market Removal of Carpet Tile SY $6.41 $6.41 $4.74 $4.74 $6.41 $3.62 $4.90 $3.62 $4.90 $3.62 $4.90 $4.43 $5.99 Open Market Open Market Removal/Disposal Resilient Flooring SF $2.14 $2.14 $1.58 $1.58 $2.14 $1.27 $1.71 $1.46 $1.98 $1.46 $1.98 $1.46 $1.98 Open Market Open Market Carpet Disposal SY $1.71 $1.71 $1.27 $1.27 $1.71 $0.88 $1.21 $1.11 $1.49 $1.11 $1.49 $1.13 $1.53 Open Market Open Market Broadloom or Carpet Tile Reclamation Fee SY $3.85 $3.85 $2.85 $2.85 $3.85 $2.53 $3.42 $2.65 $3.59 $2.65 $3.59 $2.65 $3.59 Open Market Open Market Installation of VCT SF $2.98 $2.98 $2.22 $2.22 $2.98 $1.42 $1.92 $1.54 $2.08 $1.54 $2.08 $1.89 $2.56 Open Market Open Market Installation of Luxury Vinyl Tile (Planks or Squares)SF $4.08 $4.08 $3.03 $3.03 $4.08 $1.89 $2.56 $2.22 $2.98 $2.22 $2.98 $2.85 $3.85 Open Market Open Market Installation of Laminate (Planks or Squares)SF $4.18 $4.18 $3.10 $3.10 $4.18 $2.28 $2.91 $2.40 $3.16 $2.40 $3.16 $3.03 $4.12 Open Market Open Market Installation of Rubber Tile SF $4.45 $4.45 $3.55 $3.55 $4.45 $2.41 $3.27 $2.54 $3.44 $2.54 $3.44 $3.27 $4.41 Open Market Open Market Installation of Rubber Roll SF $8.21 $8.21 $6.57 $6.57 $8.21 $4.72 $5.90 $4.96 $6.21 $4.96 $6.21 $6.36 $7.96 Open Market Open Market Installation of Sheet Vinyl SY $30.77 $30.77 $22.80 $22.80 $30.77 $19.61 $26.49 $19.61 $26.49 $19.61 $26.49 $22.63 $30.57 Open Market Open Market Heat Welding (Sheet Vinyl)LF $6.10 $6.10 $4.52 $4.52 $6.10 $3.81 $5.13 $3.93 $5.30 $3.93 $5.30 $4.41 $5.96 Open Market Open Market Installation Flash cove (Sheet Vinyl/Rubber Roll-excludes metal finish piece)LF $15.64 $15.64 $11.59 $11.59 $15.64 $8.13 $10.97 $9.06 $12.23 $9.06 $12.23 $11.47 $15.49 Open Market Open Market Engineered Hardwood Flooring Glue Down Installation over Concrete standard straight lay (includes equipment for dust collection and protective gear)SF $15.58 $15.58 $10.12 $10.12 $15.58 $8.04 $12.37 $8.23 $12.65 $8.23 $12.65 $9.80 $15.08 Open Market Open Market Palletize/Shrink Wrap old carpet for reclamation SY $3.42 $3.42 $2.53 $2.53 $3.42 $1.89 $2.56 $2.22 $2.98 $2.22 $2.98 $2.22 $2.98 Open Market Open Market Conventional Furniture Moving (Light)SY $5.87 $5.87 $4.35 $4.35 $5.87 $3.62 $4.90 $3.62 $4.90 $3.62 $4.90 $4.23 $5.71 Open Market Open Market Conventional Furniture Moving (Medium)SY $7.49 $7.49 $5.55 $5.55 $7.49 $4.84 $6.52 $4.84 $6.52 $4.84 $6.52 $5.44 $7.34 Open Market Open Market L I F T Systems / Carpet Tile Projects Only - Add SY $21.66 $21.66 $16.05 $16.05 $21.66 $13.63 $18.41 $14.86 $20.06 $14.86 $20.06 $16.05 $21.66 Open Market Open Market Moisture Testing EA $341.57 $341.57 $253.02 $253.02 $341.57 $189.76 $256.17 $221.40 $298.88 $221.40 $298.88 $221.40 $298.88 Open Market Open Market Night / Saturday Labor - Add SY $6.12 $6.12 $4.88 $4.88 $6.12 $3.56 $4.46 $3.81 $4.78 $3.81 $4.78 $4.83 $6.05 Open Market Open Market Sunday / Holiday Labor - Add SY $9.17 $9.17 $7.34 $7.34 $9.17 $5.35 $6.69 $5.73 $7.16 $5.73 $7.16 $7.27 $9.07 Open Market Open Market Install Base LF $4.92 $4.92 $3.47 $3.47 $4.92 $2.53 $3.63 $2.53 $3.63 $2.53 $3.63 $3.30 $4.68 Open Market Open Market Furnish / Install Base, Std. 4-Inch Vinyl/Rubber Blend, Black/Brown LF $5.55 $5.55 $4.10 $4.10 $5.55 $3.16 $4.26 $3.16 $4.26 $3.16 $4.26 $3.93 $5.31 Open Market Open Market Furnish / Install Base, Std. 6-Inch Vinyl/Rubber Blend, Black/Brown LF $6.51 $6.51 $4.83 $4.83 $6.51 $3.71 $5.02 $3.71 $5.02 $3.71 $5.02 $4.63 $6.24 Open Market Open Market Furnish / Install Transition, Standard, Black/Brown/Gold/Silver LF $6.83 $6.83 $5.05 $5.05 $6.83 $3.79 $5.10 $3.79 $5.10 $3.79 $5.10 $4.86 $6.55 Open Market Open Market Furnish / Install Ceramic Tile SF $63.80 $63.80 $47.26 $47.26 $63.80 $36.75 $49.62 $36.75 $49.62 $36.75 $49.62 $47.26 $63.78 Open Market Open Market Floor Prep - Skim Coating to 1/8 Inch (Labor and Portland Based Material. Excludes leveling.)SF $2.98 $2.98 $2.22 $2.22 $2.98 $1.52 $2.05 $1.77 $2.39 $1.77 $2.39 $1.89 $2.56 Open Market Open Market Hourly Labor Rate for Flooring Contract Labor Services not Listed HR $168.03 $168.03 $124.48 $124.48 $168.03 $63.25 $85.39 $82.23 $111.02 $82.23 $111.02 $101.20 $136.64 Open Market Open Market Supplemental Benefits HR $26.26 $26.26 $26.26 $26.26 $26.26 $26.26 $26.26 $26.26 $26.26 $26.26 $26.26 $26.26 $26.26 Open Market Open Market Project Management Fee is included if labor is provided directly by MohawkONE Open Market Open Market LABOR NOTES: Labor prices are not to exceed prices and are effective 4/15/21. Installation of floor coverings are for direct glue down installation and include installation of floor covering and minor floor prep, defined as filling of minor gaps and voids no larger than 1/8"x1/8" and sweeping and are based on a clean and clear floor. Other services and ancillary items are available through Mohawk. These services are quoted job by job and negotiated between Mohawk and the customer. Ceramic tile material pricing includes standard profile tile product suitable for light to medium indoor commercial applications. Additional charges may apply for Fingerprinting and Background Checks. Labor quoted job by job for Alaska, Hawaii, American Samoa, Federated States of Micronesia, Guam, Midway Islands, Northern Marina Islands, Puerto Rico, and U.S. Virgin Islands. LABOR EXCLUSIONS: Asbestos Testing and Abatement Border Labor Carpet Cleaning Ceramic tile furnish and install, in addition to other stated exclusions herein, excludes accessories, trim pieces, specialty tiles, moisture membranes, flashing, wet area installations, setting materials, grout, transitions, freight and fuel surcharges Cleaning, sanding, refinishing, or sealing of new flooring Non-Continental: AK & HI West CA, CO, HI, AK, NV, NM, OR, WA, WY, MT, ID, SD, ND, UT South: AR, AZ, TX, LA, MS Southeast Region: AL, FL, GA, KY, NC, SC, Northeast Region: MA, ME, VT, NH, CT, RI, PA, VA, DC, RI, MD, DE, NJ Central: KS, OH, MI, MN, WI, MO, OK, MS, NE, IA, PA, IL, IN DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 Delivery/Handling to job site from installer warehouse Disposal of Existing Hard Tile Flooring Dumpster Charges Excessive trip charges and/or small job charges less than 200sy or 1,800sf per trade Excessive cutting/trimming/sanding/staining of hardwood/flooring for custom pattern work Extensive floor exceeding the above described floor prep Furniture Moving (high density or extraordinary) Hoisting Material, adhesive, pad, underlayment, base inside corners, base outside corners, entry mats, felt paper, rosin paper, moldings, plywood, solid wood planks or sleepers, vapor retarder, unless otherwise noted. Millwork/trim/transition/quarter round/wood base for completion of hardwood installation Moisture Remediation/Abatement Moving of computers, telephony, equipment, or personal items Pattern match labor or custom pattern labor, unless otherwise noted Payment and Performance Insurance Bonds Phasing Labor Protection of Floors Reclamation Government Imposed Fees are Excluded wherever applicable. Reclamation fee excludes packaging, palletization, and shipment to reclamation processor Removal/disposal of floorings other than quoted above Sales Tax - Local, State, and Federal Stair Labor Storage of Materials long-term Transitions exclude Schluter or similar needed for ceramic tile installation Union upcharges DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 55575.00001\40098778.2 Revised 2.9.22 Page 14 of 17 EXHIBIT “B” INSURANCE PROVISIONS Including Verification of Coverage, Sufficiency of Insurers, Errors and Omissions Coverage, Minimum Scope of Insurance, Deductibles and Self-Insured Retentions, and Severability of Interests (Separation of Insureds) DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 55575.00001\40098778.2 Revised 2.9.22 Page 15 of 17 INSURANCE 1. Procurement and Maintenance of Insurance. Contractor shall procure and maintain public liability and property damage insurance against all claims for injuries against persons or damages to property resulting from Contractor’s performance under this Agreement. Contractor shall procure and maintain all insurance at its sole cost and expense, in a form and content satisfactory to the City, and submit concurrently with its execution of this Agreement. Contractor shall also carry workers’ compensation insurance in accordance with California workers’ compensation laws. Such insurance shall be kept in full force and effect during the term of this Agreement, including any extensions. Such insurance shall not be cancelable without thirty (30) days advance written notice to City of any proposed cancellation. Certificates of insurance evidencing the foregoing and designating the City, its elected officials, officers, employees, agents, and volunteers as additional named insureds by blanket shall be delivered to and approved by City prior to commencement of services. The procuring of such insurance certificates, and endorsements evidencing the same shall not be construed as a limitation of Contractor’s obligation to indemnify City, its elected officials, officers, agents, employees, and volunteers. 2. Minimum Scope of Insurance. The minimum amount of insurance required under this Agreement shall be as follows: 1. Comprehensive general liability and personal injury with limits of at least one million dollars ($1,000,000.00) combined single limit coverage per occurrence and two million dollars ($2,000,000) general aggregate; 2. Automobile liability insurance with limits of at least one million dollars ($1,000,000.00) per occurrence; 3. Professional liability (errors and omissions) insurance with limits of at least one million dollars ($1,000,000.00) per occurrence and two million dollars ($2,000,000) annual aggregate is: _________ required ____X_____ is not required; 4. Workers’ Compensation insurance in the statutory amount as required by the State of California and Employer’s Liability Insurance with limits of at least one million dollars $1 million per occurrence. If Contractor has no employees, Contractor shall complete the City’s Request for Waiver of Workers’ Compensation Insurance Requirement form. 3. Primary Insurance. For any claims related to this Agreement, Contractor’s insurance coverage shall be primary with respect to the City and its respective elected offi cials, officers, employees, agents, and volunteers. Any insurance or self-insurance maintained by City and its respective elected officials, officers, employees, agents, and volunteers shall be in excess of Contractor’s insurance and shall not contribute with it. For Workers’ Compensation and Employer’s Liability Insurance only, the insurer shall waive all rights of subrogation and DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 55575.00001\40098778.2 Revised 2.9.22 Page 16 of 17 contribution it may have against City, its elected officials, officers, employees, agents, and volunteers. 5. Sufficiency of Insurers. Insurance required in this Agreement shall be provided by authorized insurers in good standing with the State of California. Coverage shall be provided by insurers admitted in the State of California with an A.M. Best’s Key Rating of B++, Class VII, or better, unless otherwise acceptable to the City. 6. Verification of Coverage. Contractor shall furnish City with both certificates of insurance and blanket endorsements, including blanket additional insured endorsements, affecting all of the coverages required by this Agreement. The certificates are to be signed by a person authorized by that insurer to bind coverage on its behalf. All proof of insurance is to be received and approved by the City before work commences. City reserves the right to require Contractor’s insurers to provide complete. Additional insured endorsements are not required for Errors and Omissions and Workers’ Compensation policies. Verification of Insurance coverage may be provided by: (1) an approved General and/or Auto Liability Endorsement Form for the City of Palm Springs or (2) an acceptable Certificate of Liability Insurance Coverage with an approved Additional Insured Endorsement with the following endorsements stated on the certificate: A. "The City of Palm Springs, its officials, employees, and agents are included as an additional insured…” ("as respects City of Palm Springs Contract No.___" or "for any and all work performed with the City" may be included in this statement). B. "This insurance is primary and non-contributory over any insurance or self- insurance the City may have..." ("as respects City of Palm Springs Contract No.___" or "for any and all work performed with the City" may be included in this statement). C. "Should any of the above-described policies be canceled before the expiration date thereof, the issuing company will mail 30 days written notice to the Certificate Holder named." Language such as, “endeavor to” mail and "but failure to mail such notice shall impose no obligation or liability of any kind upon the company, its agents or representative" is not acceptable and must be crossed out. D. Both the Workers’ Compensation and Employers' Liability policies shall contain the insurer's waiver of subrogation in favor of City, its elected officials, officers, employees, agents, and volunteers. In addition to the endorsements listed above, the City of Palm Springs shall be named the certificate holder on the policies. All certificates of insurance and endorsements are to be received and approved by the City before work commences. All certificates of insurance must be authorized by a person with authority to bind coverage, whether that is the authorized agent/broker or insurance underwriter. Failure to obtain the required documents prior to the commencement of work shall not waive the Contractor’s obligation to provide them. DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 55575.00001\40098778.2 Revised 2.9.22 Page 17 of 17 7. Deductibles and Self-Insured Retentions. Contractor guarantees payment of all deductibles and self-insured retentions. 8. Severability of Interests (Separation of Insureds). This insurance applies separately to each insured against whom claim is made or suit is brought except with respect to the limits of the insurer’s liability. DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. INSURER(S) AFFORDING COVERAGE INSURER F : INSURER E : INSURER D : INSURER C : INSURER B : INSURER A : NAIC # NAME:CONTACT (A/C, No):FAX E-MAILADDRESS: PRODUCER (A/C, No, Ext):PHONE INSURED REVISION NUMBER:CERTIFICATE NUMBER:COVERAGES IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. OTHER: (Per accident) (Ea accident) $ $ N / A SUBR WVD ADDL INSD THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. $ $ $ $PROPERTY DAMAGE BODILY INJURY (Per accident) BODILY INJURY (Per person) COMBINED SINGLE LIMIT AUTOS ONLY AUTOSAUTOS ONLY NON-OWNED SCHEDULEDOWNED ANY AUTO AUTOMOBILE LIABILITY Y / N WORKERS COMPENSATION AND EMPLOYERS' LIABILITY OFFICER/MEMBER EXCLUDED? (Mandatory in NH) DESCRIPTION OF OPERATIONS below If yes, describe under ANY PROPRIETOR/PARTNER/EXECUTIVE $ $ $ E.L. DISEASE - POLICY LIMIT E.L. DISEASE - EA EMPLOYEE E.L. EACH ACCIDENT EROTH-STATUTEPER LIMITS(MM/DD/YYYY)POLICY EXP(MM/DD/YYYY)POLICY EFFPOLICY NUMBERTYPE OF INSURANCELTRINSR DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) EXCESS LIAB UMBRELLA LIAB $EACH OCCURRENCE $AGGREGATE $ OCCUR CLAIMS-MADE DED RETENTION $ $PRODUCTS - COMP/OP AGG $GENERAL AGGREGATE $PERSONAL & ADV INJURY $MED EXP (Any one person) $EACH OCCURRENCE DAMAGE TO RENTED $PREMISES (Ea occurrence) COMMERCIAL GENERAL LIABILITY CLAIMS-MADE OCCUR GEN'L AGGREGATE LIMIT APPLIES PER: POLICY PRO-JECT LOC CERTIFICATE OF LIABILITY INSURANCE DATE (MM/DD/YYYY) CANCELLATION AUTHORIZED REPRESENTATIVE ACORD 25 (2016/03) © 1988-2016 ACORD CORPORATION. All rights reserved. CERTIFICATE HOLDER The ACORD name and logo are registered marks of ACORD HIRED AUTOS ONLY 05/25/2022 MARSH USA, INC. TWO ALLIANCE CENTER3560 LENOX ROAD, SUITE 2400ATLANTA, GA 30326 CN101225804--GAWU-21-22 . Liberty Mutual Insurance Corp. Liberty Mutual Fire Insurance Company Liberty Insurance Corporation American Guarantee & Liability Ins Co 26247 42404 23035 33600 Mohawk Industries, Inc. 160 S. Industrial BlvdCalhoun, GA 30701 ATL-005437856-00 0 X X X X X terms and conditions. self-insured retention per policy evidenced above is subject to a The Excess General Liability policy EB2-651-004272-041 10/01/2021 10/01/2022 2,000,000 5,000 2,000,000 2,000,000 B X X X AS2-651004272-031 10/01/2021 10/01/2022 5,000,000 D X X X X AUC-9139812-15 10/01/2021 10/01/2022 5,000,000 5,000,000 C C A N WA7-65D-004272-011 (MA) WC7-651004272-021 (WI MN) WA5-65D-004272-271 (AOS) 10/01/2021 10/01/2021 10/01/2021 10/01/2022 10/01/2022 10/01/2022 1,000,000 1,000,000 1,000,000 RE: Contract No. 2020002149 The City of Palm Springs, its officials, employees, and agents are included as Additional Insured where required by written contract. Waiver of subrogation is applicable where required by written contract and subject to policy terms and conditions. Should any of the above described policies be cancelled before the expiration date thereof, 30 day notice of may be delivered to certificate holders in accordance with the policy. This insurance is primary and non-contributory. 2,000,000 2,000,000 XX B City of Palm Springs of Marsh USA Inc. Attention: City Manager/ City Clerk 3200 E. Tahquitz Canyon Way Palm Springs, CA 92262 DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 LC 20 19 06 05 Page 1 of 2 LIBERTY MUTUAL FIRE INSURANCE COMPANY THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. BLANKET ADDITIONAL INSURED This endorsement modifies insurance provided under the following: EXCESS COMMERCIAL GENERAL LIABILITY COVERAGE FORM SECTION II - WHO IS AN INSURED is amended to include as an insured any person or organization for whom you have agreed in writing to provide liability insurance. But: The insurance provided by this amendment: 1. Applies only to "bodily injury" or "property damage" arising out of (a) "your work" or (b) premises or other property owned by or rented to you; 2. Applies only to coverage and minimum limits of insurance required by the written agreement, but in no event exceeds either the scope of coverage or the limits of insurance provided by this policy; and 3. Does not apply to any person or organization for whom you have procured separate liability insurance while such insurance is in effect, regardless of whether the scope of coverage or limits of insurance of this policy exceed those of such other insurance or whether such other insurance is valid and collectible. The following provisions also apply: 1. Regardless of any provisions of any written agreement, policy of insurance, or endorsement, insurance provided to the Additional Insured is excess over the "self-insured amount". 2. Subject to 1. above, where the applicable written agreement requires the insured to provide liability insurance on a primary, excess, contingent, or any other basis, this policy will apply solely on the basis required by such written agreement 3. Where the applicable written agreement does not specify on what basis the liability insurance will apply, this insurance is primary (subject to the "self-insured amount"), and we will share liability in excess of the "self- insured amount" with any other valid and collectible primary insurance available to the Additional Insured. 4. We shall have no duty to defend the Additional Insured. 5. Items 4.c. and d. of Condition 4. Other Insurance of SECTION IV will not apply to the Additional Insured. 6. This endorsement shall not apply to any person or organization for any "bodily injury" or "property damage" if any other additional insured endorsement applies to that person or organization with regard to the "bodily injury" or "property damage". 7. Subject to 1. above, if any other additional insured endorsement applies to any person or organization and you are obligated under a written agreement to provide liability insurance on a primary, excess, contingent, or any DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 Page 2 of 2 other basis for that additional insured, this policy will apply solely on the basis required by such written agreement. Where the applicable written agreement does not specify on what basis the liability insurance will apply, this insurance is primary (subject to the “self-insured amount”), and we will share liability in excess of the “self-insured amount” with any other valid and collectible primary insurance available to the Additional Insured. Policy Number: EB2-651-004272-041 LC 20 19 06 05 DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 CG 24 04 12 19 © Insurance Services Office, Inc., 2018 Page 1 of 1 POLICY NUMBER: EB2-651-004272-041 COMMERCIAL GENERAL LIABILITY CG 24 04 12 19 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. WAIVER OF TRANSFER OF RIGHTS OF RECOVERY AGAINST OTHERS TO US (WAIVER OF SUBROGATION) This endorsement modifies insurance provided under the following: COMMERCIAL GENERAL LIABILITY COVERAGE PART ELECTRONIC DATA LIABILITY COVERAGE PART LIQUOR LIABILITY COVERAGE PART POLLUTION LIABILITY COVERAGE PART DESIGNATED SITES POLLUTION LIABILITY LIMITED COVERAGE PART DESIGNATED SITES PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART RAILROAD PROTECTIVE LIABILITY COVERAGE PART UNDERGROUND STORAGE TANK POLICY DESIGNATED TANKS SCHEDULE Name Of Person(s) Or Organization(s): As required by written contract or agreement entered into prior to loss. Information required to complete this Schedule, if not shown above, will be shown in the Declarations. The following is added to Paragraph 8. Transfer Of Rights Of Recovery Against Others To Us of Section IV – Conditions: We waive any right of recovery against the person(s) or organization(s) shown in the Schedule above because of payments we make under this Coverage Part. Such waiver by us applies only to the extent that the insured has waived its right of recovery against such person(s) or organization(s) prior to loss. This endorsement applies only to the person(s) or organization(s) shown in the Schedule above. DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 POLICY NUMBER:COMMERCIAL AUTO CA 20 01 10 13 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. LESSOR - ADDITIONAL INSURED AND LOSS PAYEE This endorsement modifies insurance provided under the following: AUTO DEALERS COVERAGE FORM BUSINESS AUTO COVERAGE FORM MOTOR CARRIER COVERAGE FORM SCHEDULE CA 20 01 10 13 © Insurance Services Office, Inc., 2011 Page 1 of 2 Insurance Company: Policy Number: Expiration Date: Named Insured: Address: Additional Insured (Lessor): Address: Designation Or Description Of "Leased Autos": Effective Date: SEE ATTACHED SCHEDULE SEE ATTACHED SCHEDULE With respect to coverage provided by this endorsement,the provisions of the Coverage Form apply unless modified by the endorsement. AS2-651-004272-031 DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 Coverages Limit Of Insurance Covered Autos Liability Each "Accident" Comprehensive Actual Cash Value Or Cost Of Repair, Whichever Is Less, Minus Deductible For Each Covered "Leased Auto"$ $ Collision Actual Cash Value Or Cost Of Repair, Whichever Is Less, Minus $Deductible For Each Covered "Leased Auto" Actual Cash Value Or Cost Of Repair, Whichever Is Less, Minus $Deductible For Each Covered "Leased Auto" Information required to complete this Schedule, if not shown above, will be shown in the Declarations. CA 20 01 10 13© Insurance Services Office, Inc., 2011 Page 2 of 2 Specified Causes Of Loss A.Coverage 1.Any "leased auto"designated or described in the Schedule will be considered a covered "auto"you own and not a covered "auto"you hire or borrow. 2.For a "leased auto"designated or described in the Schedule,the Who Is An Insured provision under Covered Autos Liability Coverage is changed to include as an "insured"the lessor named in the Schedule.However,the lessor is an "insured"only for "bodily injury"or "property damage"resulting from the acts or omissions by: a.You; b.Any of your "employees" or agents; or c.Any person,except the lessor or any "employee"or agent of the lessor,operating a "leased auto"with the permission of any of the above. 3.The coverages provided under this endorsement apply to any "leased auto" described in the Schedule until the expiration date shown in the Schedule,or when the lessor or his or her agent takes possession of the "leased auto", whichever occurs first. B.Loss Payable Clause 1.We will pay,as interest may appear,you and the lessor named in this endorsement for "loss" to a "leased auto". 2.The insurance covers the interest of the lessor unless the "loss"results from fraudulent acts or omissions on your part. 3.If we make any payment to the lessor,we will obtain his or her rights against any other party. C.Cancellation 1.If we cancel the policy,we will mail notice to the lessor in accordance with the Cancellation Common Policy Condition. 2.If you cancel the policy,we will mail notice to the lessor. 3.Cancellation ends this agreement. D.The lessor is not liable for payment of your premiums. E.Additional Definition As used in this endorsement: "Leased auto"means an "auto"leased or rented to you,including any substitute,replacement or extra "auto"needed to meet seasonal or other needs, under a leasing or rental agreement that requires you to provide direct primary insurance for the lessor. DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 POLICY NUMBER:COMMERCIAL AUTO CA 04 44 10 13 THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. WAIVER OF TRANSFER OF RIGHTS OF RECOVERY This endorsement modifies insurance provided under the following: AUTO DEALERS COVERAGE FORM BUSINESS AUTO COVERAGE FORM MOTOR CARRIER COVERAGE FORM SCHEDULE CA 04 44 10 13 © Insurance Services Office, Inc., 2011 Page 1 of 1 AGAINST OTHERS TO US (WAIVER OF SUBROGATION) Name(s) Of Person(s) Or Organization(s): Information required to complete this Schedule, if not shown above, will be shown in the Declarations. With respect to coverage provided by this endorsement,the provisions of the Coverage Form apply unless modified by the endorsement. The Transfer Of Rights Of Recovery Against Others To Us condition does not apply to the person(s)or organization(s)shown in the Schedule, but only to the extent that subrogation is waived prior to the "accident"or the "loss"under a contract with that person or organization. Premium: $ Any person or organization for whom you perform work under a written contract if the contract requires you to obtain this agreement from us, but only if the contract is executed prior to the injury or damage occurring. AS2-651-004272-031 INCL DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 Policy Number: Issued By: Schedule LIM 99 01 05 11 © 2011, Liberty Mutual Group of Companies. All rights reserved.Page 1 of 1 Includes copyrighted material of Insurance Services Office, Inc. with its permission. THIS ENDORSEMENT CHANGES THE POLICY. PLEASE READ IT CAREFULLY. NOTICE OF CANCELLATION TO THIRD PARTIES This endorsement modifies insurance provided under the following: BUSINESS AUTO COVERAGE PART MOTOR CARRIER COVERAGE PART GARAGE COVERAGE PART TRUCKERS COVERAGE PART EXCESS AUTOMOBILE LIABILITY INDEMNITY COVERAGE PART SELF-INSURED TRUCKER EXCESS LIABILITY COVERAGE PART COMMERCIAL GENERAL LIABILITY COVERAGE PART EXCESS COMMERCIAL GENERAL LIABILITY COVERAGE PART PRODUCTS/COMPLETED OPERATIONS LIABILITY COVERAGE PART LIQUOR LIABILITY COVERAGE PART Name of Other Person(s)/ Email Address or mailing Number Organization(s): address: Days Notice: A.If we cancel this policy for any reason other than nonpayment of premium,we will notify the persons or organizations shown in the Schedule above.We will send notice to the email or mailing address listed above at least 10 days,or the number of days listed above,if any,before the cancellation becomes effective. In no event does the notice to the third party exceed the notice to the first named insured. B.This advance notification of a pending cancellation of coverage is intended as a courtesy only.Our failure to provide such advance notification will not extend the policy cancellation date nor negate cancellation of the policy. All other terms and conditions of this policy remain unchanged. AS2-651-004272-031 Liberty Mutual Fire Insurance Co. Per Schedule on file with Company Per Schedule on file with Company 30 DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 Not applicable in Alaska, Kansas, Kentucky, New Hampshire, and New Jersey WAIVER OF OUR RIGHT TO RECOVER FROM OTHERS ENDORSEMENT We have the right to recover our payments from anyone liable for an injury covered by this policy. We will not enforce our right against the person or organization named in the Schedule. (This agreement applies only to the extent that you perform work under a written contract that requires you to obtain this agreement from us.) This agreement shall not operate directly or indirectly to benefit anyone not named in the Schedule. Schedule Any person or organization for which the employer has agreed by written contract, executed prior to loss, may execute a waiver of subrogation. However, for purposes of work performed by the employer in Missouri, this waiver of subrogation does not apply to any construction group of classifications as designated by the waiver of right to recover from others (subrogation) rule in our manual. Where required by contract or written agreement prior to loss and allowed by law In the states of Alabama, Arizona, Arkansas, Colorado, Delaware, Dist. Of Col, Georgia, Idaho, Illinois, Indiana, Maine, Michigan, Mississippi, Missouri, Montana, Nevada, New Mexico, North Carolina, Oklahoma, Pennsylvania, Rhode Island, South Carolina, South Dakota, Vermont and West Virginia, the premium charge is 2% of the total manual premium, subject to a minimum premium of $100 per policy. In the states of Connecticut, Florida, Iowa, Maryland, Nebraska and Oregon, the premium charge is 1% of the total manual premium, subject to a minimum premium of $250 per policy. In the state of Hawaii, the premium charge is $250 and determined as follows: The premium chargefor thisendorsement is 1% of the total manual premium, subject to a minimum premium of $250 per policy. In the state of Louisiana, the premium charge is 2% of the total standard premium, subject to a minimum premium of $250 per policy. In the states of New York and Tennessee, the premium charge is 2% of the total manual premium, subject to a minimum premium of $250 per policy. In the state of Virginia, the premium charge is 5% of the total manual premium, subject to a minimum premium of $250 per policy. Issued by For attachment to Policy No. Effective Date Premium $ Issued to Endorsement No.Mohawk Industries, Inc. LM Insurance Corporation 27243 WA5-65D-004272-271 WC 00 03 13 Ed. 04/01/1984 © 1983 National Council on Compensation Insurance.Page of 1 1 DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 Name of Other Person(s) /Email Address or mailing address:Number Days Notice: Organization(s): Schedule on file with the company Schedule on file with the company 30 NOTICE OF CANCELLATION TO THIRD PARTIES A.If we cancel this policy for any reason other than nonpayment of premium, we will notify the persons or organizations shown in the Schedule below. We will send notice to the email or mailing address listed below at least 10 days, or the number of days listed below, if any, before cancellation becomes effective. In no event does the notice to the third party exceed the notice to the first named insured. B.This advance notification of a pending cancellation of coverage is intended as a courtesy only. Our failure to provide such advance notification will not extend the policy cancellation date nor negate cancellation of the policy. Schedule All other terms and conditions of this policy remain unchanged. Issued by For attachment to Policy No. Effective Date Premium $ Issued to Endorsement No.Mohawk Industries, Inc. LM Insurance Corporation 27243 WA5-65D-004272-271 WC 99 20 75 Ed. 12/01/2016 Page of© 2016 Liberty Mutual Insurance 1 1 DocuSign Envelope ID: 4259CC7C-AEC5-439F-8F1A-DAC872C6F17CDocuSign Envelope ID: 2844807F-8605-4C08-9354-1616B1AFEC40 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. INSURER(S) AFFORDING COVERAGE INSURER F : INSURER E : INSURER D : INSURER C : INSURER B : INSURER A : NAIC # NAME:CONTACT (A/C, No):FAX E-MAILADDRESS: PRODUCER (A/C, No, Ext):PHONE INSURED REVISION NUMBER:CERTIFICATE NUMBER:COVERAGES IMPORTANT: If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. OTHER: (Per accident) (Ea accident) $ $ N / A SUBR WVD ADDL INSD THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. $ $ $ $PROPERTY DAMAGE BODILY INJURY (Per accident) BODILY INJURY (Per person) COMBINED SINGLE LIMIT AUTOS ONLY AUTOSAUTOS ONLY NON-OWNED SCHEDULEDOWNED ANY AUTO AUTOMOBILE LIABILITY Y / N WORKERS COMPENSATION AND EMPLOYERS' LIABILITY OFFICER/MEMBER EXCLUDED? (Mandatory in NH) DESCRIPTION OF OPERATIONS below If yes, describe under ANY PROPRIETOR/PARTNER/EXECUTIVE $ $ $ E.L. DISEASE - POLICY LIMIT E.L. DISEASE - EA EMPLOYEE E.L. EACH ACCIDENT EROTH-STATUTEPER LIMITS(MM/DD/YYYY)POLICY EXP(MM/DD/YYYY)POLICY EFFPOLICY NUMBERTYPE OF INSURANCELTRINSR DESCRIPTION OF OPERATIONS / LOCATIONS / VEHICLES (ACORD 101, Additional Remarks Schedule, may be attached if more space is required) EXCESS LIAB UMBRELLA LIAB $EACH OCCURRENCE $AGGREGATE $ OCCUR CLAIMS-MADE DED RETENTION $ $PRODUCTS - COMP/OP AGG $GENERAL AGGREGATE $PERSONAL & ADV INJURY $MED EXP (Any one person) $EACH OCCURRENCE DAMAGE TO RENTED $PREMISES (Ea occurrence) COMMERCIAL GENERAL LIABILITY CLAIMS-MADE OCCUR GEN'L AGGREGATE LIMIT APPLIES PER: POLICY PRO-JECT LOC CERTIFICATE OF LIABILITY INSURANCE DATE (MM/DD/YYYY) CANCELLATION AUTHORIZED REPRESENTATIVE ACORD 25 (2016/03) © 1988-2016 ACORD CORPORATION. All rights reserved. CERTIFICATE HOLDER The ACORD name and logo are registered marks of ACORD HIRED AUTOS ONLY D self-insured retention per policy 1,000,000 10/01/2024 EB2-651-004272-043 ATL-005437856-04 1,000,000 5,000,000 WC7-651004272-023 (WI MN) X 23035 5,000,000 ATLANTA, GA 30326 N X10/01/2023 0 10/01/2024 26247 10/01/2024 AS2-651-004272-033 A terms and conditions. 2,000,000 2,000,000 42404 Liberty Mutual Fire Insurance Company 1,000,000 X X insurance is primary and non-contributory. 09/25/2023 10/01/2023 RE: Contract No. 2020002149 The City of Palm Springs, its officials, employees, and agents are included as Additional Insured where required by written contract. Waiver of subrogation is applicable where required by written contract and subject X 10/01/2023 3200 E. Tahquitz Canyon Way Palm Springs, CA 92262 City of Palm Springs American Guarantee & Liability Ins Co to policy terms and conditions. Should any of the above described policies be cancelled before the expiration date thereof, 30 day notice of may be delivered to certificate holders in accordance with the policy. This B Liberty Insurance Corporation CN101225804--GAWU-23-24 evidenced above is subject to a 5,000 10/01/2024 5,000,000 AUC-9139812-17 C 2,000,000 33600 1,000,000 1,000,000 WA5-65D-004272-273 (AOS) TWO ALLIANCE CENTER MARSH USA, LLC. X 3560 LENOX ROAD, SUITE 2400 160 S. Industrial Blvd Mohawk Industries, Inc. Calhoun, GA 30701 The Excess General Liability policy X 10/01/2023 Attention: City Manager/ City Clerk X X X 10/01/2023 X X B . X 10/01/2024 Liberty Mutual Insurance Corp. X Docusign Envelope ID: 180AE912-59DB-41DE-BFEC-2895A52A1C33